{"canonical":"https://abierto.us/opportunities/w912qrpdbfortcarsonecs","key":"W912QRPDBFORTCARSONECS","url":"https://abierto.us/opportunities/w912qrpdbfortcarsonecs","title":"Sources Sought/Market Intelligence: Fort Carson Equipment Concentration Site - Potential Use of Construction Management at Risk using Other Transaction Authority (OTA)","solicitation_number":"W912QR-PDB-FortCarsonECS","notice_type":"r","open":false,"response_deadline":"2026-08-07T14:00:00Z","first_posted":"2026-06-24","last_posted":"2026-07-29","department":"DEPT OF DEFENSE","subagency":"DEPT OF THE ARMY","office":"W072 ENDIST LOUISVILLE","naics":"236220","psc":null,"set_aside":null,"place_state":"CO","winner":null,"award_amount":null,"publications":[{"notice_id":"1aa4a6101d2e447aa7e287e888112051","title":"Fort Carson Equipment Concentration Site: Potential Use of Progressive Design Build using Other Transaction Authority (OTA)","solicitation_number":"W912QR-PDB-FortCarsonECS","notice_type":"r","base_type":"r","posted":"2026-06-24","posted_at":null,"due_at":"2026-07-10T14:00:00Z","due_date":"2026-07-10","cancelled":null,"archived":null,"archive_date":"2026-07-25","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/1aa4a6101d2e447aa7e287e888112051/view","enriched":false,"history":[]},{"notice_id":"739c2a278c6148a49dd168c645c51881","title":"Fort Carson Equipment Concentration Site: Potential Use of Progressive Design Build using Other Transaction Authority (OTA)","solicitation_number":"W912QR-PDB-FortCarsonECS","notice_type":"r","base_type":"r","posted":"2026-06-24","posted_at":null,"due_at":"2026-07-10T14:00:00Z","due_date":"2026-07-10","cancelled":null,"archived":null,"archive_date":"2026-07-25","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/739c2a278c6148a49dd168c645c51881/view","enriched":false,"history":[]},{"notice_id":"f46a14d7122b431a9b7ec553eea006d9","title":"Sources Sought/Market Intelligence: Fort Carson Equipment Concentration Site - Potential Use of Progressive Design Build using Other Transaction Authority (OTA)","solicitation_number":"W912QR-PDB-FortCarsonECS","notice_type":"r","base_type":"r","posted":"2026-07-06","posted_at":null,"due_at":"2026-07-10T14:00:00Z","due_date":"2026-07-10","cancelled":null,"archived":null,"archive_date":"2026-07-25","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/f46a14d7122b431a9b7ec553eea006d9/view","enriched":false,"history":[]},{"notice_id":"4486a70e667e4326bd32b18ce897a1b3","title":"Sources Sought/Market Intelligence: Fort Carson Equipment Concentration Site - Potential Use of Progressive Design Build using Other Transaction Authority (OTA)","solicitation_number":"W912QR-PDB-FortCarsonECS","notice_type":"r","base_type":"r","posted":"2026-07-29","posted_at":null,"due_at":"2026-08-07T14:00:00Z","due_date":"2026-08-07","cancelled":null,"archived":null,"archive_date":"2026-08-22","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/4486a70e667e4326bd32b18ce897a1b3/view","enriched":false,"history":[]},{"notice_id":"474e35f26f0e4581a0cde73f9e6592b5","title":"Sources Sought/Market Intelligence: Fort Carson Equipment Concentration Site - Potential Use of Construction Management at Risk using Other Transaction Authority (OTA)","solicitation_number":"W912QR-PDB-FortCarsonECS","notice_type":"r","base_type":"r","posted":"2026-07-29","posted_at":null,"due_at":"2026-08-07T14:00:00Z","due_date":"2026-08-07","cancelled":null,"archived":null,"archive_date":"2026-08-22","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/474e35f26f0e4581a0cde73f9e6592b5/view","enriched":false,"history":[]}],"latest_notice_id":"474e35f26f0e4581a0cde73f9e6592b5","first_type":"r","notices":[{"dates":{"posted":"2026-06-24","response_deadline":{"raw":"2026-07-10T10:00:00-04:00","utc":"2026-07-10T14:00:00Z","date":"2026-07-10","time":"10:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/1aa4a6101d2e447aa7e287e888112051/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Fort Carson Equipment Concentration Site: Potential Use of Progressive Design Build using Other Transaction Authority (OTA)","agency":{"office":{"code":"W912QR","name":"W072 ENDIST LOUISVILLE"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"40202-2230","city":"LOUISVILLE","state":"KY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-07-25","archive_type":"auto15"},"contacts":[{"name":"Chris Brackett","role":"primary","email":"Christopher.brackett@usace.army.mil","phone":"5023156666"}],"base_type":{"code":"r","label":"Sources Sought"},"notice_id":"1aa4a6101d2e447aa7e287e888112051","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T00:55:27.040971Z","row_sha256":"86e9c51de5fadf160051d53f26f17754c53026289594ef4602e3d923d7572e63","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T00:55:27.040971Z","first_seen_at":"2026-09-16T00:55:27.040971Z"},"description":{"text":"REQUEST FOR INFORMATION (RFI) / MARKET RESEARCH NOTICE Notice: This is a Request for Information (RFI) for market research and for informational purposes only. This announcement does not constitute a Solicitation or a Request for Proposal (RFP), and no solicitation is currently available. Participation in this RFI is strictly voluntary. The Government will not be obligated to award any agreement or contract because of this RFI, nor will it reimburse respondents for any costs associated with the preparation or submission of information. Submitting a response will not affect a firm’s ability to submit a proposal should a formal solicitation be issued in the future. NAICS Code: 236220 – Commercial and Institutional Building Construction (Note: While Other Transaction Authority is not subject to FAR-based small business regulations, this NAICS code is provided for market research to help the Government understand the size and demographics of the interested industrial base.) Small Business Size Standard: $45 Million PROJECT OVERVIEW The U.S. Army Corps of Engineers (USACE), Louisville District, has a requirement for the design and construction of an Equipment Concentration Site (ECS) complex of facilities on Fort Carson. The scope of work consists of furnishing all necessary equipment, materials, labor, supervision, quality control, and supplies to deliver a fully functional Area Maintenance Support Activity (AMSA) shop, General Purpose Warehouse (GPW), and Organizational Storage Building. Key features of the project may include: Vehicle maintenance shop required features including but not limited to concrete shop aprons, vehicle wash rack/platform, bi-level equipment loading ramps. Specialized Systems: special building foundations, extensive pavements, improved surfaces, and the related site clearing, and excavation costs associated with developing the 48-acre parcel of land. Administrative & Support: Adjoining maintenance shops, tool rooms, administrative offices, and personnel support spaces. Military Equipment Parking lot & Site Work: Construction of paving areas for heavy equipment, POVs, security fencing, and utility tie-ins. Estimated Acquisition Magnitude: $75,000,000.00 Planned Acquisition Strategy: Progressive Design-Build (PDB) via Other Transaction Authority (OTA) The Government is considering utilizing an Other Transaction (OT) Agreement for a prototype project under the authority of 10 U.S.C. § 2808a. This authority is intended for military construction projects that involve testing and experimentation associated with new and emergent construction technologies to achieve potential benefits such as enhanced mission resilience, improved installation support, or cost and schedule reduction. The anticipated delivery method is Progressive Design-Build (PDB). Phase 1 (Design & Pre-Construction): The Government and the OT Awardee will work collaboratively to advance the design, perform constructability reviews, conduct open-book cost estimating, and mitigate project risks. Phase 2 (Construction): Upon reaching an agreed-upon level of design (e.g., 60% to 90%), the Awardee will propose a Guaranteed Maximum Price (GMP). If the GMP is accepted, the Government will exercise Phase 2 for construction execution. If a GMP cannot be agreed upon, the Government retains an \"off-ramp\" to complete the design and construct the facility via alternative methods. INFORMATION REQUESTED 1. Company Profile: Firm Name, Address, and Point of Contact (Name, Title). Phone Number, Email Address, and Unique Entity ID (UEI). Socioeconomic Status (Large, Small, 8(a), SDVOSB, etc.). 2. Other Transaction Authority (OTA) & Statutory Compliance: Innovative Technologies: The authority for this OTA (10 U.S.C. § 2808a) is focused on prototyping with new or emergent construction technologies. Describe any innovative materials, methods, or technologies your firm could propose for a project of this scale that could lead to cost savings, schedule acceleration, or enhanced facility performance and resilience. OTA Experience: Describe your firm's previous experience (if any) executing prototype projects under an OTA. Barriers to Innovation: What commercial or Government-imposed barriers currently make it difficult to propose or implement innovative construction technologies on traditional military construction projects? How could the flexibility of an OTA help overcome these barriers? What project characteristics make PDB-OTA particularly advantageous or disadvantageous for this requirement? 3. Progressive Design-Build (PDB) / Early Contractor Involvement: Baseline Definition: What minimum level of detail (e.g., Statement of Need, conceptual site plans, target budget) does your firm require prior to entering Phase 1 (Design/Pre-construction) to feel confident in the project's viability? Collaborative Framework: What collaborative mechanisms (such as joint design charrettes, target-value design workshops, or phased scoping approvals) do you recommend the Government implement in the first 30-90 days to rapidly transition from a \"blank page\" to a mutually agreed-upon baseline? Describe your experience executing Progressive Design-Build, Construction Manager at Risk (CMAR), or other highly collaborative delivery methods. How do you approach \"open-book\" pricing and transparency during Phase 1 (Pre-Construction) to build trust and ensure the Government is receiving fair market value? 4. Guaranteed Maximum Price (GMP), Risk Allocation & Compensation: Phase 1 Off-Ramp Risk: If the Government and the contractor cannot reach an agreement on the GMP or final design (the \"off-ramp\"), what specific compensation structures (e.g., stipends, time-and-materials for design effort) would adequately compensate your firm for pre-construction efforts? Payment Milestones: Because an OTA allows for flexible payment structures, what milestone payment arrangement during Phase 1 (e.g., monthly progress, completion of design percentages, deliverable-based) best supports your firm's cash flow and resource allocation? Data Rights: Under an OTA, data rights and intellectual property can be negotiated. What data rights structure for the final design deliverables (if an off-ramp is taken) would provide a fair balance between the Government's need to construct the facility and your firm's proprietary design methods? In your experience with PDB, at what design milestone (e.g., 35%, 65%, 90%) is it most advantageous to lock in the GMP for a complex aviation facility, and why? How do you handle the procurement of long-lead items (e.g., switchgear, specialized fire pumps, large span steel) prior to establishing the final GMP? What level of cost growth would you typically expect between conceptual planning and GMP establishment? 5. Industrial Maintenance & Storage Facility Construction Expertise: Describe your specific experience with large-scale heavy tactical maintenance facilities, specialized systems like tactical vehicle wash platforms, and highly specialized fire suppression systems. What are the greatest supply chain, scheduling, or technical risks you foresee for a project of this type at Fort Carson, and how would the PDB delivery method help mitigate them? Are there specific trades, materials, equipment, or subcontractor resources in the Fort Carson/Colorado Springs market that are currently constrained? Would early contractor involvement through Progressive Design-Build materially improve the Government’s ability to manage these market risks? Why or why not? 6. Teaming & Subcontractor Integration: Under a PDB model, how and when do you plan to on-board your critical subcontractors (e.g., structural steel, MEP, fire protection)? Will you compete these subcontracts openly during Phase 1, or do you prefer bringing in established partners from day one? 7. Feedback on the Acquisition Strategy & Alternatives: Does the proposed PDB-OTA strategy incentivize your firm to participate? Why or why not? Are there alternative acquisition strategies, phasing approaches, or commercial practices the Government has not considered that would yield a better facility, faster delivery, or lower cost? Have current market conditions increased the value of collaborative delivery methods compared to traditional procurement methods? If so, how? 8. Bonding Capability: Phased Bonding Approach: Would a phased bonding structure—where the contractor is only required to bond the value of the Phase 1 effort initially, and construction bonds are deferred until the execution of Phase 2—effectively mitigate this risk? Surety Timelines: If construction bonds are deferred to Phase 2, what is the maximum duration your surety would hold a commitment open between the finalization of the GMP and the Notice to Proceed for construction? Funding Gap Mitigations: If funding for construction is delayed beyond an anticipated window (e.g., 90-180 days post-design completion), what mechanisms (e.g., formalized escalation clauses, right to off-ramp without penalty) would your firm require to maintain the agreement? Specify your maximum bonding (Single and Aggregate) as a Sole Prime Contractor and/or as a Joint Venture. SUBMISSION INSTRUCTIONS: Please email your responses in PDF format to Chris Brackett at Christopher.Brackett@usace.army.mil by 10 July 2026 at 1000 Eastern Time.","origin":"extract"},"notice_type":{"code":"r","label":"Sources Sought"},"schema_version":1,"solicitation_number":"W912QR-PDB-FortCarsonECS","place_of_performance":{"zip":"80913","city":{"name":"Colorado Springs"},"state":{"code":"CO"},"country":{"code":"USA"}}},{"dates":{"posted":"2026-06-24","response_deadline":{"raw":"2026-07-10T10:00:00-04:00","utc":"2026-07-10T14:00:00Z","date":"2026-07-10","time":"10:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/739c2a278c6148a49dd168c645c51881/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Fort Carson Equipment Concentration Site: Potential Use of Progressive Design Build using Other Transaction Authority (OTA)","agency":{"office":{"code":"W912QR","name":"W072 ENDIST LOUISVILLE"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"40202-2230","city":"LOUISVILLE","state":"KY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-07-25","archive_type":"auto15"},"contacts":[{"name":"Chris Brackett","role":"primary","email":"Christopher.brackett@usace.army.mil","phone":"5023156666"}],"base_type":{"code":"r","label":"Sources Sought"},"notice_id":"739c2a278c6148a49dd168c645c51881","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T00:55:27.040971Z","row_sha256":"9ce64174fc25ac38b8381e21428ecd7a4aa277917c713db56ceedd3ff802c9d0","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T00:55:27.040971Z","first_seen_at":"2026-09-16T00:55:27.040971Z"},"description":{"text":"REQUEST FOR INFORMATION (RFI) / MARKET RESEARCH NOTICE Notice: This is a Request for Information (RFI) for market research and for informational purposes only. This announcement does not constitute a Solicitation or a Request for Proposal (RFP), and no solicitation is currently available. Participation in this RFI is strictly voluntary. The Government will not be obligated to award any agreement or contract because of this RFI, nor will it reimburse respondents for any costs associated with the preparation or submission of information. Submitting a response will not affect a firm’s ability to submit a proposal should a formal solicitation be issued in the future. NAICS Code: 236220 – Commercial and Institutional Building Construction (Note: While Other Transaction Authority is not subject to FAR-based small business regulations, this NAICS code is provided for market research to help the Government understand the size and demographics of the interested industrial base.) Small Business Size Standard: $45 Million PROJECT OVERVIEW The U.S. Army Corps of Engineers (USACE), Louisville District, has a requirement for the design and construction of an Equipment Concentration Site (ECS) complex of facilities on Fort Carson. The scope of work consists of furnishing all necessary equipment, materials, labor, supervision, quality control, and supplies to deliver a fully functional Area Maintenance Support Activity (AMSA) shop, General Purpose Warehouse (GPW), and Organizational Storage Building. Key features of the project may include: Vehicle maintenance shop required features including but not limited to concrete shop aprons, vehicle wash rack/platform, bi-level equipment loading ramps. Specialized Systems: special building foundations, extensive pavements, improved surfaces, and the related site clearing, and excavation costs associated with developing the 48-acre parcel of land. Administrative & Support: Adjoining maintenance shops, tool rooms, administrative offices, and personnel support spaces. Military Equipment Parking lot & Site Work: Construction of paving areas for heavy equipment, POVs, security fencing, and utility tie-ins. Estimated Acquisition Magnitude: $75,000,000.00 Planned Acquisition Strategy: Progressive Design-Build (PDB) via Other Transaction Authority (OTA) The Government is considering utilizing an Other Transaction (OT) Agreement for a prototype project under the authority of 10 U.S.C. § 2808a. This authority is intended for military construction projects that involve testing and experimentation associated with new and emergent construction technologies to achieve potential benefits such as enhanced mission resilience, improved installation support, or cost and schedule reduction. The anticipated delivery method is Progressive Design-Build (PDB). Phase 1 (Design & Pre-Construction): The Government and the OT Awardee will work collaboratively to advance the design, perform constructability reviews, conduct open-book cost estimating, and mitigate project risks. Phase 2 (Construction): Upon reaching an agreed-upon level of design (e.g., 60% to 90%), the Awardee will propose a Guaranteed Maximum Price (GMP). If the GMP is accepted, the Government will exercise Phase 2 for construction execution. If a GMP cannot be agreed upon, the Government retains an \"off-ramp\" to complete the design and construct the facility via alternative methods. INFORMATION REQUESTED 1. Company Profile: Firm Name, Address, and Point of Contact (Name, Title). Phone Number, Email Address, and Unique Entity ID (UEI). Socioeconomic Status (Large, Small, 8(a), SDVOSB, etc.). 2. Other Transaction Authority (OTA) & Statutory Compliance: Innovative Technologies: The authority for this OTA (10 U.S.C. § 2808a) is focused on prototyping with new or emergent construction technologies. Describe any innovative materials, methods, or technologies your firm could propose for a project of this scale that could lead to cost savings, schedule acceleration, or enhanced facility performance and resilience. OTA Experience: Describe your firm's previous experience (if any) executing prototype projects under an OTA. Barriers to Innovation: What commercial or Government-imposed barriers currently make it difficult to propose or implement innovative construction technologies on traditional military construction projects? How could the flexibility of an OTA help overcome these barriers? What project characteristics make PDB-OTA particularly advantageous or disadvantageous for this requirement? 3. Progressive Design-Build (PDB) / Early Contractor Involvement: Baseline Definition: What minimum level of detail (e.g., Statement of Need, conceptual site plans, target budget) does your firm require prior to entering Phase 1 (Design/Pre-construction) to feel confident in the project's viability? Collaborative Framework: What collaborative mechanisms (such as joint design charrettes, target-value design workshops, or phased scoping approvals) do you recommend the Government implement in the first 30-90 days to rapidly transition from a \"blank page\" to a mutually agreed-upon baseline? Describe your experience executing Progressive Design-Build, Construction Manager at Risk (CMAR), or other highly collaborative delivery methods. How do you approach \"open-book\" pricing and transparency during Phase 1 (Pre-Construction) to build trust and ensure the Government is receiving fair market value? 4. Guaranteed Maximum Price (GMP), Risk Allocation & Compensation: Phase 1 Off-Ramp Risk: If the Government and the contractor cannot reach an agreement on the GMP or final design (the \"off-ramp\"), what specific compensation structures (e.g., stipends, time-and-materials for design effort) would adequately compensate your firm for pre-construction efforts? Payment Milestones: Because an OTA allows for flexible payment structures, what milestone payment arrangement during Phase 1 (e.g., monthly progress, completion of design percentages, deliverable-based) best supports your firm's cash flow and resource allocation? Data Rights: Under an OTA, data rights and intellectual property can be negotiated. What data rights structure for the final design deliverables (if an off-ramp is taken) would provide a fair balance between the Government's need to construct the facility and your firm's proprietary design methods? In your experience with PDB, at what design milestone (e.g., 35%, 65%, 90%) is it most advantageous to lock in the GMP for a complex aviation facility, and why? How do you handle the procurement of long-lead items (e.g., switchgear, specialized fire pumps, large span steel) prior to establishing the final GMP? What level of cost growth would you typically expect between conceptual planning and GMP establishment? 5. Industrial Maintenance & Storage Facility Construction Expertise: Describe your specific experience with large-scale heavy tactical maintenance facilities, specialized systems like tactical vehicle wash platforms, and highly specialized fire suppression systems. What are the greatest supply chain, scheduling, or technical risks you foresee for a project of this type at Fort Carson, and how would the PDB delivery method help mitigate them? Are there specific trades, materials, equipment, or subcontractor resources in the Fort Carson/Colorado Springs market that are currently constrained? Would early contractor involvement through Progressive Design-Build materially improve the Government’s ability to manage these market risks? Why or why not? 6. Teaming & Subcontractor Integration: Under a PDB model, how and when do you plan to on-board your critical subcontractors (e.g., structural steel, MEP, fire protection)? Will you compete these subcontracts openly during Phase 1, or do you prefer bringing in established partners from day one? 7. Feedback on the Acquisition Strategy & Alternatives: Does the proposed PDB-OTA strategy incentivize your firm to participate? Why or why not? Are there alternative acquisition strategies, phasing approaches, or commercial practices the Government has not considered that would yield a better facility, faster delivery, or lower cost? Have current market conditions increased the value of collaborative delivery methods compared to traditional procurement methods? If so, how? 8. Bonding Capability: Phased Bonding Approach: Would a phased bonding structure—where the contractor is only required to bond the value of the Phase 1 effort initially, and construction bonds are deferred until the execution of Phase 2—effectively mitigate this risk? Surety Timelines: If construction bonds are deferred to Phase 2, what is the maximum duration your surety would hold a commitment open between the finalization of the GMP and the Notice to Proceed for construction? Funding Gap Mitigations: If funding for construction is delayed beyond an anticipated window (e.g., 90-180 days post-design completion), what mechanisms (e.g., formalized escalation clauses, right to off-ramp without penalty) would your firm require to maintain the agreement? Specify your maximum bonding (Single and Aggregate) as a Sole Prime Contractor and/or as a Joint Venture. SUBMISSION INSTRUCTIONS: Please email your responses in PDF format to Chris Brackett at Christopher.Brackett@usace.army.mil by 10 July 2026 at 1000 Eastern Time.","origin":"extract"},"notice_type":{"code":"r","label":"Sources Sought"},"schema_version":1,"solicitation_number":"W912QR-PDB-FortCarsonECS","place_of_performance":{"zip":"80913","city":{"name":"Colorado Springs"},"state":{"code":"CO"},"country":{"code":"USA"}}},{"dates":{"posted":"2026-07-06","response_deadline":{"raw":"2026-07-10T10:00:00-04:00","utc":"2026-07-10T14:00:00Z","date":"2026-07-10","time":"10:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/f46a14d7122b431a9b7ec553eea006d9/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Sources Sought/Market Intelligence: Fort Carson Equipment Concentration Site - Potential Use of Progressive Design Build using Other Transaction Authority (OTA)","agency":{"office":{"code":"W912QR","name":"W072 ENDIST LOUISVILLE"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"40202-2230","city":"LOUISVILLE","state":"KY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-07-25","archive_type":"auto15"},"contacts":[{"name":"Chris Brackett","role":"primary","email":"Christopher.brackett@usace.army.mil","phone":"5023156666"}],"base_type":{"code":"r","label":"Sources Sought"},"notice_id":"f46a14d7122b431a9b7ec553eea006d9","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T00:55:27.040971Z","row_sha256":"01f4731191af2fbbb8acadf2759e2618042248c9247833a4ea248c1111f2c8ca","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T00:55:27.040971Z","first_seen_at":"2026-09-16T00:55:27.040971Z"},"description":{"text":"REQUEST FOR INFORMATION (RFI) / MARKET INTELLIGENCE NOTICE Notice: This is a Request for Information (RFI) for market intelligence and for informational purposes only. This announcement does not constitute a Solicitation or a Request for Proposal (RFP), and no solicitation is currently available. Participation in this RFI is strictly voluntary. The Government will not be obligated to award any agreement or contract because of this RFI, nor will it reimburse respondents for any costs associated with the preparation or submission of information. Submitting a response will not affect a firm’s ability to submit a proposal should a formal solicitation be issued in the future. NAICS Code: 236220 – Commercial and Institutional Building Construction (Note: While Other Transaction Authority is not subject to FAR-based small business regulations, this NAICS code is provided for market research to help the Government understand the size and demographics of the interested industrial base.) Small Business Size Standard: $45 Million PROJECT OVERVIEW The U.S. Army Corps of Engineers (USACE), Louisville District, has a requirement for the design and construction of an Equipment Concentration Site (ECS) complex of facilities on Fort Carson. The scope of work consists of furnishing all necessary equipment, materials, labor, supervision, quality control, and supplies to deliver a fully functional Area Maintenance Support Activity (AMSA) shop, General Purpose Warehouse (GPW), and Organizational Storage Building. Key features of the project may include: Vehicle maintenance shop required features including but not limited to concrete shop aprons, vehicle wash rack/platform, bi-level equipment loading ramps. Specialized Systems: special building foundations, extensive pavements, improved surfaces, and the related site clearing, and excavation costs associated with developing the 48-acre parcel of land. Administrative & Support: Adjoining maintenance shops, tool rooms, administrative offices, and personnel support spaces. Military Equipment Parking lot & Site Work: Construction of paving areas for heavy equipment, POVs, security fencing, and utility tie-ins. Estimated Acquisition Magnitude: $75,000,000.00 Planned Acquisition Strategy: Progressive Design-Build (PDB) via Other Transaction Authority (OTA) The Louisville District is conducting market intelligence to assess industry capability and interest in supporting this effort utilizing an Other Transaction (OT) Agreement under the authority of 10 U.S.C. § 2808a, Facility Construction or Repair: Transactions Other Than Contracts and Grants. This authority is distinct from the Department of Defense protptype OT authorities commonly associated with 10 U.S.C. § 4021 and 4022. This authority is intended for military construction projects that involve testing and experimentation associated with new and emergent construction technologies to achieve potential benefits such as enhanced mission resilience, improved installation support, or cost and schedule reduction. The anticipated delivery method is Progressive Design-Build (PDB). Phase 1 (Design & Pre-Construction): The Government and the OT Awardee will work collaboratively to advance the design, perform constructability reviews, conduct open-book cost estimating, and mitigate project risks. Phase 2 (Construction): Upon reaching an agreed-upon level of design (e.g., 60% to 90%), the Awardee will propose a Guaranteed Maximum Price (GMP). If the GMP is accepted, the Government will exercise Phase 2 for construction execution. If a GMP cannot be agreed upon, the Government retains an \"off-ramp\" to complete the design and construct the facility via alternative methods. INFORMATION REQUESTED 1. Company Profile: Firm Name, Address, and Point of Contact (Name, Title). Phone Number, Email Address, and Unique Entity ID (UEI). Socioeconomic Status (Large, Small, 8(a), SDVOSB, etc.). 2. Other Transaction Authority (OTA) & Statutory Compliance: Innovative Technologies: The authority for this OTA (10 U.S.C. § 2808a) is focused pecifically designed to bring the fast-paced, iterative, and flexible principles of Other Transaction Authority (OTA), which traditionally governs research and technology prototyping, into the physical infrastructure and military construction (MILCON) domain. Describe any innovative materials, methods, or technologies your firm could propose for a project of this scale that could lead to cost savings, schedule acceleration, or enhanced facility performance and resilience. OTA Experience: Describe your firm's previous experience (if any) executing prototype projects under an OTA. Barriers to Innovation: What commercial or Government-imposed barriers currently make it difficult to propose or implement innovative construction technologies on traditional military construction projects? How could the flexibility of an OTA help overcome these barriers? What project characteristics make PDB-OTA particularly advantageous or disadvantageous for this requirement? 3. Progressive Design-Build (PDB) / Early Contractor Involvement: Baseline Definition: What minimum level of detail (e.g., Statement of Need, conceptual site plans, target budget) does your firm require prior to entering Phase 1 (Design/Pre-construction) to feel confident in the project's viability? Collaborative Framework: What collaborative mechanisms (such as joint design charrettes, target-value design workshops, or phased scoping approvals) do you recommend the Government implement in the first 30-90 days to rapidly transition from a \"blank page\" to a mutually agreed-upon baseline? Describe your experience executing Progressive Design-Build, Construction Manager at Risk (CMAR), or other highly collaborative delivery methods. How do you approach \"open-book\" pricing and transparency during Phase 1 (Pre-Construction) to build trust and ensure the Government is receiving fair market value? 4. Guaranteed Maximum Price (GMP), Risk Allocation & Compensation: Phase 1 Off-Ramp Risk: If the Government and the contractor cannot reach an agreement on the GMP or final design (the \"off-ramp\"), what specific compensation structures (e.g., stipends, time-and-materials for design effort) would adequately compensate your firm for pre-construction efforts? Payment Milestones: Because an OTA allows for flexible payment structures, what milestone payment arrangement during Phase 1 (e.g., monthly progress, completion of design percentages, deliverable-based) best supports your firm's cash flow and resource allocation? Data Rights: Under an OTA, data rights and intellectual property can be negotiated. What data rights structure for the final design deliverables (if an off-ramp is taken) would provide a fair balance between the Government's need to construct the facility and your firm's proprietary design methods? In your experience with PDB, at what design milestone (e.g., 35%, 65%, 90%) is it most advantageous to lock in the GMP for a complex aviation facility, and why? How do you handle the procurement of long-lead items (e.g., switchgear, specialized fire pumps, large span steel) prior to establishing the final GMP? What level of cost growth would you typically expect between conceptual planning and GMP establishment? 5. Industrial Maintenance & Storage Facility Construction Expertise: Describe your specific experience with large-scale heavy tactical maintenance facilities, specialized systems like tactical vehicle wash platforms, and highly specialized fire suppression systems. What are the greatest supply chain, scheduling, or technical risks you foresee for a project of this type at Fort Carson, and how would the PDB delivery method help mitigate them? Are there specific trades, materials, equipment, or subcontractor resources in the Fort Carson/Colorado Springs market that are currently constrained? Would early contractor involvement through Progressive Design-Build materially improve the Government’s ability to manage these market risks? Why or why not? 6. Teaming & Subcontractor Integration: Under a PDB model, how and when do you plan to on-board your critical subcontractors (e.g., structural steel, MEP, fire protection)? Will you compete these subcontracts openly during Phase 1, or do you prefer bringing in established partners from day one? 7. Feedback on the Acquisition Strategy & Alternatives: Does the proposed PDB-OTA strategy incentivize your firm to participate? Why or why not? Are there alternative acquisition strategies, phasing approaches, or commercial practices the Government has not considered that would yield a better facility, faster delivery, or lower cost? Have current market conditions increased the value of collaborative delivery methods compared to traditional procurement methods? If so, how? 8. Bonding Capability: Phased Bonding Approach: Would a phased bonding structure—where the contractor is only required to bond the value of the Phase 1 effort initially, and construction bonds are deferred until the execution of Phase 2—effectively mitigate this risk? Surety Timelines: If construction bonds are deferred to Phase 2, what is the maximum duration your surety would hold a commitment open between the finalization of the GMP and the Notice to Proceed for construction? Funding Gap Mitigations: If funding for construction is delayed beyond an anticipated window (e.g., 90-180 days post-design completion), what mechanisms (e.g., formalized escalation clauses, right to off-ramp without penalty) would your firm require to maintain the agreement? Specify your maximum bonding (Single and Aggregate) as a Sole Prime Contractor and/or as a Joint Venture. SUBMISSION INSTRUCTIONS: Please email your responses in PDF format to Chris Brackett at Christopher.Brackett@usace.army.mil by 10 July 2026 at 1000 Eastern Time.","origin":"extract"},"notice_type":{"code":"r","label":"Sources Sought"},"schema_version":1,"solicitation_number":"W912QR-PDB-FortCarsonECS","place_of_performance":{"zip":"80913","city":{"name":"Colorado Springs"},"state":{"code":"CO"},"country":{"code":"USA"}}},{"dates":{"posted":"2026-07-29","response_deadline":{"raw":"2026-08-07T10:00:00-04:00","utc":"2026-08-07T14:00:00Z","date":"2026-08-07","time":"10:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/4486a70e667e4326bd32b18ce897a1b3/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Sources Sought/Market Intelligence: Fort Carson Equipment Concentration Site - Potential Use of Progressive Design Build using Other Transaction Authority (OTA)","agency":{"office":{"code":"W912QR","name":"W072 ENDIST LOUISVILLE"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"40202-2230","city":"LOUISVILLE","state":"KY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-08-22","archive_type":"auto15"},"contacts":[{"name":"Chris Brackett","role":"primary","email":"Christopher.brackett@usace.army.mil","phone":"5023156666"}],"base_type":{"code":"r","label":"Sources Sought"},"notice_id":"4486a70e667e4326bd32b18ce897a1b3","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T00:55:27.040971Z","row_sha256":"9c64c739790e92521e47f2e0b6bcf9eadb7bd4602127d4cb47118c5a8edb5471","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T00:55:27.040971Z","first_seen_at":"2026-09-16T00:55:27.040971Z"},"description":{"text":"REQUEST FOR INFORMATION (RFI) / MARKET INTELLIGENCE NOTICE Notice: This is a Request for Information (RFI) for market intelligence and for informational purposes only. This announcement does not constitute a Solicitation or a Request for Proposal (RFP), and no solicitation is currently available. Participation in this RFI is strictly voluntary. The Government will not be obligated to award any agreement or contract because of this RFI, nor will it reimburse respondents for any costs associated with the preparation or submission of information. Submitting a response will not affect a firm’s ability to submit a proposal should a formal solicitation be issued in the future. NAICS Code: 236220 – Commercial and Institutional Building Construction (Note: While Other Transaction Authority is not subject to FAR-based small business regulations, this NAICS code is provided for market research to help the Government understand the size and demographics of the interested industrial base.) Small Business Size Standard: $45 Million PROJECT OVERVIEW The U.S. Army Corps of Engineers (USACE), Louisville District, has a requirement for the design and construction of an Equipment Concentration Site (ECS) complex of facilities on Fort Carson. The scope of work consists of furnishing all necessary equipment, materials, labor, supervision, quality control, and supplies to deliver a fully functional Area Maintenance Support Activity (AMSA) shop, General Purpose Warehouse (GPW), and Organizational Storage Building. Key features of the project may include: Vehicle maintenance shop required features including but not limited to concrete shop aprons, vehicle wash rack/platform, bi-level equipment loading ramps. Specialized Systems: special building foundations, extensive pavements, improved surfaces, and the related site clearing, and excavation costs associated with developing the 48-acre parcel of land. Administrative & Support: Adjoining maintenance shops, tool rooms, administrative offices, and personnel support spaces. Military Equipment Parking lot & Site Work: Construction of paving areas for heavy equipment, POVs, security fencing, and utility tie-ins. Estimated Acquisition Magnitude: $75,000,000.00 Planned Acquisition Strategy: Progressive Design-Build (PDB) via Other Transaction Authority (OTA) The Louisville District is conducting market intelligence to assess industry capability and interest in supporting this effort utilizing an Other Transaction (OT) Agreement under the authority of 10 U.S.C. § 2808a, Facility Construction or Repair: Transactions Other Than Contracts and Grants. This authority is distinct from the Department of Defense protptype OT authorities commonly associated with 10 U.S.C. § 4021 and 4022. This authority is intended for military construction projects that involve testing and experimentation associated with new and emergent construction technologies to achieve potential benefits such as enhanced mission resilience, improved installation support, or cost and schedule reduction. The anticipated delivery method is Progressive Design-Build (PDB). Phase 1 (Design & Pre-Construction): The Government and the OT Awardee will work collaboratively to advance the design, perform constructability reviews, conduct open-book cost estimating, and mitigate project risks. Phase 2 (Construction): Upon reaching an agreed-upon level of design (e.g., 60% to 90%), the Awardee will propose a Guaranteed Maximum Price (GMP). If the GMP is accepted, the Government will exercise Phase 2 for construction execution. If a GMP cannot be agreed upon, the Government retains an \"off-ramp\" to complete the design and construct the facility via alternative methods. INFORMATION REQUESTED 1. Company Profile: Firm Name, Address, and Point of Contact (Name, Title). Phone Number, Email Address, and Unique Entity ID (UEI). Socioeconomic Status (Large, Small, 8(a), SDVOSB, etc.). 2. Other Transaction Authority (OTA) & Statutory Compliance: Innovative Technologies: The authority for this OTA (10 U.S.C. § 2808a) is focused pecifically designed to bring the fast-paced, iterative, and flexible principles of Other Transaction Authority (OTA), which traditionally governs research and technology prototyping, into the physical infrastructure and military construction (MILCON) domain. Describe any innovative materials, methods, or technologies your firm could propose for a project of this scale that could lead to cost savings, schedule acceleration, or enhanced facility performance and resilience. OTA Experience: Describe your firm's previous experience (if any) executing prototype projects under an OTA. Barriers to Innovation: What commercial or Government-imposed barriers currently make it difficult to propose or implement innovative construction technologies on traditional military construction projects? How could the flexibility of an OTA help overcome these barriers? What project characteristics make PDB-OTA particularly advantageous or disadvantageous for this requirement? 3. Progressive Design-Build (PDB) / Early Contractor Involvement: Baseline Definition: What minimum level of detail (e.g., Statement of Need, conceptual site plans, target budget) does your firm require prior to entering Phase 1 (Design/Pre-construction) to feel confident in the project's viability? Collaborative Framework: What collaborative mechanisms (such as joint design charrettes, target-value design workshops, or phased scoping approvals) do you recommend the Government implement in the first 30-90 days to rapidly transition from a \"blank page\" to a mutually agreed-upon baseline? Describe your experience executing Progressive Design-Build, Construction Manager at Risk (CMAR), or other highly collaborative delivery methods. How do you approach \"open-book\" pricing and transparency during Phase 1 (Pre-Construction) to build trust and ensure the Government is receiving fair market value? 4. Guaranteed Maximum Price (GMP), Risk Allocation & Compensation: Phase 1 Off-Ramp Risk: If the Government and the contractor cannot reach an agreement on the GMP or final design (the \"off-ramp\"), what specific compensation structures (e.g., stipends, time-and-materials for design effort) would adequately compensate your firm for pre-construction efforts? Payment Milestones: Because an OTA allows for flexible payment structures, what milestone payment arrangement during Phase 1 (e.g., monthly progress, completion of design percentages, deliverable-based) best supports your firm's cash flow and resource allocation? Data Rights: Under an OTA, data rights and intellectual property can be negotiated. What data rights structure for the final design deliverables (if an off-ramp is taken) would provide a fair balance between the Government's need to construct the facility and your firm's proprietary design methods? In your experience with PDB, at what design milestone (e.g., 35%, 65%, 90%) is it most advantageous to lock in the GMP for a complex aviation facility, and why? How do you handle the procurement of long-lead items (e.g., switchgear, specialized fire pumps, large span steel) prior to establishing the final GMP? What level of cost growth would you typically expect between conceptual planning and GMP establishment? 5. Industrial Maintenance & Storage Facility Construction Expertise: Describe your specific experience with large-scale heavy tactical maintenance facilities, specialized systems like tactical vehicle wash platforms, and highly specialized fire suppression systems. What are the greatest supply chain, scheduling, or technical risks you foresee for a project of this type at Fort Carson, and how would the PDB delivery method help mitigate them? Are there specific trades, materials, equipment, or subcontractor resources in the Fort Carson/Colorado Springs market that are currently constrained? Would early contractor involvement through Progressive Design-Build materially improve the Government’s ability to manage these market risks? Why or why not? 6. Teaming & Subcontractor Integration: Under a PDB model, how and when do you plan to on-board your critical subcontractors (e.g., structural steel, MEP, fire protection)? Will you compete these subcontracts openly during Phase 1, or do you prefer bringing in established partners from day one? 7. Feedback on the Acquisition Strategy & Alternatives: Does the proposed PDB-OTA strategy incentivize your firm to participate? Why or why not? Are there alternative acquisition strategies, phasing approaches, or commercial practices the Government has not considered that would yield a better facility, faster delivery, or lower cost? Have current market conditions increased the value of collaborative delivery methods compared to traditional procurement methods? If so, how? 8. Bonding Capability: Phased Bonding Approach: Would a phased bonding structure—where the contractor is only required to bond the value of the Phase 1 effort initially, and construction bonds are deferred until the execution of Phase 2—effectively mitigate this risk? Surety Timelines: If construction bonds are deferred to Phase 2, what is the maximum duration your surety would hold a commitment open between the finalization of the GMP and the Notice to Proceed for construction? Funding Gap Mitigations: If funding for construction is delayed beyond an anticipated window (e.g., 90-180 days post-design completion), what mechanisms (e.g., formalized escalation clauses, right to off-ramp without penalty) would your firm require to maintain the agreement? Specify your maximum bonding (Single and Aggregate) as a Sole Prime Contractor and/or as a Joint Venture. SUBMISSION INSTRUCTIONS: Please email your responses in PDF format to Chris Brackett at Christopher.Brackett@usace.army.mil by 10 July 2026 at 1000 Eastern Time.","origin":"extract"},"notice_type":{"code":"r","label":"Sources Sought"},"schema_version":1,"solicitation_number":"W912QR-PDB-FortCarsonECS","place_of_performance":{"zip":"80913","city":{"name":"Colorado Springs"},"state":{"code":"CO"},"country":{"code":"USA"}}},{"dates":{"posted":"2026-07-29","response_deadline":{"raw":"2026-08-07T10:00:00-04:00","utc":"2026-08-07T14:00:00Z","date":"2026-08-07","time":"10:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/474e35f26f0e4581a0cde73f9e6592b5/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Sources Sought/Market Intelligence: Fort Carson Equipment Concentration Site - Potential Use of Construction Management at Risk using Other Transaction Authority (OTA)","agency":{"office":{"code":"W912QR","name":"W072 ENDIST LOUISVILLE"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"40202-2230","city":"LOUISVILLE","state":"KY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-08-22","archive_type":"auto15"},"contacts":[{"name":"Chris Brackett","role":"primary","email":"Christopher.brackett@usace.army.mil","phone":"5023156666"}],"base_type":{"code":"r","label":"Sources Sought"},"notice_id":"474e35f26f0e4581a0cde73f9e6592b5","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T00:55:27.040971Z","row_sha256":"0bdccb45237ee18a3c275f569be0a19ee289572e9c3692a86424297c96d6cdfc","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T00:55:27.040971Z","first_seen_at":"2026-09-16T00:55:27.040971Z"},"description":{"text":"REQUEST FOR INFORMATION (RFI) / MARKET INTELLIGENCE NOTICE Notice: This is a Request for Information (RFI) for market intelligence and for informational purposes only. This announcement does not constitute a Solicitation or a Request for Proposal (RFP), and no solicitation is currently available. Participation in this RFI is strictly voluntary. The Government will not be obligated to award any agreement or contract because of this RFI, nor will it reimburse respondents for any costs associated with the preparation or submission of information. Submitting a response will not affect a firm’s ability to submit a proposal should a formal solicitation be issued in the future. (Note: While Other Transaction Authority is not subject to FAR-based small business regulations, this NAICS code is provided for market research to help the Government understand the size and demographics of the interested industrial base. Small Business Size Standard: $45 Million) PROJECT OVERVIEW The U.S. Army Corps of Engineers (USACE), Louisville District, has a requirement for the design and construction of an Equipment Concentration Site (ECS) complex of facilities on Fort Carson. The scope of work consists of furnishing all necessary equipment, materials, labor, supervision, quality control, and supplies to deliver a fully functional Area Maintenance Support Activity (AMSA) shop, General Purpose Warehouse (GPW), and Organizational Storage Building. Key features of the project may include: Vehicle maintenance shop: required features including but not limited to concrete shop aprons, vehicle wash rack/platform, bi-level equipment loading ramps. Specialized Systems: special building foundations, extensive pavements, improved surfaces, and the related site clearing, and excavation costs associated with developing the 48-acre parcel of land. Administrative & Support: Adjoining maintenance shops, tool rooms, administrative offices, and personnel support spaces. Military Equipment Parking lot & Site Work: Construction of paving areas for heavy equipment, POVs, security fencing, and utility tie-ins. Estimated Acquisition Magnitude: $75,000,000.00 PLANNED ACQUISITION STRATEGY: CM@Risk via Other Transaction Authority (OTA) The Louisville District previously issued this RFI exploring a Progressive Design-Build (PDB) using Other Transaction Authority strategy. Based on recent project developments, the Government has advanced the design to approximately 35% and intends to progress to full design. The Government is now updating this market intelligence to assess industry capability and interest in utilizing Construction Management at Risk (CM@Risk) utilizing an Other Transaction (OT) Agreement under the authority of 10 U.S.C. § 2808a. This Course of Action utilizes the 10 U.S.C. § 2808a OT authority to execute a construction project where the design is at/near 95% completion. The builder is hired during Phase 1 to act as an expert consultant, helping the Designer of Record (DOR) push the design from 95% to 100% using real-time market data and MII (MCACES 2nd Generation) cost comparisons. Once the design hits 100% and the MII estimate validates the open-book pricing, the agreement transitions to Phase 2, where the builder goes \"At-Risk\" to construct the facility under a Guaranteed Maximum Price (GMP). The DOR retains design liability, but the contractor drives constructability and assumes responsibility for layout, schedule, and trade coordination. The Pricing Structure: Pre-Con Fee + Target Fee & GMP Preconstruction Services Fee: A small, fixed-price or time-and-materials amount paid to the contractor strictly to fund their time spent helping the A/E finalize the 95% design into a 100% design. The Target Fee: The contractor’s transparent profit margin for managing the actual construction, bid competitively upfront. The GMP: The absolute ceiling for the construction phase (Validated Direct Costs + Target Fee + Shared Contingency). PHASED EXECUTION PLAN Phase 1: Preconstruction Services Agreement (CM@Risk Advisory) Solicitation (White Papers): The Solicitation would likely include the 95% design. The Deliverable is anticipated to be a concise 5-to-10 page White Paper. Evaluation Criteria will likely include Corporate capability and CM@Risk past performance; preconstruction approach (how the firm plans to collaborate with the Government's A/E to close the remaining 5% design gap, identify value-engineering opportunities, and mitigate supply-chain risks); proposed Target Fee (for construction) and Preconstruction Services Fee. The Pitch Meeting (Oral Presentations): A 90-minute pitch where the contractor must bring their Project Manager, Site Superintendent, and their Preconstruction Manager. The Government team assesses how well the contractor's team will integrate with the A/E during the critical final design push. The OT is initially awarded and funded only for the Preconstruction Services Fee. Design Finalization (Bridging the 5% Gap): The contractor’s Preconstruction team sits with the Government and the DOR. Because the design is not locked, they can actively change it. They perform value engineering, finalize equipment selections, and ensure the drawings are 100% constructible. Open Book Pricing vs. MII: As the design reaches 100%, the contractor conducts open-book market outreach. The Government and contractor review actual sub-bids together. USACE cost estimators finalize the Independent Government Estimate (IGE) using the MII software to validate costs and establish the GMP base. Phase 2: Construction Execution Agreement (Going \"At-Risk\") Execution: The Agreements Officer (AO) executes a bilateral modification to the OT Agreement, incorporating the GMP and funding the physical construction. Risk Allocation: Under CM@Risk, the contractor is now \"At-Risk.\" While the DOR still owns fundamental engineering failures, the contractor loses the ability to claim \"defective design\" for constructability issues, material delays, or coordination errors, because they were explicitly paid to help finalize those exact decisions using market and MII data during Phase 1. INFORMATION REQUESTED 1. Company Profile: Firm Name, Address, and Point of Contact (Name, Title). Phone Number, Email Address, and Unique Entity ID (UEI). Socioeconomic Status (Large, Small, 8(a), SDVOSB, etc.). 2. Other Transaction Authority (OTA) & Statutory Compliance: Innovative Technologies: Describe any innovative materials, methods, or technologies your firm could propose for a project of this scale that could lead to cost savings, schedule acceleration, or enhanced facility performance and resilience. Barriers to Innovation: What commercial or Government-imposed barriers currently make it difficult to propose or implement innovative construction technologies? How could the flexibility of an OTA help overcome these barriers? 3. CM@Risk & Design-Assist Involvement: 95% Design Entry: The Government plans to bring the CM@Risk contractor on board when the design is at 95%. Based on your experience, is a 5% design gap sufficient to add meaningful constructability and value-engineering input, or are the most critical decisions already locked in?[MH1] Collaborative Framework: What collaborative mechanisms do you recommend the Government implement to rapidly close the 5% design gap and transition to a validated GMP? Describe your experience executing Construction Manager at Risk (CMAR) or other highly collaborative delivery methods, particularly where you served as an advisor before going \"at-risk\". 4. Guaranteed Maximum Price (GMP), Risk Allocation & Compensation: Preconstruction Compensation: What specific compensation structures (e.g., fixed stipends, time-and-materials) would best compensate your firm for the pre-construction effort and design-assist phase? Open Book Pricing: How do you approach \"open-book\" pricing and transparency during Phase 1 to build trust and ensure the Government is receiving fair market value before locking in the GMP? Long-Lead Items: How do you handle the procurement of long-lead items (e.g., switchgear, specialized fire pumps, large span steel) if they must be ordered prior to the finalization of the 100% design and GMP? Phase 1 Off-Ramp Risk: If the Government and the contractor cannot reach an agreement on the final GMP, what specific off-ramp conditions are critical to your firm? 5. Industrial Maintenance & Storage Facility Construction Expertise: Describe your specific experience with large-scale heavy tactical maintenance facilities, specialized systems like tactical vehicle wash platforms, and highly specialized fire suppression systems. What are the greatest supply chain, scheduling, or technical risks you foresee for a project of this type at Fort Carson, and how would this CM@Risk delivery method help mitigate them? 6. Teaming & Subcontractor Integration: Under a CM@Risk model starting at a 95% design, how and when do you plan to on-board your critical subcontractors (e.g., structural steel, MEP, fire protection)? Will you compete these subcontracts openly during Phase 1 to build the open-book GMP, or do you prefer bringing in established partners from day one? 7. Feedback on the Acquisition Strategy & Alternatives: Does the proposed CM@Risk-OTA strategy incentivize your firm to participate? Why or why not? Are there alternative acquisition strategies, phasing approaches, or commercial practices the Government has not considered that would yield a better facility, faster delivery, or lower cost? 8. Bonding Capability: Specify your maximum bonding (Single and Aggregate) as a Sole Prime Contractor and/or as a Joint Venture. SUBMISSION INSTRUCTIONS Please email your responses in PDF format to Chris Brackett at Christopher.Brackett@usace.army.mil by 07 August 2026 at 1000 Eastern Time. [MH1]This is my biggest sticking point. I’ll be curious as to Industry feedback on this and if they feel taking the at risk for only providing input at the final 5% design stage is going to be enough to go in on an agreement.","origin":"extract"},"notice_type":{"code":"r","label":"Sources Sought"},"schema_version":1,"solicitation_number":"W912QR-PDB-FortCarsonECS","place_of_performance":{"zip":"80913","city":{"name":"Colorado Springs"},"state":{"code":"CO"},"country":{"code":"USA"}}}],"due_at":"2026-08-07T14:00:00Z","due_date":"2026-08-07","closes_at":"2026-08-07T14:00:00Z","awardable":true,"dept_key":"d-021","dept_name":"DEPT OF DEFENSE","sub_key":"s-2100","sub_name":"DEPT OF THE ARMY","office_key":"o-W912QR","office_name":"W072 ENDIST LOUISVILLE","state":"CO","country":"USA","winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T07:31:38.954589Z","principal_notice_id":"474e35f26f0e4581a0cde73f9e6592b5","description":{"text":"REQUEST FOR INFORMATION (RFI) / MARKET INTELLIGENCE NOTICE Notice: This is a Request for Information (RFI) for market intelligence and for informational purposes only. This announcement does not constitute a Solicitation or a Request for Proposal (RFP), and no solicitation is currently available. Participation in this RFI is strictly voluntary. The Government will not be obligated to award any agreement or contract because of this RFI, nor will it reimburse respondents for any costs associated with the preparation or submission of information. Submitting a response will not affect a firm’s ability to submit a proposal should a formal solicitation be issued in the future. (Note: While Other Transaction Authority is not subject to FAR-based small business regulations, this NAICS code is provided for market research to help the Government understand the size and demographics of the interested industrial base. Small Business Size Standard: $45 Million) PROJECT OVERVIEW The U.S. Army Corps of Engineers (USACE), Louisville District, has a requirement for the design and construction of an Equipment Concentration Site (ECS) complex of facilities on Fort Carson. The scope of work consists of furnishing all necessary equipment, materials, labor, supervision, quality control, and supplies to deliver a fully functional Area Maintenance Support Activity (AMSA) shop, General Purpose Warehouse (GPW), and Organizational Storage Building. Key features of the project may include: Vehicle maintenance shop: required features including but not limited to concrete shop aprons, vehicle wash rack/platform, bi-level equipment loading ramps. Specialized Systems: special building foundations, extensive pavements, improved surfaces, and the related site clearing, and excavation costs associated with developing the 48-acre parcel of land. Administrative & Support: Adjoining maintenance shops, tool rooms, administrative offices, and personnel support spaces. Military Equipment Parking lot & Site Work: Construction of paving areas for heavy equipment, POVs, security fencing, and utility tie-ins. Estimated Acquisition Magnitude: $75,000,000.00 PLANNED ACQUISITION STRATEGY: CM@Risk via Other Transaction Authority (OTA) The Louisville District previously issued this RFI exploring a Progressive Design-Build (PDB) using Other Transaction Authority strategy. Based on recent project developments, the Government has advanced the design to approximately 35% and intends to progress to full design. The Government is now updating this market intelligence to assess industry capability and interest in utilizing Construction Management at Risk (CM@Risk) utilizing an Other Transaction (OT) Agreement under the authority of 10 U.S.C. § 2808a. This Course of Action utilizes the 10 U.S.C. § 2808a OT authority to execute a construction project where the design is at/near 95% completion. The builder is hired during Phase 1 to act as an expert consultant, helping the Designer of Record (DOR) push the design from 95% to 100% using real-time market data and MII (MCACES 2nd Generation) cost comparisons. Once the design hits 100% and the MII estimate validates the open-book pricing, the agreement transitions to Phase 2, where the builder goes \"At-Risk\" to construct the facility under a Guaranteed Maximum Price (GMP). The DOR retains design liability, but the contractor drives constructability and assumes responsibility for layout, schedule, and trade coordination. The Pricing Structure: Pre-Con Fee + Target Fee & GMP Preconstruction Services Fee: A small, fixed-price or time-and-materials amount paid to the contractor strictly to fund their time spent helping the A/E finalize the 95% design into a 100% design. The Target Fee: The contractor’s transparent profit margin for managing the actual construction, bid competitively upfront. The GMP: The absolute ceiling for the construction phase (Validated Direct Costs + Target Fee + Shared Contingency). PHASED EXECUTION PLAN Phase 1: Preconstruction Services Agreement (CM@Risk Advisory) Solicitation (White Papers): The Solicitation would likely include the 95% design. The Deliverable is anticipated to be a concise 5-to-10 page White Paper. Evaluation Criteria will likely include Corporate capability and CM@Risk past performance; preconstruction approach (how the firm plans to collaborate with the Government's A/E to close the remaining 5% design gap, identify value-engineering opportunities, and mitigate supply-chain risks); proposed Target Fee (for construction) and Preconstruction Services Fee. The Pitch Meeting (Oral Presentations): A 90-minute pitch where the contractor must bring their Project Manager, Site Superintendent, and their Preconstruction Manager. The Government team assesses how well the contractor's team will integrate with the A/E during the critical final design push. The OT is initially awarded and funded only for the Preconstruction Services Fee. Design Finalization (Bridging the 5% Gap): The contractor’s Preconstruction team sits with the Government and the DOR. Because the design is not locked, they can actively change it. They perform value engineering, finalize equipment selections, and ensure the drawings are 100% constructible. Open Book Pricing vs. MII: As the design reaches 100%, the contractor conducts open-book market outreach. The Government and contractor review actual sub-bids together. USACE cost estimators finalize the Independent Government Estimate (IGE) using the MII software to validate costs and establish the GMP base. Phase 2: Construction Execution Agreement (Going \"At-Risk\") Execution: The Agreements Officer (AO) executes a bilateral modification to the OT Agreement, incorporating the GMP and funding the physical construction. Risk Allocation: Under CM@Risk, the contractor is now \"At-Risk.\" While the DOR still owns fundamental engineering failures, the contractor loses the ability to claim \"defective design\" for constructability issues, material delays, or coordination errors, because they were explicitly paid to help finalize those exact decisions using market and MII data during Phase 1. INFORMATION REQUESTED 1. Company Profile: Firm Name, Address, and Point of Contact (Name, Title). Phone Number, Email Address, and Unique Entity ID (UEI). Socioeconomic Status (Large, Small, 8(a), SDVOSB, etc.). 2. Other Transaction Authority (OTA) & Statutory Compliance: Innovative Technologies: Describe any innovative materials, methods, or technologies your firm could propose for a project of this scale that could lead to cost savings, schedule acceleration, or enhanced facility performance and resilience. Barriers to Innovation: What commercial or Government-imposed barriers currently make it difficult to propose or implement innovative construction technologies? How could the flexibility of an OTA help overcome these barriers? 3. CM@Risk & Design-Assist Involvement: 95% Design Entry: The Government plans to bring the CM@Risk contractor on board when the design is at 95%. Based on your experience, is a 5% design gap sufficient to add meaningful constructability and value-engineering input, or are the most critical decisions already locked in?[MH1] Collaborative Framework: What collaborative mechanisms do you recommend the Government implement to rapidly close the 5% design gap and transition to a validated GMP? Describe your experience executing Construction Manager at Risk (CMAR) or other highly collaborative delivery methods, particularly where you served as an advisor before going \"at-risk\". 4. Guaranteed Maximum Price (GMP), Risk Allocation & Compensation: Preconstruction Compensation: What specific compensation structures (e.g., fixed stipends, time-and-materials) would best compensate your firm for the pre-construction effort and design-assist phase? Open Book Pricing: How do you approach \"open-book\" pricing and transparency during Phase 1 to build trust and ensure the Government is receiving fair market value before locking in the GMP? Long-Lead Items: How do you handle the procurement of long-lead items (e.g., switchgear, specialized fire pumps, large span steel) if they must be ordered prior to the finalization of the 100% design and GMP? Phase 1 Off-Ramp Risk: If the Government and the contractor cannot reach an agreement on the final GMP, what specific off-ramp conditions are critical to your firm? 5. Industrial Maintenance & Storage Facility Construction Expertise: Describe your specific experience with large-scale heavy tactical maintenance facilities, specialized systems like tactical vehicle wash platforms, and highly specialized fire suppression systems. What are the greatest supply chain, scheduling, or technical risks you foresee for a project of this type at Fort Carson, and how would this CM@Risk delivery method help mitigate them? 6. Teaming & Subcontractor Integration: Under a CM@Risk model starting at a 95% design, how and when do you plan to on-board your critical subcontractors (e.g., structural steel, MEP, fire protection)? Will you compete these subcontracts openly during Phase 1 to build the open-book GMP, or do you prefer bringing in established partners from day one? 7. Feedback on the Acquisition Strategy & Alternatives: Does the proposed CM@Risk-OTA strategy incentivize your firm to participate? Why or why not? Are there alternative acquisition strategies, phasing approaches, or commercial practices the Government has not considered that would yield a better facility, faster delivery, or lower cost? 8. Bonding Capability: Specify your maximum bonding (Single and Aggregate) as a Sole Prime Contractor and/or as a Joint Venture. SUBMISSION INSTRUCTIONS Please email your responses in PDF format to Chris Brackett at Christopher.Brackett@usace.army.mil by 07 August 2026 at 1000 Eastern Time. [MH1]This is my biggest sticking point. I’ll be curious as to Industry feedback on this and if they feel taking the at risk for only providing input at the final 5% design stage is going to be enough to go in on an agreement.","html":null,"origin":"extract"},"contacts":[{"name":"Chris Brackett","role":"primary","email":"Christopher.brackett@usace.army.mil","phone":"5023156666"}],"place_of_performance":{"zip":"80913","city":{"name":"Colorado Springs"},"state":{"code":"CO"},"country":{"code":"USA"}},"office_address":{"zip":"40202-2230","city":"LOUISVILLE","state":"KY","country":"USA"},"naics_codes":["236220"],"award":null,"attachments":[],"awards":[],"related":[{"key":"W912QR26QA098","latest_notice_id":"330286878dc745e79c9a45632ff95ba3","title":"Caesar Creek Lake Overhead Crane Wheel Bearing Repair and Replace","solicitation_number":"W912QR26QA098","notice_type":"o","first_type":"o","first_posted":"2026-08-25","last_posted":"2026-09-09","notices":2,"due_at":"2026-09-17T06:00:00Z","due_date":"2026-09-17","closes_at":"2026-09-17T06:00:00Z","awardable":true,"open":true,"dept_key":"d-021","dept_name":"DEPT OF DEFENSE","sub_key":"s-2100","sub_name":"DEPT OF THE ARMY","office_key":"o-W912QR","office_name":"W072 ENDIST LOUISVILLE","naics":"811310","psc":"M1KA","set_aside":null,"state":null,"country":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T07:31:38.954589Z"},{"key":"W912QR26QA106","latest_notice_id":"6ef37acfd1a049a39b0fd532bbc3d67e","title":"Brookville Lake Dam Road Crack Fill and Seal","solicitation_number":"W912QR26QA106","notice_type":"k","first_type":"k","first_posted":"2026-09-02","last_posted":"2026-09-15","notices":4,"due_at":"2026-09-17T17:00:00Z","due_date":"2026-09-17","closes_at":"2026-09-17T17:00:00Z","awardable":true,"open":true,"dept_key":"d-021","dept_name":"DEPT OF DEFENSE","sub_key":"s-2100","sub_name":"DEPT OF THE ARMY","office_key":"o-W912QR","office_name":"W072 ENDIST LOUISVILLE","naics":"237310","psc":"Z2KA","set_aside":"SBA","state":"IN","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T07:50:43.959643Z"},{"key":"W912QR26BA021","latest_notice_id":"552083cd37cc43d4b2300c7b6d52b729","title":"Renovation/Repair of Bldg 27 at DSCC, OH","solicitation_number":"W912QR26BA021","notice_type":"o","first_type":"o","first_posted":"2026-08-06","last_posted":"2026-09-14","notices":10,"due_at":"2026-09-17T17:00:00Z","due_date":"2026-09-17","closes_at":"2026-09-17T17:00:00Z","awardable":true,"open":true,"dept_key":"d-021","dept_name":"DEPT OF DEFENSE","sub_key":"s-2100","sub_name":"DEPT OF THE ARMY","office_key":"o-W912QR","office_name":"W072 ENDIST LOUISVILLE","naics":"236220","psc":"Z2FB","set_aside":"SBA","state":"OH","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T07:31:38.954589Z"},{"key":"W912QR26R1C3V","latest_notice_id":"04c88174e0d143158a84a844b17c4d1a","title":"Design and Construction Services for the FY26 National Roofing Program (NRP) Project #10 - NC106 Wilmington, NC","solicitation_number":"W912QR26R1C3V","notice_type":"k","first_type":"k","first_posted":"2026-08-20","last_posted":"2026-09-14","notices":3,"due_at":"2026-09-17T18:00:00Z","due_date":"2026-09-17","closes_at":"2026-09-17T18:00:00Z","awardable":true,"open":true,"dept_key":"d-021","dept_name":"DEPT OF DEFENSE","sub_key":"s-2100","sub_name":"DEPT OF THE ARMY","office_key":"o-W912QR","office_name":"W072 ENDIST LOUISVILLE","naics":"238160","psc":"Y1JZ","set_aside":null,"state":"NC","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T07:31:38.954589Z"},{"key":"W912QR26QA101","latest_notice_id":"175710884601490e89cf6c82b00c8950","title":"C.J. Brown Dam and Reservoir Elevator Modernization - Amendment 01","solicitation_number":"W912QR26QA101","notice_type":"k","first_type":"k","first_posted":"2026-08-25","last_posted":"2026-09-15","notices":2,"due_at":"2026-09-18T14:00:00Z","due_date":"2026-09-18","closes_at":"2026-09-18T14:00:00Z","awardable":true,"open":true,"dept_key":"d-021","dept_name":"DEPT OF DEFENSE","sub_key":"s-2100","sub_name":"DEPT OF THE ARMY","office_key":"o-W912QR","office_name":"W072 ENDIST LOUISVILLE","naics":"333921","psc":"Z2AZ","set_aside":null,"state":null,"country":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T07:50:43.959643Z"}]}