{"canonical":"https://abierto.us/opportunities/w9123624b2014","key":"W9123624B2014","url":"https://abierto.us/opportunities/w9123624b2014","title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","solicitation_number":"W9123624B2014","notice_type":"a","open":false,"response_deadline":"2024-06-20T18:00:00Z","first_posted":"2024-01-12","last_posted":"2024-11-07","department":"DEPT OF DEFENSE","subagency":"DEPT OF THE ARMY","office":"W2SD ENDIST NORFOLK","naics":"236220","psc":"Y1AZ","set_aside":"SBA","place_state":"VA","place_county":"51700","place_county_name":"City of Newport News","place_city":"5156000","place_city_name":"Newport News","winner":"STRUCTURAL ENGINEERING GROUP INC","award_amount":"17003058.00","publications":[{"notice_id":"e709703464e84a4fb4c49964f8b6d81a","title":"AIT Phase IV Headquarters Buildings","solicitation_number":"W9123624B2014","notice_type":"p","base_type":"p","posted":"2024-01-12","posted_at":null,"due_at":"2024-02-01T19:00:00Z","due_date":"2024-02-01","cancelled":null,"archived":null,"archive_date":"2024-02-16","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/e709703464e84a4fb4c49964f8b6d81a/view","enriched":false,"history":[]},{"notice_id":"23acd6fad3944bb6961fa3b7aab4b94e","title":"AIT Phase IV Headquarters Buildings","solicitation_number":"W9123624B2014","notice_type":"p","base_type":"p","posted":"2024-02-07","posted_at":null,"due_at":"2024-02-22T19:00:00Z","due_date":"2024-02-22","cancelled":null,"archived":null,"archive_date":"2024-03-08","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/23acd6fad3944bb6961fa3b7aab4b94e/view","enriched":false,"history":[]},{"notice_id":"6437e91a74dc4e9eb0ec0b97edb84e09","title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","solicitation_number":"W9123624B2014","notice_type":"o","base_type":"o","posted":"2024-05-03","posted_at":null,"due_at":"2024-06-17T18:00:00Z","due_date":"2024-06-17","cancelled":null,"archived":null,"archive_date":"2025-01-01","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/6437e91a74dc4e9eb0ec0b97edb84e09/view","enriched":false,"history":[]},{"notice_id":"b1f943a171c0419e9d434638f0b90088","title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","solicitation_number":"W9123624B2014","notice_type":"o","base_type":"o","posted":"2024-05-03","posted_at":null,"due_at":"2024-06-17T18:00:00Z","due_date":"2024-06-17","cancelled":null,"archived":null,"archive_date":"2025-01-01","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/b1f943a171c0419e9d434638f0b90088/view","enriched":false,"history":[]},{"notice_id":"a23acfb34376473f9492361b496b4f2c","title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","solicitation_number":"W9123624B2014","notice_type":"o","base_type":"o","posted":"2024-05-14","posted_at":null,"due_at":"2024-06-17T18:00:00Z","due_date":"2024-06-17","cancelled":null,"archived":null,"archive_date":"2025-01-01","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/a23acfb34376473f9492361b496b4f2c/view","enriched":false,"history":[]},{"notice_id":"bbce2b53c0f14a1bb853a91d48c0e482","title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","solicitation_number":"W9123624B2014","notice_type":"o","base_type":"o","posted":"2024-05-30","posted_at":null,"due_at":"2024-06-17T18:00:00Z","due_date":"2024-06-17","cancelled":null,"archived":null,"archive_date":"2025-01-01","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/bbce2b53c0f14a1bb853a91d48c0e482/view","enriched":false,"history":[]},{"notice_id":"de6d48a6339948db91a1feaef5bdefee","title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","solicitation_number":"W9123624B2014","notice_type":"o","base_type":"o","posted":"2024-06-07","posted_at":null,"due_at":"2024-06-20T18:00:00Z","due_date":"2024-06-20","cancelled":null,"archived":null,"archive_date":"2025-01-01","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/de6d48a6339948db91a1feaef5bdefee/view","enriched":false,"history":[]},{"notice_id":"abd7d7b5b72540e382be60b9db907848","title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","solicitation_number":"W9123624B2014","notice_type":"o","base_type":"o","posted":"2024-06-12","posted_at":null,"due_at":"2024-06-20T18:00:00Z","due_date":"2024-06-20","cancelled":null,"archived":null,"archive_date":"2025-01-01","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/abd7d7b5b72540e382be60b9db907848/view","enriched":false,"history":[]},{"notice_id":"332330c8bfd64d739915caa86ce28e78","title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","solicitation_number":"W9123624B2014","notice_type":"o","base_type":"o","posted":"2024-06-14","posted_at":null,"due_at":"2024-06-20T18:00:00Z","due_date":"2024-06-20","cancelled":null,"archived":null,"archive_date":"2025-01-01","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/332330c8bfd64d739915caa86ce28e78/view","enriched":false,"history":[]},{"notice_id":"0839558440884bcc8394da20befbf439","title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","solicitation_number":"W9123624B2014","notice_type":"o","base_type":"o","posted":"2024-06-21","posted_at":null,"due_at":"2024-06-20T18:00:00Z","due_date":"2024-06-20","cancelled":null,"archived":null,"archive_date":"2025-01-01","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/0839558440884bcc8394da20befbf439/view","enriched":false,"history":[]},{"notice_id":"b78e0a07840a4f7489fd40059e1c2066","title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","solicitation_number":"W9123625C2002","notice_type":"a","base_type":"o","posted":"2024-11-07","posted_at":null,"due_at":null,"due_date":null,"cancelled":null,"archived":null,"archive_date":"2024-11-22","award_number":"W9123625C2002","awardee_name":"STRUCTURAL ENGINEERING GROUP INC Hamilton","amount":"17003058.00","link_sam":"https://sam.gov/workspace/contract/opp/b78e0a07840a4f7489fd40059e1c2066/view","enriched":false,"history":[]}],"latest_notice_id":"b78e0a07840a4f7489fd40059e1c2066","first_type":"p","notices":[{"dates":{"posted":"2024-01-12","response_deadline":{"raw":"2024-02-01T14:00:00-05:00","utc":"2024-02-01T19:00:00Z","date":"2024-02-01","time":"14:00:00","utc_offset_seconds":-18000}},"links":{"sam":"https://sam.gov/workspace/contract/opp/e709703464e84a4fb4c49964f8b6d81a/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"AIT Phase IV Headquarters Buildings","agency":{"office":{"code":"W91236","name":"W2SD ENDIST NORFOLK"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"23510-1096","city":"NORFOLK","state":"VA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-02-16","archive_type":"auto15"},"contacts":[{"name":"JACOB COODY","role":"primary","email":"jacob.w.coody@usace.army.mil","phone":"7572017814"},{"name":"Michael Hagerty","role":"secondary","email":"michael.hagerty@usace.army.mil","phone":"7572017303"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"e709703464e84a4fb4c49964f8b6d81a","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"6e4fbc4beaed345449f70dd0558ba9acd9daf3e5c4ea0814e0762333dd0d266b","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"W9123624B2014 CONSTRUCTION OF THE AIT PHASE IV HEADQUARTERS BUILDINGS FT. EUSTIS, NEWPORT NEWS, VA This is a pre-solicitation notice. This is NOT a solicitation. Do NOT submit proposals or questions in response to this notice. The U.S. Army Corps of Engineers-Norfolk District intends to issue an Invitation for Bid (IFB) for the construction of the Advanced Individual Training (AIT) Phase IV Headquarters Buildings at Ft. Eustis, Newport News, VA. This procurement will be conducted in accordance with FAR Part 14, Sealed Bidding. The Government intends to award a firm-fixed-price (FFP) contract. The requirement will be solicited as a 100% Small Business set-aside. The applicable NAICS code is 236220 - Commercial and Institutional Building Construction, with a Business Standard of $45,000,000.00, and Product Service Code of Y1AZ – Construction of Other Administrative Facilities and Service Buildings. In accordance with DFARS 236.204 - Disclosure of the Magnitude of Construction Projects, the estimated price range of construction is between $10,000,000 and 25,000,000. Project Description: The work will include construction of a standard design Battalion Headquarters Building (10,900 SF) and a standard design Brigade Headquarters Building (9,450 SF), both being single story facilities. Construction includes: special foundation, fire protection & alarm systems, and Energy Monitoring Control Systems (EMCS) connection. Sustainability and energy enhancement measures are included. Supporting facilities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping and signage, and site improvements. Heating and air conditioning will be provided by self-contained systems. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. The project will provide buildings that will be safe to personnel, protect mission critical assets, and comply with current design criteria & all applicable codes. All utility connection work required by the contract documents will need to be coordinated with the Privatized Utility Providers at Ft. Eustis. The contract completion date will be 540 calendar days after Notice to Proceed. Contractors will be required to submit bid bonds documents with the bid. The successful awardee will be required to provide 100% payment and performance bonds for the project. Prospective offerors are responsible for monitoring sam.gov to respond to the solicitation and any amendments or other information regarding this acquisition. Prospective Offerors are required to be registered in SAM when submitting an offer; and shall continue to be registered until time of award, during performance, and through final payment of any contract. The Government will not be accepting questions regarding the requirement until after the Solicitation is posted. Points of contact are the Contract Specialist Jacob Coody at jacob.w.coody@usace.army.mil and the Contracting Officer Michael Hagerty at michael.hagerty@usace.army.mil.","origin":"extract"},"notice_type":{"code":"p","label":"Presolicitation"},"schema_version":1,"solicitation_number":"W9123624B2014","place_of_performance":{"zip":"23604","city":{"name":"Fort Eustis"},"state":{"code":"VA"},"country":{"code":"USA"}},"product_service_code":"Y1AZ"},{"dates":{"posted":"2024-02-07","response_deadline":{"raw":"2024-02-22T14:00:00-05:00","utc":"2024-02-22T19:00:00Z","date":"2024-02-22","time":"14:00:00","utc_offset_seconds":-18000}},"links":{"sam":"https://sam.gov/workspace/contract/opp/23acd6fad3944bb6961fa3b7aab4b94e/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"AIT Phase IV Headquarters Buildings","agency":{"office":{"code":"W91236","name":"W2SD ENDIST NORFOLK"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"23510-1096","city":"NORFOLK","state":"VA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-03-08","archive_type":"auto15"},"contacts":[{"name":"JACOB COODY","role":"primary","email":"jacob.w.coody@usace.army.mil","phone":"7572017814"},{"name":"Michael Hagerty","role":"secondary","email":"michael.hagerty@usace.army.mil","phone":"7572017303"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"23acd6fad3944bb6961fa3b7aab4b94e","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"cd48ffc1cdb458c8641dd7f5ff38c83e6023c6c6a8961b61f43d7d4500ae8e09","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"[7FEB2024] This Pre-Solicitation is amended to include drawings and specifications for industry review in advance of the Solicitation. [12JAN2024] W9123624B2014 CONSTRUCTION OF THE AIT PHASE IV HEADQUARTERS BUILDINGS FT. EUSTIS, NEWPORT NEWS, VA This is a pre-solicitation notice. This is NOT a solicitation. Do NOT submit proposals or questions in response to this notice. The U.S. Army Corps of Engineers-Norfolk District intends to issue an Invitation for Bid (IFB) for the construction of the Advanced Individual Training (AIT) Phase IV Headquarters Buildings at Ft. Eustis, Newport News, VA. This procurement will be conducted in accordance with FAR Part 14, Sealed Bidding. The Government intends to award a firm-fixed-price (FFP) contract. The requirement will be solicited as a 100% Small Business set-aside. The applicable NAICS code is 236220 - Commercial and Institutional Building Construction, with a Business Standard of $45,000,000.00, and Product Service Code of Y1AZ – Construction of Other Administrative Facilities and Service Buildings. In accordance with DFARS 236.204 - Disclosure of the Magnitude of Construction Projects, the estimated price range of construction is between $10,000,000 and 25,000,000. Project Description: The work will include construction of a standard design Battalion Headquarters Building (10,900 SF) and a standard design Brigade Headquarters Building (9,450 SF), both being single story facilities. Construction includes: special foundation, fire protection & alarm systems, and Energy Monitoring Control Systems (EMCS) connection. Sustainability and energy enhancement measures are included. Supporting facilities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping and signage, and site improvements. Heating and air conditioning will be provided by self-contained systems. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. The project will provide buildings that will be safe to personnel, protect mission critical assets, and comply with current design criteria & all applicable codes. All utility connection work required by the contract documents will need to be coordinated with the Privatized Utility Providers at Ft. Eustis. The contract completion date will be 540 calendar days after Notice to Proceed. Contractors will be required to submit bid bonds documents with the bid. The successful awardee will be required to provide 100% payment and performance bonds for the project. Prospective offerors are responsible for monitoring sam.gov to respond to the solicitation and any amendments or other information regarding this acquisition. Prospective Offerors are required to be registered in SAM when submitting an offer; and shall continue to be registered until time of award, during performance, and through final payment of any contract. The Government will not be accepting questions regarding the requirement until after the Solicitation is posted. Points of contact are the Contract Specialist Jacob Coody at jacob.w.coody@usace.army.mil and the Contracting Officer Michael Hagerty at michael.hagerty@usace.army.mil.","origin":"extract"},"notice_type":{"code":"p","label":"Presolicitation"},"schema_version":1,"solicitation_number":"W9123624B2014","place_of_performance":{"zip":"23604","city":{"name":"Fort Eustis"},"state":{"code":"VA"},"country":{"code":"USA"}},"product_service_code":"Y1AZ"},{"dates":{"posted":"2024-05-03","response_deadline":{"raw":"2024-06-17T14:00:00-04:00","utc":"2024-06-17T18:00:00Z","date":"2024-06-17","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/6437e91a74dc4e9eb0ec0b97edb84e09/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","agency":{"office":{"code":"W91236","name":"W2SD ENDIST NORFOLK"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"23510-1096","city":"NORFOLK","state":"VA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-01-01","archive_type":"auto_custom"},"contacts":[{"name":"Jacob Coody","role":"primary","email":"jacob.w.coody@usace.army.mil","phone":"757-201-7814"},{"name":"Katya Oxley","role":"secondary","email":"ekaterina.oxley@usace.army.mil","phone":"7572017026"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"6437e91a74dc4e9eb0ec0b97edb84e09","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"68e0aa366ef77a79e6e63847ac4ae4c4a720f1e1179241aa6df948bd7fe3b709","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"The Norfolk District, Corps of Engineers is procuring a firm-fixed-price contract for the AIT Complex Phase IV Headquarters Building Construction Project at Fort Eustis (Joint Base Langley Eustis); Virginia. The work will include construction of a standard design Battalion Headquarters Building (10,900 SF) and a standard design Brigade Headquarters Building (9,450 SF), both being single story facilities. Construction includes: special foundation, fire protection and alarm systems and Energy Monitoring Control Systems (EMCS) connection. Sustainability and energy enhancement measures are included. Supporting facilities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping and signage, and site improvements. Heating and air conditioning will be provided by self-contained systems. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. The project will provide a building that will be safe to personnel, protect mission critical assets and comply with current design criteria and all applicable codes. All utility connection work required by the contract documents will need to be coordinated with the Privatized Utility Providers at JBLE-Eustis.In accordance with FAR 36.205, the statutory cost limitation for AIT Complex Phase IV Headquarters Building Construction Project is $16,000,000.00. This amount applies to CLINs 0001 through 0004. The Government shall reject an offer if its prices exceed applicable statutory limitations, unless laws or agency procedures provide pertinent exemptions. If in the Government?s interest, the contracting officer reserves the right to award of separate contracts for individual items whose prices are within or subject to applicable statutory limitations.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"W9123624B2014","product_service_code":"Y1AZ"},{"dates":{"posted":"2024-05-03","response_deadline":{"raw":"2024-06-17T14:00:00-04:00","utc":"2024-06-17T18:00:00Z","date":"2024-06-17","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/b1f943a171c0419e9d434638f0b90088/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","agency":{"office":{"code":"W91236","name":"W2SD ENDIST NORFOLK"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"23510-1096","city":"NORFOLK","state":"VA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-01-01","archive_type":"auto_custom"},"contacts":[{"name":"Jacob Coody","role":"primary","email":"jacob.w.coody@usace.army.mil","phone":"757-201-7814"},{"name":"Katya Oxley","role":"secondary","email":"ekaterina.oxley@usace.army.mil","phone":"7572017026"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"b1f943a171c0419e9d434638f0b90088","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"2f05c159187afd8534f40f528024b3b8aab43e96e55674935026f4f52cb893a9","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"The Norfolk District, Corps of Engineers is procuring a firm-fixed-price contract for the AIT Complex Phase IV Headquarters Building Construction Project at Fort Eustis (Joint Base Langley Eustis); Virginia. The work will include construction of a standard design Battalion Headquarters Building (10,900 SF) and a standard design Brigade Headquarters Building (9,450 SF), both being single story facilities. Construction includes: special foundation, fire protection and alarm systems and Energy Monitoring Control Systems (EMCS) connection. Sustainability and energy enhancement measures are included. Supporting facilities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping and signage, and site improvements. Heating and air conditioning will be provided by self-contained systems. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. The project will provide a building that will be safe to personnel, protect mission critical assets and comply with current design criteria and all applicable codes. All utility connection work required by the contract documents will need to be coordinated with the Privatized Utility Providers at JBLE-Eustis.In accordance with FAR 36.205, the statutory cost limitation for AIT Complex Phase IV Headquarters Building Construction Project is $16,000,000.00. This amount applies to CLINs 0001 through 0004. The Government shall reject an offer if its prices exceed applicable statutory limitations, unless laws or agency procedures provide pertinent exemptions. If in the Government?s interest, the contracting officer reserves the right to award of separate contracts for individual items whose prices are within or subject to applicable statutory limitations.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"W9123624B2014","product_service_code":"Y1AZ"},{"dates":{"posted":"2024-05-14","response_deadline":{"raw":"2024-06-17T14:00:00-04:00","utc":"2024-06-17T18:00:00Z","date":"2024-06-17","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/a23acfb34376473f9492361b496b4f2c/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","agency":{"office":{"code":"W91236","name":"W2SD ENDIST NORFOLK"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"23510-1096","city":"NORFOLK","state":"VA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-01-01","archive_type":"auto_custom"},"contacts":[{"name":"Jacob Coody","role":"primary","email":"jacob.w.coody@usace.army.mil","phone":"757-201-7814"},{"name":"Katya Oxley","role":"secondary","email":"ekaterina.oxley@usace.army.mil","phone":"7572017026"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"a23acfb34376473f9492361b496b4f2c","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"a327dfa14b33d7c5aa9a2027652d69fd3f127ab731ba5a1431255df2a638bf91","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"The Norfolk District, Corps of Engineers is procuring a firm-fixed-price contract for the AIT Complex Phase IV Headquarters Building Construction Project at Fort Eustis (Joint Base Langley Eustis); Virginia. The work will include construction of a standard design Battalion Headquarters Building (10,900 SF) and a standard design Brigade Headquarters Building (9,450 SF), both being single story facilities. Construction includes: special foundation, fire protection and alarm systems and Energy Monitoring Control Systems (EMCS) connection. Sustainability and energy enhancement measures are included. Supporting facilities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping and signage, and site improvements. Heating and air conditioning will be provided by self-contained systems. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. The project will provide a building that will be safe to personnel, protect mission critical assets and comply with current design criteria and all applicable codes. All utility connection work required by the contract documents will need to be coordinated with the Privatized Utility Providers at JBLE-Eustis.In accordance with FAR 36.205, the statutory cost limitation for AIT Complex Phase IV Headquarters Building Construction Project is $16,000,000.00. This amount applies to CLINs 0001 through 0004. The Government shall reject an offer if its prices exceed applicable statutory limitations, unless laws or agency procedures provide pertinent exemptions. If in the Government?s interest, the contracting officer reserves the right to award of separate contracts for individual items whose prices are within or subject to applicable statutory limitations.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"W9123624B2014","product_service_code":"Y1AZ"},{"dates":{"posted":"2024-05-30","response_deadline":{"raw":"2024-06-17T14:00:00-04:00","utc":"2024-06-17T18:00:00Z","date":"2024-06-17","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/bbce2b53c0f14a1bb853a91d48c0e482/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","agency":{"office":{"code":"W91236","name":"W2SD ENDIST NORFOLK"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"23510-1096","city":"NORFOLK","state":"VA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-01-01","archive_type":"auto_custom"},"contacts":[{"name":"Jacob Coody","role":"primary","email":"jacob.w.coody@usace.army.mil","phone":"757-201-7814"},{"name":"Katya Oxley","role":"secondary","email":"ekaterina.oxley@usace.army.mil","phone":"7572017026"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"bbce2b53c0f14a1bb853a91d48c0e482","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"9e4ff03208417a9224d8101b87a2e0ed1efd011904adef1cab4c6a3444b4556b","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"Amendment 0003: Issued to provide scalable drawings.The Norfolk District, Corps of Engineers is procuring a firm-fixed-price contract for the AIT Complex Phase IV Headquarters Building Construction Project at Fort Eustis (Joint Base Langley Eustis); Virginia. The work will include construction of a standard design Battalion Headquarters Building (10,900 SF) and a standard design Brigade Headquarters Building (9,450 SF), both being single story facilities. Construction includes: special foundation, fire protection and alarm systems and Energy Monitoring Control Systems (EMCS) connection. Sustainability and energy enhancement measures are included. Supporting facilities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping and signage, and site improvements. Heating and air conditioning will be provided by self-contained systems. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. The project will provide a building that will be safe to personnel, protect mission critical assets and comply with current design criteria and all applicable codes. All utility connection work required by the contract documents will need to be coordinated with the Privatized Utility Providers at JBLE-Eustis.In accordance with FAR 36.205, the statutory cost limitation for AIT Complex Phase IV Headquarters Building Construction Project is $16,000,000.00. This amount applies to CLINs 0001 through 0004. The Government shall reject an offer if its prices exceed applicable statutory limitations, unless laws or agency procedures provide pertinent exemptions. If in the Government?s interest, the contracting officer reserves the right to award of separate contracts for individual items whose prices are within or subject to applicable statutory limitations.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"W9123624B2014","product_service_code":"Y1AZ"},{"dates":{"posted":"2024-06-07","response_deadline":{"raw":"2024-06-20T14:00:00-04:00","utc":"2024-06-20T18:00:00Z","date":"2024-06-20","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/de6d48a6339948db91a1feaef5bdefee/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","agency":{"office":{"code":"W91236","name":"W2SD ENDIST NORFOLK"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"23510-1096","city":"NORFOLK","state":"VA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-01-01","archive_type":"auto_custom"},"contacts":[{"name":"Jacob Coody","role":"primary","email":"jacob.w.coody@usace.army.mil","phone":"757-201-7814"},{"name":"Katya Oxley","role":"secondary","email":"ekaterina.oxley@usace.army.mil","phone":"7572017026"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"de6d48a6339948db91a1feaef5bdefee","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"1ba0f4f9b88adcc77c4a5a08e9c84362a0a3d44e84807e26cf5e934ae4498793","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"Amendment 0004: Issued to extend bid due date and bid opening date. Amendment 0003: Issued to provide scalable drawings. The Norfolk District, Corps of Engineers is procuring a firm-fixed-price contract for the AIT Complex Phase IV Headquarters Building Construction Project at Fort Eustis (Joint Base Langley Eustis); Virginia. The work will include construction of a standard design Battalion Headquarters Building (10,900 SF) and a standard design Brigade Headquarters Building (9,450 SF), both being single story facilities. Construction includes: special foundation, fire protection and alarm systems and Energy Monitoring Control Systems (EMCS) connection. Sustainability and energy enhancement measures are included. Supporting facilities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping and signage, and site improvements. Heating and air conditioning will be provided by self-contained systems. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. The project will provide a building that will be safe to personnel, protect mission critical assets and comply with current design criteria and all applicable codes. All utility connection work required by the contract documents will need to be coordinated with the Privatized Utility Providers at JBLE-Eustis.In accordance with FAR 36.205, the statutory cost limitation for AIT Complex Phase IV Headquarters Building Construction Project is $16,000,000.00. This amount applies to CLINs 0001 through 0004. The Government shall reject an offer if its prices exceed applicable statutory limitations, unless laws or agency procedures provide pertinent exemptions. If in the Government?s interest, the contracting officer reserves the right to award of separate contracts for individual items whose prices are within or subject to applicable statutory limitations.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"W9123624B2014","product_service_code":"Y1AZ"},{"dates":{"posted":"2024-06-12","response_deadline":{"raw":"2024-06-20T14:00:00-04:00","utc":"2024-06-20T18:00:00Z","date":"2024-06-20","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/abd7d7b5b72540e382be60b9db907848/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","agency":{"office":{"code":"W91236","name":"W2SD ENDIST NORFOLK"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"23510-1096","city":"NORFOLK","state":"VA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-01-01","archive_type":"auto_custom"},"contacts":[{"name":"Jacob Coody","role":"primary","email":"jacob.w.coody@usace.army.mil","phone":"757-201-7814"},{"name":"Katya Oxley","role":"secondary","email":"ekaterina.oxley@usace.army.mil","phone":"7572017026"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"abd7d7b5b72540e382be60b9db907848","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"a129ce17a7658eb03d2dd780df3594791f4f66dadc101779852cafa157174e9a","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"Amendment 0005: Issued to revise the Wage Determination and provide revised attachments, which are related to answers provided in ProjNet.Amendment 0004: Issued to extend bid due date and bid opening date. Amendment 0003: Issued to provide scalable drawings. The Norfolk District, Corps of Engineers is procuring a firm-fixed-price contract for the AIT Complex Phase IV Headquarters Building Construction Project at Fort Eustis (Joint Base Langley Eustis); Virginia. The work will include construction of a standard design Battalion Headquarters Building (10,900 SF) and a standard design Brigade Headquarters Building (9,450 SF), both being single story facilities. Construction includes: special foundation, fire protection and alarm systems and Energy Monitoring Control Systems (EMCS) connection. Sustainability and energy enhancement measures are included. Supporting facilities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping and signage, and site improvements. Heating and air conditioning will be provided by self-contained systems. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. The project will provide a building that will be safe to personnel, protect mission critical assets and comply with current design criteria and all applicable codes. All utility connection work required by the contract documents will need to be coordinated with the Privatized Utility Providers at JBLE-Eustis.In accordance with FAR 36.205, the statutory cost limitation for AIT Complex Phase IV Headquarters Building Construction Project is $16,000,000.00. This amount applies to CLINs 0001 through 0004. The Government shall reject an offer if its prices exceed applicable statutory limitations, unless laws or agency procedures provide pertinent exemptions. If in the Government?s interest, the contracting officer reserves the right to award of separate contracts for individual items whose prices are within or subject to applicable statutory limitations.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"W9123624B2014","product_service_code":"Y1AZ"},{"dates":{"posted":"2024-06-14","response_deadline":{"raw":"2024-06-20T14:00:00-04:00","utc":"2024-06-20T18:00:00Z","date":"2024-06-20","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/332330c8bfd64d739915caa86ce28e78/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","agency":{"office":{"code":"W91236","name":"W2SD ENDIST NORFOLK"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"23510-1096","city":"NORFOLK","state":"VA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-01-01","archive_type":"auto_custom"},"contacts":[{"name":"Jacob Coody","role":"primary","email":"jacob.w.coody@usace.army.mil","phone":"757-201-7814"},{"name":"Katya Oxley","role":"secondary","email":"ekaterina.oxley@usace.army.mil","phone":"7572017026"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"332330c8bfd64d739915caa86ce28e78","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"2d0dbeef1108f731234ed7e0cb67a968b798e3017ca077d2c8b5a919ded47e66","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"Amendment 0006: Issued to provide ProjNet Inquiries and Responses and revised attachment. Amendment 0005: Issued to revise the Wage Determination and provide revised attachments, which are related to answers provided in ProjNet. Amendment 0004: Issued to extend bid due date and bid opening date. Amendment 0003: Issued to provide scalable drawings. The Norfolk District, Corps of Engineers is procuring a firm-fixed-price contract for the AIT Complex Phase IV Headquarters Building Construction Project at Fort Eustis (Joint Base Langley Eustis); Virginia. The work will include construction of a standard design Battalion Headquarters Building (10,900 SF) and a standard design Brigade Headquarters Building (9,450 SF), both being single story facilities. Construction includes: special foundation, fire protection and alarm systems and Energy Monitoring Control Systems (EMCS) connection. Sustainability and energy enhancement measures are included. Supporting facilities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping and signage, and site improvements. Heating and air conditioning will be provided by self-contained systems. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. The project will provide a building that will be safe to personnel, protect mission critical assets and comply with current design criteria and all applicable codes. All utility connection work required by the contract documents will need to be coordinated with the Privatized Utility Providers at JBLE-Eustis.In accordance with FAR 36.205, the statutory cost limitation for AIT Complex Phase IV Headquarters Building Construction Project is $16,000,000.00. This amount applies to CLINs 0001 through 0004. The Government shall reject an offer if its prices exceed applicable statutory limitations, unless laws or agency procedures provide pertinent exemptions. If in the Government?s interest, the contracting officer reserves the right to award of separate contracts for individual items whose prices are within or subject to applicable statutory limitations.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"W9123624B2014","product_service_code":"Y1AZ"},{"dates":{"posted":"2024-06-21","response_deadline":{"raw":"2024-06-20T14:00:00-04:00","utc":"2024-06-20T18:00:00Z","date":"2024-06-20","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/0839558440884bcc8394da20befbf439/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","agency":{"office":{"code":"W91236","name":"W2SD ENDIST NORFOLK"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"23510-1096","city":"NORFOLK","state":"VA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-01-01","archive_type":"auto_custom"},"contacts":[{"name":"Jacob Coody","role":"primary","email":"jacob.w.coody@usace.army.mil","phone":"757-201-7814"},{"name":"Katya Oxley","role":"secondary","email":"ekaterina.oxley@usace.army.mil","phone":"7572017026"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"0839558440884bcc8394da20befbf439","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"b63c36a091cdc9aea1775802437c3de24083cbaf01b529bbeea3111b39794b6e","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"Amendment 0006: Issued to provide ProjNet Inquiries and Responses and revised attachment. Amendment 0005: Issued to revise the Wage Determination and provide revised attachments, which are related to answers provided in ProjNet. Amendment 0004: Issued to extend bid due date and bid opening date. Amendment 0003: Issued to provide scalable drawings. The Norfolk District, Corps of Engineers is procuring a firm-fixed-price contract for the AIT Complex Phase IV Headquarters Building Construction Project at Fort Eustis (Joint Base Langley Eustis); Virginia. The work will include construction of a standard design Battalion Headquarters Building (10,900 SF) and a standard design Brigade Headquarters Building (9,450 SF), both being single story facilities. Construction includes: special foundation, fire protection and alarm systems and Energy Monitoring Control Systems (EMCS) connection. Sustainability and energy enhancement measures are included. Supporting facilities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping and signage, and site improvements. Heating and air conditioning will be provided by self-contained systems. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. The project will provide a building that will be safe to personnel, protect mission critical assets and comply with current design criteria and all applicable codes. All utility connection work required by the contract documents will need to be coordinated with the Privatized Utility Providers at JBLE-Eustis.In accordance with FAR 36.205, the statutory cost limitation for AIT Complex Phase IV Headquarters Building Construction Project is $16,000,000.00. This amount applies to CLINs 0001 through 0004. The Government shall reject an offer if its prices exceed applicable statutory limitations, unless laws or agency procedures provide pertinent exemptions. If in the Government?s interest, the contracting officer reserves the right to award of separate contracts for individual items whose prices are within or subject to applicable statutory limitations.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"W9123624B2014","product_service_code":"Y1AZ"},{"award":{"date":"2024-11-07","amount":"17003058.00","number":"W9123625C2002","awardee":{"raw":"STRUCTURAL ENGINEERING GROUP INC Hamilton VA 20158 USA","name":"STRUCTURAL ENGINEERING GROUP INC Hamilton","location":{"zip":"20158","state":{"code":"VA"},"country":{"code":"USA"}}}},"dates":{"posted":"2024-11-07","award_date":"2024-11-07"},"links":{"sam":"https://sam.gov/workspace/contract/opp/b78e0a07840a4f7489fd40059e1c2066/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"AIT Complex Phase IV Headquarters Building Construction Project, Fort Eustis; Virginia.","agency":{"office":{"code":"W91236","name":"W2SD ENDIST NORFOLK"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"23510-1096","city":"NORFOLK","state":"VA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-11-22","archive_type":"auto15"},"contacts":[{"name":"Jacob Coody","role":"primary","email":"jacob.w.coody@usace.army.mil","phone":"757-201-7814"},{"name":"Michael Hagerty","role":"secondary","email":"michael.hagerty@usace.army.mil","phone":"7572017303"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"b78e0a07840a4f7489fd40059e1c2066","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T19:12:38.374141Z","row_sha256":"f678038bf0d5d56631f2819263738537634208d2f3f45a36858ddc28e8803f5a","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T19:12:38.374141Z","first_seen_at":"2026-09-16T19:12:38.374141Z"},"description":{"text":"The work will include construction of a standard design Battalion Headquarters Building (10,900 SF) and a standard design Brigade Headquarters Building (9,450 SF), both being single story facilities. Construction includes: special foundation, fire protection and alarm systems and Energy Monitoring Control Systems (EMCS) connection. Sustainability and energy enhancement measures are included. Supporting facilities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping and signage, and site improvements. Heating and air conditioning will be provided by self-contained systems. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. The project will provide a building that will be safe to personnel, protect mission critical assets and comply with current design criteria and all applicable codes. All utility connection work required by the contract documents will need to be coordinated with the Privatized Utility Providers at JBLE-Eustis.","origin":"extract"},"notice_type":{"code":"a","label":"Award Notice"},"schema_version":1,"solicitation_number":"W9123625C2002","place_of_performance":{"city":{"name":"Newport News"},"state":{"code":"VA"},"country":{"code":"USA"}},"product_service_code":"Y1AZ"}],"due_at":"2024-06-20T18:00:00Z","due_date":"2024-06-20","closes_at":"2024-06-20T18:00:00Z","awardable":false,"dept_key":"d-021","dept_name":"DEPT OF DEFENSE","sub_key":"s-2100","sub_name":"DEPT OF THE ARMY","office_key":"o-W91236","office_name":"W2SD ENDIST NORFOLK","state":"VA","county":"51700","county_name":"City of Newport News","city":"5156000","city_name":"Newport News","country":"USA","winner_key":"C8YXMSHK3N34","amount":"17003058.00","linked_awards":11,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z","principal_notice_id":"b78e0a07840a4f7489fd40059e1c2066","description":{"text":"The work will include construction of a standard design Battalion Headquarters Building (10,900 SF) and a standard design Brigade Headquarters Building (9,450 SF), both being single story facilities. Construction includes: special foundation, fire protection and alarm systems and Energy Monitoring Control Systems (EMCS) connection. Sustainability and energy enhancement measures are included. Supporting facilities include site development, utilities and connections, lighting, paving, parking, walks, curbs and gutters, storm drainage, information systems, landscaping and signage, and site improvements. Heating and air conditioning will be provided by self-contained systems. Measures in accordance with the Department of Defense (DoD) Minimum Antiterrorism for Buildings standards will be provided. The project will provide a building that will be safe to personnel, protect mission critical assets and comply with current design criteria and all applicable codes. All utility connection work required by the contract documents will need to be coordinated with the Privatized Utility Providers at JBLE-Eustis.","html":null,"origin":"extract"},"contacts":[{"name":"Jacob Coody","role":"primary","email":"jacob.w.coody@usace.army.mil","phone":"757-201-7814"},{"name":"Michael Hagerty","role":"secondary","email":"michael.hagerty@usace.army.mil","phone":"7572017303"}],"place_of_performance":{"city":{"name":"Newport News"},"state":{"code":"VA"},"country":{"code":"USA"}},"office_address":{"zip":"23510-1096","city":"NORFOLK","state":"VA","country":"USA"},"naics_codes":["236220"],"award":{"date":"2024-11-07","amount":"17003058.00","number":"W9123625C2002","awardee":{"raw":"STRUCTURAL ENGINEERING GROUP INC Hamilton VA 20158 USA","name":"STRUCTURAL ENGINEERING GROUP INC Hamilton","location":{"zip":"20158","state":{"code":"VA"},"country":{"code":"USA"}}}},"attachments":[],"awards":[{"award_key":"CONT_AWD_W9123625C2002_9700_-NONE-_-NONE-","permalink":"https://www.usaspending.gov/award/CONT_AWD_W9123625C2002_9700_-NONE-_-NONE-/","piid":"W9123625C2002","parent_piid":null,"award_type":"DEFINITIVE CONTRACT","vendor_key":"C8YXMSHK3N34","recipient_name":"STRUCTURAL ENGINEERING GROUP INC","recipient_uei":"C8YXMSHK3N34","recipient_cage":"4JP87","recipient_city":"HAMILTON","recipient_state":"VA","sub_name":"Department of the Army","office_name":"W2SD ENDIST NORFOLK","office_key":"o-W91236","first_action_date":"2024-11-07","last_action_date":"2026-06-04","actions":6,"obligated":"17205123.95","current_total_value":"17205123.95","potential_total_value":"17205123.95","naics":"236220","psc":"Y1AZ","extent_competed":"FULL AND OPEN COMPETITION AFTER EXCLUSION OF SOURCES","set_aside":"SMALL BUSINESS SET ASIDE - TOTAL","offers_received":8,"description":"CONSTRUCTION OF BATTALION AND BRIGADE HEADQUARTERS BUILDINGS AT JOINT BASE LANGLEY-EUSTIS, NEWPORT NEWS, VIRGINIA.","method":"solicitation","confidence":"high","evidence":["solicitation number W9123624B2014 equals the FPDS solicitation identifier","same awarding office W91236"],"opportunity_key":null,"opportunity_title":null}],"related":[{"key":"DACA65B2704","latest_notice_id":"6f442a94a6934e6794f88306a077716e","title":"Standing_Timber_Sale_Fort_Drum","solicitation_number":"DACA65-B-27-04","notice_type":"k","first_type":"k","first_posted":"2026-08-18","last_posted":"2026-08-18","notices":1,"due_at":"2026-09-17T18:00:00Z","due_date":"2026-09-17","closes_at":"2026-09-17T18:00:00Z","awardable":true,"open":true,"dept_key":"d-021","dept_name":"DEPT OF DEFENSE","sub_key":"s-2100","sub_name":"DEPT OF THE ARMY","office_key":"o-W91236","office_name":"W2SD ENDIST NORFOLK","naics":"113310","psc":"5510","set_aside":null,"state":"NY","county":"36045","county_name":"Jefferson County","city":"3626759","city_name":"Fort Drum","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z"},{"key":"W9123626RA013","latest_notice_id":"3970274c74be4a14aadd0035b1012d2f","title":"DoWEA PMDM-NC IDIQ RFP","solicitation_number":"W9123626RA013","notice_type":"o","first_type":"o","first_posted":"2026-08-20","last_posted":"2026-09-08","notices":2,"due_at":"2026-09-21T14:00:00Z","due_date":"2026-09-21","closes_at":"2026-09-21T14:00:00Z","awardable":true,"open":true,"dept_key":"d-021","dept_name":"DEPT OF DEFENSE","sub_key":"s-2100","sub_name":"DEPT OF THE ARMY","office_key":"o-W91236","office_name":"W2SD ENDIST NORFOLK","naics":"238220","psc":"Z1CA","set_aside":"SBA","state":null,"county":null,"county_name":null,"city":null,"city_name":null,"country":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z"},{"key":"W9123627X1CJ7","latest_notice_id":"58269cbbe9064c3fb03965b3038201ae","title":"Water Intake Facility at Radford Army Ammunition Plant","solicitation_number":"W9123627X1CJ7","notice_type":"r","first_type":"r","first_posted":"2026-09-11","last_posted":"2026-09-11","notices":1,"due_at":"2026-09-28T14:00:00Z","due_date":"2026-09-28","closes_at":"2026-09-28T14:00:00Z","awardable":true,"open":true,"dept_key":"d-021","dept_name":"DEPT OF DEFENSE","sub_key":"s-2100","sub_name":"DEPT OF THE ARMY","office_key":"o-W91236","office_name":"W2SD ENDIST NORFOLK","naics":"237110","psc":"Y1NE","set_aside":null,"state":"VA","county":"51750","county_name":"City of Radford","city":"5165392","city_name":"Radford","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z"},{"key":"W9123626BA006","latest_notice_id":"f46186008fd74b78a4b34dda5272802e","title":"Fort Lee Vehicle Recovery Range","solicitation_number":"W9123626BA006","notice_type":"o","first_type":"p","first_posted":"2025-12-01","last_posted":"2026-08-25","notices":7,"due_at":"2026-09-29T18:00:00Z","due_date":"2026-09-29","closes_at":"2026-09-29T18:00:00Z","awardable":true,"open":true,"dept_key":"d-021","dept_name":"DEPT OF DEFENSE","sub_key":"s-2100","sub_name":"DEPT OF THE ARMY","office_key":"o-W91236","office_name":"W2SD ENDIST NORFOLK","naics":"236220","psc":"Y1PZ","set_aside":"8A","state":"VA","county":"51149","county_name":"Prince George County","city":"5129152","city_name":"Fort Lee","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z"},{"key":"W9123626QA004","latest_notice_id":"b44b63a740134d28b88da31dbe5b9feb","title":"Gathright Dam Herbicide Service Contract","solicitation_number":"W9123626QA004","notice_type":"o","first_type":"o","first_posted":"2026-08-31","last_posted":"2026-08-31","notices":1,"due_at":"2026-09-30T18:00:00Z","due_date":"2026-09-30","closes_at":"2026-09-30T18:00:00Z","awardable":true,"open":true,"dept_key":"d-021","dept_name":"DEPT OF DEFENSE","sub_key":"s-2100","sub_name":"DEPT OF THE ARMY","office_key":"o-W91236","office_name":"W2SD ENDIST NORFOLK","naics":"561730","psc":"S208","set_aside":"SBA","state":null,"county":null,"county_name":null,"city":null,"city_name":null,"country":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z"}]}