SV0102-27 Aluminum Blanks
\n\n\n\nSolicitation Posting: 10/23/2026
\n\nQuestions Deadline: 11/6/2026 8AM EST
\n\nProposal Deadline: 11/13/2026 2PM EST
\n\nRFQ/RFP: Request for Quote (RFQ)
\n\nContract: 2 Year, Firm Fixed Price, IDIQ, EPA
\n\nNAICS: 331315 Aluminum Sheet, Plate and Foil Manufacturing (small business size 1,400)
\n\nEPA Index: PCU331315331315 Aluminum Sheet, Plate, and Foil Manufacturing.
\n\nSmall Business Set Aside: 100% Set Aside for Small Business
\n\nSubmissions Email: Wesley Newell, Contract Specialist, wesley.newell2@usdoj.gov
\n\nDelivery Terms: FOB Destination to Unicor, 14601 Burbridge Rd, Cumberland, MD, 21502.
\n\n\n\n\n\nThis is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6 as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; offers are being requested and a written solicitation will not be issued.
\n\n\n\nUNICOR, Federal Prison Industries, Inc., intends to enter into a two (2)-year, firm-fixed-price, indefinite delivery-indefinite quantity contract for the following commercial item(s):
\n\n\n\nLine 1 SBL0127A 3105-H14 Aluminum Sheet, 7”× 10”, .040” thick 50,000 each
\n\nyellow/yellow, masked, 1/2-inch radius corners
\n\n\n\nLine 2 SBL0133 3105-H14 Aluminum Sheet, 4.5” × 5”, .040” thick 20,000 each
\n\nyellow/yellow, masked, 3/8-inch radius corners
\n\n\n\nLine 3 SBL0128 3105-H14 Aluminum Sheet, 2.5” × 15”, .040” thick 1,000 each
\n\nyellow/yellow, masked, square corners
\n\n\n\nGuaranteed contract minimum: 40,000 EA, (any combination of line items)
\n\nDelivery Order Minimum: 4,000 EA, (any combination of line items)
\n\nDelivery Order Maximum: 10,000 EA, (any combination of line items)
\n\n\n\nDelivery orders will be issued in accordance with 52.216-19.
\n\n\n\nDelivery order schedule is unknown and varies as each order is based on a specific sales.
\n\n\n\nPackaging shall comply with the specifications of ASTM D-3951-95, standard practice for commercial packages.
\n\n\n\nCommercial Goods Evaluation Factors:
\n\n\n\nTechnical specifications, price, past performance, and delivery time.
\n\nTechnical and past performance, when combined, are: More important than price.
\n\n\n\n\n\nAny amendments issued to this solicitation shall be synopsized in the same manner as this solicitation and must be acknowledged by each Offeror. Offeror must hold prices firm for 60 calendar days from the date specified for receipt of offers. Offers or modifications to offers received at the address specified for the receipt of offers after the exact time specified may not be considered.
\n\n\n\nEach submission must include the following:
\n\n\n\nSF1449, signed including line-item pricing and lead time
\n\nAll Amendments, signed
\n\nCompany Name:
\n\nCompany Address:
\n\nSAM Unique Entity Identifier (UEI):
\n\nBusiness Size: (Large or Small):
\n\nCompany Point of Contact:
\n\nTelephone number:
\n\nEmail Address:
\n\nTechnical Descriptions of Items Offered
\n\nCountry of Origination:
\n\nRolled/Manufactured in USA: (Yes / No)
\n\nWarranty:
\n\nThree Business Management Questionnaires for past performance. (or a statement indicating you are a new vendor without past performance who will not receive a positive or negative rating due to no history)
\n\n\n\n\n\nBy submission of an offer, the Offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database (System Award Management) prior to submitting a proposal, during performance and through final payment of any contract resulting from this solicitation.
\n\n\n\n\n\nNOTICE TO GOVERNMENT WHEN CONTRACTOR(S) DELAYS:
\n\nIn the event the contractor(s) encounter difficulty in meeting performance requirements, or when there is an anticipated difficulty in complying with the delivery terms or completion dates, or whenever the contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely delivery/performance of this contract, the contractor must immediately notify the Field Administrative Contracting Officers at UNICOR Cumberland or in writing, giving pertinent details. This information will not be construed as a waiver by the Government of the required delivery schedule, or the Governments rights to impose consideration against delinquencies or other remedies provided by this contract.
\n\n\n\nFuture requirements for these or similar items from this or other UNICOR factories may be added to the resulting contract if considered to fall within the scope of work and the price is determined to be fair and reasonable.
\n\n\n\nInvoices are to be emailed to: accountspayable@central.unicor.gov
","text":"SV0102-27 Aluminum Blanks\n\nSolicitation Posting: 10/23/2026\n\nQuestions Deadline: 11/6/2026 8AM EST\n\nProposal Deadline: 11/13/2026 2PM EST\n\nRFQ/RFP: Request for Quote (RFQ)\n\nContract: 2 Year, Firm Fixed Price, IDIQ, EPA\n\nNAICS: 331315 Aluminum Sheet, Plate and Foil Manufacturing (small business size 1,400)\n\nEPA Index: PCU331315331315 Aluminum Sheet, Plate, and Foil Manufacturing.\n\nSmall Business Set Aside: 100% Set Aside for Small Business\n\nSubmissions Email: Wesley Newell, Contract Specialist, wesley.newell2@usdoj.gov\n\nDelivery Terms: FOB Destination to Unicor, 14601 Burbridge Rd, Cumberland, MD, 21502.\n\nThis is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6 as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; offers are being requested and a written solicitation will not be issued.\n\nUNICOR, Federal Prison Industries, Inc., intends to enter into a two (2)-year, firm-fixed-price, indefinite delivery-indefinite quantity contract for the following commercial item(s):\n\nLine 1 SBL0127A 3105-H14 Aluminum Sheet, 7”× 10”, .040” thick 50,000 each\n\nyellow/yellow, masked, 1/2-inch radius corners\n\nLine 2 SBL0133 3105-H14 Aluminum Sheet, 4.5” × 5”, .040” thick 20,000 each\n\nyellow/yellow, masked, 3/8-inch radius corners\n\nLine 3 SBL0128 3105-H14 Aluminum Sheet, 2.5” × 15”, .040” thick 1,000 each\n\nyellow/yellow, masked, square corners\n\nGuaranteed contract minimum: 40,000 EA, (any combination of line items)\n\nDelivery Order Minimum: 4,000 EA, (any combination of line items)\n\nDelivery Order Maximum: 10,000 EA, (any combination of line items)\n\nDelivery orders will be issued in accordance with 52.216-19.\n\nDelivery order schedule is unknown and varies as each order is based on a specific sales.\n\nPackaging shall comply with the specifications of ASTM D-3951-95, standard practice for commercial packages.\n\nCommercial Goods Evaluation Factors:\n\nTechnical specifications, price, past performance, and delivery time.\n\nTechnical and past performance, when combined, are: More important than price.\n\nAny amendments issued to this solicitation shall be synopsized in the same manner as this solicitation and must be acknowledged by each Offeror. Offeror must hold prices firm for 60 calendar days from the date specified for receipt of offers. Offers or modifications to offers received at the address specified for the receipt of offers after the exact time specified may not be considered.\n\nEach submission must include the following:\n\nSF1449, signed including line-item pricing and lead time\n\nAll Amendments, signed\n\nCompany Name:\n\nCompany Address:\n\nSAM Unique Entity Identifier (UEI):\n\nBusiness Size: (Large or Small):\n\nCompany Point of Contact:\n\nTelephone number:\n\nEmail Address:\n\nTechnical Descriptions of Items Offered\n\nCountry of Origination:\n\nRolled/Manufactured in USA: (Yes / No)\n\nWarranty:\n\nThree Business Management Questionnaires for past performance. (or a statement indicating you are a new vendor without past performance who will not receive a positive or negative rating due to no history)\n\nBy submission of an offer, the Offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database (System Award Management) prior to submitting a proposal, during performance and through final payment of any contract resulting from this solicitation.\n\nNOTICE TO GOVERNMENT WHEN CONTRACTOR(S) DELAYS:\n\nIn the event the contractor(s) encounter difficulty in meeting performance requirements, or when there is an anticipated difficulty in complying with the delivery terms or completion dates, or whenever the contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely delivery/performance of this contract, the contractor must immediately notify the Field Administrative Contracting Officers at UNICOR Cumberland or in writing, giving pertinent details. This information will not be construed as a waiver by the Government of the required delivery schedule, or the Governments rights to impose consideration against delinquencies or other remedies provided by this contract.\n\nFuture requirements for these or similar items from this or other UNICOR factories may be added to the resulting contract if considered to fall within the scope of work and the price is determined to be fair and reasonable.\n\nInvoices are to be emailed to: accountspayable@central.unicor.gov","origin":"detail"},"notice_type":{"code":"k","label":"Combined Synopsis/Solicitation"},"schema_version":1,"solicitation_number":"SV0120-27","place_of_performance":{"zip":"21502","state":{"code":"MD","name":"Maryland"},"country":{"code":"USA","name":"UNITED STATES"}},"product_service_code":"9905"},{"dates":{"posted":"2026-10-27","posted_at":"2026-10-27T14:05:11.606Z","created_at":"2026-10-27T13:54:59.756Z","modified_at":"2026-10-27T14:05:11.612Z","response_deadline":{"raw":"2026-11-13T14:00:00-05:00","utc":"2026-11-13T19:00:00Z","date":"2026-11-13","time":"14:00:00","timezone":"America/New_York","utc_offset_seconds":-18000}},"links":{"sam":"https://sam.gov/workspace/contract/opp/aa9648816e3f43e49ad2b3071cc101ed/view"},"naics":{"codes":["331315"],"primary":"331315"},"title":"Aluminum Blanks","agency":{"office":{"code":"15UCUM","name":"UNITED STATES DEPARTMENT OF JUSTICE, DBA FEDERAL PRISON INDUSTRIES"},"subtier":{"code":"1542","name":"FEDERAL PRISON INDUSTRIES, INC"},"department":{"code":"015","name":"JUSTICE, DEPARTMENT OF"},"office_address":{"zip":"21502","city":"CUMBERLAND","state":"MD","country":"USA"},"organization_id":"100523330","organization_type":"OFFICE"},"status":{"active":true,"latest":true,"deleted":false,"archived":false,"cancelled":false,"publication":"published","archive_date":"2026-11-28","archive_type":"auto15"},"history":[{"index":2,"title":"Aluminum Blanks","action":"publish","latest":true,"deleted":false,"archived":false,"cancelled":false,"posted_at":"2026-10-27T14:05:11.606Z","notice_type":{"code":"k","label":"Combined Synopsis/Solicitation"},"request_type":"modify","opportunity_id":"aa9648816e3f43e49ad2b3071cc101ed","solicitation_number":"SV0120-27","parent_opportunity_id":"ac511cbbb7104265a57a138f2effd155"},{"index":1,"title":"Aluminum Blanks","action":"publish","latest":false,"deleted":false,"archived":false,"cancelled":false,"posted_at":"2026-10-26T15:41:31.140Z","notice_type":{"code":"k","label":"Combined Synopsis/Solicitation"},"request_type":"submit","opportunity_id":"ac511cbbb7104265a57a138f2effd155","solicitation_number":"SV0120-27"}],"contacts":[{"name":"Wesley Newell","role":"primary","email":"wesley.newell2@usdoj.gov"}],"base_type":{"code":"k","label":"Combined Synopsis/Solicitation"},"notice_id":"aa9648816e3f43e49ad2b3071cc101ed","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"lineage_id":"ac511cbbb7104265a57a138f2effd155","provenance":{"detail":{"endpoints":["opportunity","resources","history"],"fetched_at":"2026-10-28T04:30:42.182396626Z"},"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/datagov/ContractOpportunitiesFullCSV.csv","etag":"\"b39c5ea500075ba957a1fb03619f6009-26\"","fetched_at":"2026-10-28T03:57:20.061629687Z","row_sha256":"17aaaa18b143ce9c4eee65125aff17dcc125f5cccbdaeabc8b08b87dad562b70","last_modified":"2026-10-28T03:30:31Z"},"updated_at":"2026-10-28T04:30:42.182396626Z","first_seen_at":"2026-10-28T03:57:20.061629687Z"},"description":{"html":"SV0120-27 Aluminum Blanks
\n\n\n\nSolicitation Posting: 10/23/2026
\n\nQuestions Deadline: 11/6/2026 8AM EST
\n\nProposal Deadline: 11/13/2026 2PM EST
\n\nRFQ/RFP: Request for Quote (RFQ)
\n\nContract: 2 Year, Firm Fixed Price, IDIQ, EPA
\n\nNAICS: 331315 Aluminum Sheet, Plate and Foil Manufacturing (small business size 1,400)
\n\nEPA Index: PCU331315331315 Aluminum Sheet, Plate, and Foil Manufacturing.
\n\nSmall Business Set Aside: 100% Set Aside for Small Business
\n\nSubmissions Email: Wesley Newell, Contract Specialist, wesley.newell2@usdoj.gov
\n\nDelivery Terms: FOB Destination to Unicor, 14601 Burbridge Rd, Cumberland, MD, 21502.
\n\n\n\n\n\nThis is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6 as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; offers are being requested and a written solicitation will not be issued.
\n\n\n\nUNICOR, Federal Prison Industries, Inc., intends to enter into a two (2)-year, firm-fixed-price, indefinite delivery-indefinite quantity contract for the following commercial item(s):
\n\n\n\nLine 1 SBL0127A 3105-H14 Aluminum Sheet, 7”× 10”, .040” thick 50,000 each
\n\nyellow/yellow, masked, 1/2-inch radius corners
\n\n\n\nLine 2 SBL0133 3105-H14 Aluminum Sheet, 4.5” × 5”, .040” thick 20,000 each
\n\nyellow/yellow, masked, 3/8-inch radius corners
\n\n\n\nLine 3 SBL0128 3105-H14 Aluminum Sheet, 2.5” × 15”, .040” thick 1,000 each
\n\nyellow/yellow, masked, square corners
\n\n\n\nGuaranteed contract minimum: 40,000 EA, (any combination of line items)
\n\nDelivery Order Minimum: 4,000 EA, (any combination of line items)
\n\nDelivery Order Maximum: 10,000 EA, (any combination of line items)
\n\n\n\nDelivery orders will be issued in accordance with 52.216-19.
\n\n\n\nDelivery order schedule is unknown and varies as each order is based on a specific sales.
\n\n\n\nPackaging shall comply with the specifications of ASTM D-3951-95, standard practice for commercial packages.
\n\n\n\nCommercial Goods Evaluation Factors:
\n\n\n\nTechnical specifications, price, past performance, and delivery time.
\n\nTechnical and past performance, when combined, are: More important than price.
\n\n\n\n\n\nAny amendments issued to this solicitation shall be synopsized in the same manner as this solicitation and must be acknowledged by each Offeror. Offeror must hold prices firm for 60 calendar days from the date specified for receipt of offers. Offers or modifications to offers received at the address specified for the receipt of offers after the exact time specified may not be considered.
\n\n\n\nEach submission must include the following:
\n\n\n\nSF1449, signed including line-item pricing and lead time
\n\nAll Amendments, signed
\n\nCompany Name:
\n\nCompany Address:
\n\nSAM Unique Entity Identifier (UEI):
\n\nBusiness Size: (Large or Small):
\n\nCompany Point of Contact:
\n\nTelephone number:
\n\nEmail Address:
\n\nTechnical Descriptions of Items Offered
\n\nCountry of Origination:
\n\nRolled/Manufactured in USA: (Yes / No)
\n\nWarranty:
\n\nThree Business Management Questionnaires for past performance. (or a statement indicating you are a new vendor without past performance who will not receive a positive or negative rating due to no history)
\n\n\n\n\n\nBy submission of an offer, the Offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database (System Award Management) prior to submitting a proposal, during performance and through final payment of any contract resulting from this solicitation.
\n\n\n\n\n\nNOTICE TO GOVERNMENT WHEN CONTRACTOR(S) DELAYS:
\n\nIn the event the contractor(s) encounter difficulty in meeting performance requirements, or when there is an anticipated difficulty in complying with the delivery terms or completion dates, or whenever the contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely delivery/performance of this contract, the contractor must immediately notify the Field Administrative Contracting Officers at UNICOR Cumberland or in writing, giving pertinent details. This information will not be construed as a waiver by the Government of the required delivery schedule, or the Governments rights to impose consideration against delinquencies or other remedies provided by this contract.
\n\n\n\nFuture requirements for these or similar items from this or other UNICOR factories may be added to the resulting contract if considered to fall within the scope of work and the price is determined to be fair and reasonable.
\n\n\n\nInvoices are to be emailed to: accountspayable@central.unicor.gov
","text":"SV0120-27 Aluminum Blanks\n\nSolicitation Posting: 10/23/2026\n\nQuestions Deadline: 11/6/2026 8AM EST\n\nProposal Deadline: 11/13/2026 2PM EST\n\nRFQ/RFP: Request for Quote (RFQ)\n\nContract: 2 Year, Firm Fixed Price, IDIQ, EPA\n\nNAICS: 331315 Aluminum Sheet, Plate and Foil Manufacturing (small business size 1,400)\n\nEPA Index: PCU331315331315 Aluminum Sheet, Plate, and Foil Manufacturing.\n\nSmall Business Set Aside: 100% Set Aside for Small Business\n\nSubmissions Email: Wesley Newell, Contract Specialist, wesley.newell2@usdoj.gov\n\nDelivery Terms: FOB Destination to Unicor, 14601 Burbridge Rd, Cumberland, MD, 21502.\n\nThis is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6 as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; offers are being requested and a written solicitation will not be issued.\n\nUNICOR, Federal Prison Industries, Inc., intends to enter into a two (2)-year, firm-fixed-price, indefinite delivery-indefinite quantity contract for the following commercial item(s):\n\nLine 1 SBL0127A 3105-H14 Aluminum Sheet, 7”× 10”, .040” thick 50,000 each\n\nyellow/yellow, masked, 1/2-inch radius corners\n\nLine 2 SBL0133 3105-H14 Aluminum Sheet, 4.5” × 5”, .040” thick 20,000 each\n\nyellow/yellow, masked, 3/8-inch radius corners\n\nLine 3 SBL0128 3105-H14 Aluminum Sheet, 2.5” × 15”, .040” thick 1,000 each\n\nyellow/yellow, masked, square corners\n\nGuaranteed contract minimum: 40,000 EA, (any combination of line items)\n\nDelivery Order Minimum: 4,000 EA, (any combination of line items)\n\nDelivery Order Maximum: 10,000 EA, (any combination of line items)\n\nDelivery orders will be issued in accordance with 52.216-19.\n\nDelivery order schedule is unknown and varies as each order is based on a specific sales.\n\nPackaging shall comply with the specifications of ASTM D-3951-95, standard practice for commercial packages.\n\nCommercial Goods Evaluation Factors:\n\nTechnical specifications, price, past performance, and delivery time.\n\nTechnical and past performance, when combined, are: More important than price.\n\nAny amendments issued to this solicitation shall be synopsized in the same manner as this solicitation and must be acknowledged by each Offeror. Offeror must hold prices firm for 60 calendar days from the date specified for receipt of offers. Offers or modifications to offers received at the address specified for the receipt of offers after the exact time specified may not be considered.\n\nEach submission must include the following:\n\nSF1449, signed including line-item pricing and lead time\n\nAll Amendments, signed\n\nCompany Name:\n\nCompany Address:\n\nSAM Unique Entity Identifier (UEI):\n\nBusiness Size: (Large or Small):\n\nCompany Point of Contact:\n\nTelephone number:\n\nEmail Address:\n\nTechnical Descriptions of Items Offered\n\nCountry of Origination:\n\nRolled/Manufactured in USA: (Yes / No)\n\nWarranty:\n\nThree Business Management Questionnaires for past performance. (or a statement indicating you are a new vendor without past performance who will not receive a positive or negative rating due to no history)\n\nBy submission of an offer, the Offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database (System Award Management) prior to submitting a proposal, during performance and through final payment of any contract resulting from this solicitation.\n\nNOTICE TO GOVERNMENT WHEN CONTRACTOR(S) DELAYS:\n\nIn the event the contractor(s) encounter difficulty in meeting performance requirements, or when there is an anticipated difficulty in complying with the delivery terms or completion dates, or whenever the contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely delivery/performance of this contract, the contractor must immediately notify the Field Administrative Contracting Officers at UNICOR Cumberland or in writing, giving pertinent details. This information will not be construed as a waiver by the Government of the required delivery schedule, or the Governments rights to impose consideration against delinquencies or other remedies provided by this contract.\n\nFuture requirements for these or similar items from this or other UNICOR factories may be added to the resulting contract if considered to fall within the scope of work and the price is determined to be fair and reasonable.\n\nInvoices are to be emailed to: accountspayable@central.unicor.gov","origin":"detail"},"notice_type":{"code":"k","label":"Combined Synopsis/Solicitation"},"schema_version":1,"solicitation_number":"SV0120-27","place_of_performance":{"zip":"21502","state":{"code":"MD","name":"Maryland"},"country":{"code":"USA","name":"UNITED STATES"}},"product_service_code":"9905"},{"dates":{"posted":"2026-10-29","posted_at":"2026-10-29T17:47:03.805Z","created_at":"2026-10-29T17:45:15.718Z","modified_at":"2026-10-29T17:47:03.813Z","response_deadline":{"raw":"2026-11-13T14:00:00-05:00","utc":"2026-11-13T19:00:00Z","date":"2026-11-13","time":"14:00:00","timezone":"America/New_York","utc_offset_seconds":-18000}},"links":{"sam":"https://sam.gov/workspace/contract/opp/950f33e4f2194c8e871ccb5b2abf67a2/view"},"naics":{"codes":["331315"],"primary":"331315"},"title":"Aluminum Blanks","agency":{"office":{"code":"15UCUM","name":"UNITED STATES DEPARTMENT OF JUSTICE, DBA FEDERAL PRISON INDUSTRIES"},"subtier":{"code":"1542","name":"FEDERAL PRISON INDUSTRIES, INC"},"department":{"code":"015","name":"JUSTICE, DEPARTMENT OF"},"office_address":{"zip":"21502","city":"CUMBERLAND","state":"MD","country":"USA"},"organization_id":"100523330","organization_type":"OFFICE"},"status":{"active":true,"latest":true,"deleted":false,"archived":false,"cancelled":false,"publication":"published","archive_date":"2026-11-28","archive_type":"auto15"},"history":[{"index":3,"title":"Aluminum Blanks","action":"publish","latest":true,"deleted":false,"archived":false,"cancelled":false,"posted_at":"2026-10-29T17:47:03.805Z","notice_type":{"code":"k","label":"Combined Synopsis/Solicitation"},"request_type":"modify","opportunity_id":"950f33e4f2194c8e871ccb5b2abf67a2","solicitation_number":"SV0120-27","parent_opportunity_id":"ac511cbbb7104265a57a138f2effd155"},{"index":2,"title":"Aluminum Blanks","action":"publish","latest":false,"deleted":false,"archived":false,"cancelled":false,"posted_at":"2026-10-27T14:05:11.606Z","notice_type":{"code":"k","label":"Combined Synopsis/Solicitation"},"request_type":"modify","opportunity_id":"aa9648816e3f43e49ad2b3071cc101ed","solicitation_number":"SV0120-27","parent_opportunity_id":"ac511cbbb7104265a57a138f2effd155"},{"index":1,"title":"Aluminum Blanks","action":"publish","latest":false,"deleted":false,"archived":false,"cancelled":false,"posted_at":"2026-10-26T15:41:31.140Z","notice_type":{"code":"k","label":"Combined Synopsis/Solicitation"},"request_type":"submit","opportunity_id":"ac511cbbb7104265a57a138f2effd155","solicitation_number":"SV0120-27"}],"contacts":[{"name":"Wesley Newell","role":"primary","email":"wesley.newell2@usdoj.gov"}],"base_type":{"code":"k","label":"Combined Synopsis/Solicitation"},"notice_id":"950f33e4f2194c8e871ccb5b2abf67a2","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"lineage_id":"ac511cbbb7104265a57a138f2effd155","provenance":{"detail":{"endpoints":["opportunity","resources","history"],"fetched_at":"2026-10-30T04:14:34.812452935Z"},"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/datagov/ContractOpportunitiesFullCSV.csv","etag":"\"fee52df21fdaac6760f6309dc6a4b5e5-27\"","fetched_at":"2026-10-30T03:37:02.893800920Z","row_sha256":"412f6e1e95ca3932416064a01a734ec35899682c243c6395390910c272dcff13","last_modified":"2026-10-30T03:30:45Z"},"updated_at":"2026-10-30T04:14:34.812452935Z","first_seen_at":"2026-10-30T03:37:02.893800920Z"},"description":{"html":"SV0120-27 Aluminum Blanks
\n\n\n\nSolicitation Posting: 10/23/2026
\n\nQuestions Deadline: 11/6/2026 8AM EST
\n\nProposal Deadline: 11/13/2026 2PM EST
\n\nRFQ/RFP: Request for Quote (RFQ)
\n\nContract: 2 Year, Firm Fixed Price, IDIQ, EPA
\n\nNAICS: 331315 Aluminum Sheet, Plate and Foil Manufacturing (small business size 1,400)
\n\nEPA Index: PCU331315331315 Aluminum Sheet, Plate, and Foil Manufacturing.
\n\nSmall Business Set Aside: 100% Set Aside for Small Business
\n\nSubmissions Email: Wesley Newell, Contract Specialist, wesley.newell2@usdoj.gov
\n\nDelivery Terms: FOB Destination to Unicor, 14601 Burbridge Rd, Cumberland, MD, 21502.
\n\n\n\n\n\nThis is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6 as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; offers are being requested and a written solicitation will not be issued.
\n\n\n\nUNICOR, Federal Prison Industries, Inc., intends to enter into a two (2)-year, firm-fixed-price, indefinite delivery-indefinite quantity contract for the following commercial item(s):
\n\n\n\nLine 1 SBL0127A 3105-H14 Aluminum Sheet, 7”× 10”, .040” thick 50,000 each
\n\nyellow/yellow, masked, 1/2-inch radius corners
\n\n\n\nLine 2 SBL0133 3105-H14 Aluminum Sheet, 4.5” × 5”, .040” thick 20,000 each
\n\nyellow/yellow, masked, 3/8-inch radius corners
\n\n\n\nLine 3 SBL0128 3105-H14 Aluminum Sheet, 2.5” × 15”, .040” thick 1,000 each
\n\nyellow/yellow, masked, square corners
\n\n\n\nGuaranteed contract minimum: 40,000 EA, (any combination of line items)
\n\nDelivery Order Minimum: 4,000 EA, (any combination of line items)
\n\nDelivery Order Maximum: 10,000 EA, (any combination of line items)
\n\n\n\nDelivery orders will be issued in accordance with 52.216-19.
\n\n\n\nDelivery order schedule is unknown and varies as each order is based on a specific sales.
\n\n\n\nPackaging shall comply with the specifications of ASTM D-3951-95, standard practice for commercial packages.
\n\n\n\nCommercial Goods Evaluation Factors:
\n\n\n\nTechnical specifications, price, past performance, and delivery time.
\n\nTechnical and past performance, when combined, are: More important than price.
\n\n\n\n\n\nAny amendments issued to this solicitation shall be synopsized in the same manner as this solicitation and must be acknowledged by each Offeror. Offeror must hold prices firm for 60 calendar days from the date specified for receipt of offers. Offers or modifications to offers received at the address specified for the receipt of offers after the exact time specified may not be considered.
\n\n\n\nEach submission must include the following:
\n\n\n\nSF1449, signed including line-item pricing and lead time
\n\nAll Amendments, signed
\n\nCompany Name:
\n\nCompany Address:
\n\nSAM Unique Entity Identifier (UEI):
\n\nBusiness Size: (Large or Small):
\n\nCompany Point of Contact:
\n\nTelephone number:
\n\nEmail Address:
\n\nTechnical Descriptions of Items Offered
\n\nCountry of Origination:
\n\nRolled/Manufactured in USA: (Yes / No)
\n\nWarranty:
\n\nThree Business Management Questionnaires for past performance. (or a statement indicating you are a new vendor without past performance who will not receive a positive or negative rating due to no history)
\n\n\n\n\n\nBy submission of an offer, the Offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database (System Award Management) prior to submitting a proposal, during performance and through final payment of any contract resulting from this solicitation.
\n\n\n\n\n\nNOTICE TO GOVERNMENT WHEN CONTRACTOR(S) DELAYS:
\n\nIn the event the contractor(s) encounter difficulty in meeting performance requirements, or when there is an anticipated difficulty in complying with the delivery terms or completion dates, or whenever the contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely delivery/performance of this contract, the contractor must immediately notify the Field Administrative Contracting Officers at UNICOR Cumberland or in writing, giving pertinent details. This information will not be construed as a waiver by the Government of the required delivery schedule, or the Governments rights to impose consideration against delinquencies or other remedies provided by this contract.
\n\n\n\nFuture requirements for these or similar items from this or other UNICOR factories may be added to the resulting contract if considered to fall within the scope of work and the price is determined to be fair and reasonable.
\n\n\n\nInvoices are to be emailed to: accountspayable@central.unicor.gov
","text":"SV0120-27 Aluminum Blanks\n\nSolicitation Posting: 10/23/2026\n\nQuestions Deadline: 11/6/2026 8AM EST\n\nProposal Deadline: 11/13/2026 2PM EST\n\nRFQ/RFP: Request for Quote (RFQ)\n\nContract: 2 Year, Firm Fixed Price, IDIQ, EPA\n\nNAICS: 331315 Aluminum Sheet, Plate and Foil Manufacturing (small business size 1,400)\n\nEPA Index: PCU331315331315 Aluminum Sheet, Plate, and Foil Manufacturing.\n\nSmall Business Set Aside: 100% Set Aside for Small Business\n\nSubmissions Email: Wesley Newell, Contract Specialist, wesley.newell2@usdoj.gov\n\nDelivery Terms: FOB Destination to Unicor, 14601 Burbridge Rd, Cumberland, MD, 21502.\n\nThis is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6 as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; offers are being requested and a written solicitation will not be issued.\n\nUNICOR, Federal Prison Industries, Inc., intends to enter into a two (2)-year, firm-fixed-price, indefinite delivery-indefinite quantity contract for the following commercial item(s):\n\nLine 1 SBL0127A 3105-H14 Aluminum Sheet, 7”× 10”, .040” thick 50,000 each\n\nyellow/yellow, masked, 1/2-inch radius corners\n\nLine 2 SBL0133 3105-H14 Aluminum Sheet, 4.5” × 5”, .040” thick 20,000 each\n\nyellow/yellow, masked, 3/8-inch radius corners\n\nLine 3 SBL0128 3105-H14 Aluminum Sheet, 2.5” × 15”, .040” thick 1,000 each\n\nyellow/yellow, masked, square corners\n\nGuaranteed contract minimum: 40,000 EA, (any combination of line items)\n\nDelivery Order Minimum: 4,000 EA, (any combination of line items)\n\nDelivery Order Maximum: 10,000 EA, (any combination of line items)\n\nDelivery orders will be issued in accordance with 52.216-19.\n\nDelivery order schedule is unknown and varies as each order is based on a specific sales.\n\nPackaging shall comply with the specifications of ASTM D-3951-95, standard practice for commercial packages.\n\nCommercial Goods Evaluation Factors:\n\nTechnical specifications, price, past performance, and delivery time.\n\nTechnical and past performance, when combined, are: More important than price.\n\nAny amendments issued to this solicitation shall be synopsized in the same manner as this solicitation and must be acknowledged by each Offeror. Offeror must hold prices firm for 60 calendar days from the date specified for receipt of offers. Offers or modifications to offers received at the address specified for the receipt of offers after the exact time specified may not be considered.\n\nEach submission must include the following:\n\nSF1449, signed including line-item pricing and lead time\n\nAll Amendments, signed\n\nCompany Name:\n\nCompany Address:\n\nSAM Unique Entity Identifier (UEI):\n\nBusiness Size: (Large or Small):\n\nCompany Point of Contact:\n\nTelephone number:\n\nEmail Address:\n\nTechnical Descriptions of Items Offered\n\nCountry of Origination:\n\nRolled/Manufactured in USA: (Yes / No)\n\nWarranty:\n\nThree Business Management Questionnaires for past performance. (or a statement indicating you are a new vendor without past performance who will not receive a positive or negative rating due to no history)\n\nBy submission of an offer, the Offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database (System Award Management) prior to submitting a proposal, during performance and through final payment of any contract resulting from this solicitation.\n\nNOTICE TO GOVERNMENT WHEN CONTRACTOR(S) DELAYS:\n\nIn the event the contractor(s) encounter difficulty in meeting performance requirements, or when there is an anticipated difficulty in complying with the delivery terms or completion dates, or whenever the contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely delivery/performance of this contract, the contractor must immediately notify the Field Administrative Contracting Officers at UNICOR Cumberland or in writing, giving pertinent details. This information will not be construed as a waiver by the Government of the required delivery schedule, or the Governments rights to impose consideration against delinquencies or other remedies provided by this contract.\n\nFuture requirements for these or similar items from this or other UNICOR factories may be added to the resulting contract if considered to fall within the scope of work and the price is determined to be fair and reasonable.\n\nInvoices are to be emailed to: accountspayable@central.unicor.gov","origin":"detail"},"notice_type":{"code":"k","label":"Combined Synopsis/Solicitation"},"schema_version":1,"solicitation_number":"SV0120-27","place_of_performance":{"zip":"21502","state":{"code":"MD","name":"Maryland"},"country":{"code":"USA","name":"UNITED STATES"}},"product_service_code":"9905"}],"due_at":"2026-11-13T19:00:00Z","due_date":"2026-11-13","closes_at":"2026-11-13T19:00:00Z","awardable":true,"dept_key":"d-015","dept_name":"JUSTICE, DEPARTMENT OF","sub_key":"s-1542","sub_name":"FEDERAL PRISON INDUSTRIES, INC","office_key":"o-15UCUM","office_name":"UNITED STATES DEPARTMENT OF JUSTICE, DBA FEDERAL PRISON INDUSTRIES","state":"MD","county":"24001","county_name":"Allegany County","city":null,"city_name":null,"country":"USA","state_source":null,"state_evidence":null,"site_key":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-10-30T03:41:17.879115Z","principal_notice_id":"950f33e4f2194c8e871ccb5b2abf67a2","description":{"text":"SV0120-27 Aluminum Blanks\n\nSolicitation Posting: 10/23/2026\n\nQuestions Deadline: 11/6/2026 8AM EST\n\nProposal Deadline: 11/13/2026 2PM EST\n\nRFQ/RFP: Request for Quote (RFQ)\n\nContract: 2 Year, Firm Fixed Price, IDIQ, EPA\n\nNAICS: 331315 Aluminum Sheet, Plate and Foil Manufacturing (small business size 1,400)\n\nEPA Index: PCU331315331315 Aluminum Sheet, Plate, and Foil Manufacturing.\n\nSmall Business Set Aside: 100% Set Aside for Small Business\n\nSubmissions Email: Wesley Newell, Contract Specialist, wesley.newell2@usdoj.gov\n\nDelivery Terms: FOB Destination to Unicor, 14601 Burbridge Rd, Cumberland, MD, 21502.\n\nThis is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6 as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; offers are being requested and a written solicitation will not be issued.\n\nUNICOR, Federal Prison Industries, Inc., intends to enter into a two (2)-year, firm-fixed-price, indefinite delivery-indefinite quantity contract for the following commercial item(s):\n\nLine 1 SBL0127A 3105-H14 Aluminum Sheet, 7”× 10”, .040” thick 50,000 each\n\nyellow/yellow, masked, 1/2-inch radius corners\n\nLine 2 SBL0133 3105-H14 Aluminum Sheet, 4.5” × 5”, .040” thick 20,000 each\n\nyellow/yellow, masked, 3/8-inch radius corners\n\nLine 3 SBL0128 3105-H14 Aluminum Sheet, 2.5” × 15”, .040” thick 1,000 each\n\nyellow/yellow, masked, square corners\n\nGuaranteed contract minimum: 40,000 EA, (any combination of line items)\n\nDelivery Order Minimum: 4,000 EA, (any combination of line items)\n\nDelivery Order Maximum: 10,000 EA, (any combination of line items)\n\nDelivery orders will be issued in accordance with 52.216-19.\n\nDelivery order schedule is unknown and varies as each order is based on a specific sales.\n\nPackaging shall comply with the specifications of ASTM D-3951-95, standard practice for commercial packages.\n\nCommercial Goods Evaluation Factors:\n\nTechnical specifications, price, past performance, and delivery time.\n\nTechnical and past performance, when combined, are: More important than price.\n\nAny amendments issued to this solicitation shall be synopsized in the same manner as this solicitation and must be acknowledged by each Offeror. Offeror must hold prices firm for 60 calendar days from the date specified for receipt of offers. Offers or modifications to offers received at the address specified for the receipt of offers after the exact time specified may not be considered.\n\nEach submission must include the following:\n\nSF1449, signed including line-item pricing and lead time\n\nAll Amendments, signed\n\nCompany Name:\n\nCompany Address:\n\nSAM Unique Entity Identifier (UEI):\n\nBusiness Size: (Large or Small):\n\nCompany Point of Contact:\n\nTelephone number:\n\nEmail Address:\n\nTechnical Descriptions of Items Offered\n\nCountry of Origination:\n\nRolled/Manufactured in USA: (Yes / No)\n\nWarranty:\n\nThree Business Management Questionnaires for past performance. (or a statement indicating you are a new vendor without past performance who will not receive a positive or negative rating due to no history)\n\nBy submission of an offer, the Offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database (System Award Management) prior to submitting a proposal, during performance and through final payment of any contract resulting from this solicitation.\n\nNOTICE TO GOVERNMENT WHEN CONTRACTOR(S) DELAYS:\n\nIn the event the contractor(s) encounter difficulty in meeting performance requirements, or when there is an anticipated difficulty in complying with the delivery terms or completion dates, or whenever the contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely delivery/performance of this contract, the contractor must immediately notify the Field Administrative Contracting Officers at UNICOR Cumberland or in writing, giving pertinent details. This information will not be construed as a waiver by the Government of the required delivery schedule, or the Governments rights to impose consideration against delinquencies or other remedies provided by this contract.\n\nFuture requirements for these or similar items from this or other UNICOR factories may be added to the resulting contract if considered to fall within the scope of work and the price is determined to be fair and reasonable.\n\nInvoices are to be emailed to: accountspayable@central.unicor.gov","html":"SV0120-27 Aluminum Blanks
\n\n\n\nSolicitation Posting: 10/23/2026
\n\nQuestions Deadline: 11/6/2026 8AM EST
\n\nProposal Deadline: 11/13/2026 2PM EST
\n\nRFQ/RFP: Request for Quote (RFQ)
\n\nContract: 2 Year, Firm Fixed Price, IDIQ, EPA
\n\nNAICS: 331315 Aluminum Sheet, Plate and Foil Manufacturing (small business size 1,400)
\n\nEPA Index: PCU331315331315 Aluminum Sheet, Plate, and Foil Manufacturing.
\n\nSmall Business Set Aside: 100% Set Aside for Small Business
\n\nSubmissions Email: Wesley Newell, Contract Specialist, wesley.newell2@usdoj.gov
\n\nDelivery Terms: FOB Destination to Unicor, 14601 Burbridge Rd, Cumberland, MD, 21502.
\n\n\n\n\n\nThis is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6 as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; offers are being requested and a written solicitation will not be issued.
\n\n\n\nUNICOR, Federal Prison Industries, Inc., intends to enter into a two (2)-year, firm-fixed-price, indefinite delivery-indefinite quantity contract for the following commercial item(s):
\n\n\n\nLine 1 SBL0127A 3105-H14 Aluminum Sheet, 7”× 10”, .040” thick 50,000 each
\n\nyellow/yellow, masked, 1/2-inch radius corners
\n\n\n\nLine 2 SBL0133 3105-H14 Aluminum Sheet, 4.5” × 5”, .040” thick 20,000 each
\n\nyellow/yellow, masked, 3/8-inch radius corners
\n\n\n\nLine 3 SBL0128 3105-H14 Aluminum Sheet, 2.5” × 15”, .040” thick 1,000 each
\n\nyellow/yellow, masked, square corners
\n\n\n\nGuaranteed contract minimum: 40,000 EA, (any combination of line items)
\n\nDelivery Order Minimum: 4,000 EA, (any combination of line items)
\n\nDelivery Order Maximum: 10,000 EA, (any combination of line items)
\n\n\n\nDelivery orders will be issued in accordance with 52.216-19.
\n\n\n\nDelivery order schedule is unknown and varies as each order is based on a specific sales.
\n\n\n\nPackaging shall comply with the specifications of ASTM D-3951-95, standard practice for commercial packages.
\n\n\n\nCommercial Goods Evaluation Factors:
\n\n\n\nTechnical specifications, price, past performance, and delivery time.
\n\nTechnical and past performance, when combined, are: More important than price.
\n\n\n\n\n\nAny amendments issued to this solicitation shall be synopsized in the same manner as this solicitation and must be acknowledged by each Offeror. Offeror must hold prices firm for 60 calendar days from the date specified for receipt of offers. Offers or modifications to offers received at the address specified for the receipt of offers after the exact time specified may not be considered.
\n\n\n\nEach submission must include the following:
\n\n\n\nSF1449, signed including line-item pricing and lead time
\n\nAll Amendments, signed
\n\nCompany Name:
\n\nCompany Address:
\n\nSAM Unique Entity Identifier (UEI):
\n\nBusiness Size: (Large or Small):
\n\nCompany Point of Contact:
\n\nTelephone number:
\n\nEmail Address:
\n\nTechnical Descriptions of Items Offered
\n\nCountry of Origination:
\n\nRolled/Manufactured in USA: (Yes / No)
\n\nWarranty:
\n\nThree Business Management Questionnaires for past performance. (or a statement indicating you are a new vendor without past performance who will not receive a positive or negative rating due to no history)
\n\n\n\n\n\nBy submission of an offer, the Offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database (System Award Management) prior to submitting a proposal, during performance and through final payment of any contract resulting from this solicitation.
\n\n\n\n\n\nNOTICE TO GOVERNMENT WHEN CONTRACTOR(S) DELAYS:
\n\nIn the event the contractor(s) encounter difficulty in meeting performance requirements, or when there is an anticipated difficulty in complying with the delivery terms or completion dates, or whenever the contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely delivery/performance of this contract, the contractor must immediately notify the Field Administrative Contracting Officers at UNICOR Cumberland or in writing, giving pertinent details. This information will not be construed as a waiver by the Government of the required delivery schedule, or the Governments rights to impose consideration against delinquencies or other remedies provided by this contract.
\n\n\n\nFuture requirements for these or similar items from this or other UNICOR factories may be added to the resulting contract if considered to fall within the scope of work and the price is determined to be fair and reasonable.
\n\n\n\nInvoices are to be emailed to: accountspayable@central.unicor.gov
","origin":"detail"},"contacts":[{"name":"Wesley Newell","role":"primary","email":"wesley.newell2@usdoj.gov"}],"place_of_performance":{"zip":"21502","state":{"code":"MD","name":"Maryland"},"country":{"code":"USA","name":"UNITED STATES"}},"office_address":{"zip":"21502","city":"CUMBERLAND","state":"MD","country":"USA"},"naics_codes":["331315"],"award":null,"attachments":[{"resource_id":"d29c15d5c3044850a886a49deaea8413","name":"Business Mgmt Quest..doc","kind":"file","mime_type":".doc","size_bytes":24576,"posted_at":"2026-10-26T15:41:31.140Z","export_controlled":false,"sha256":null,"url":"https://sam.gov/api/prod/opps/v3/opportunities/resources/files/d29c15d5c3044850a886a49deaea8413/download","mirrored":false}],"awards":[],"related":[{"key":"SV010227","latest_notice_id":"5da7b372a3b54841b493a1f9043f849d","title":"Aluminum Blanks","solicitation_number":"SV0102-27","notice_type":"k","first_type":"k","first_posted":"2026-10-22","last_posted":"2026-10-22","notices":1,"due_at":"2026-11-20T19:00:00Z","due_date":"2026-11-20","closes_at":"2026-11-20T19:00:00Z","awardable":true,"open":true,"removed":false,"dept_key":"d-015","dept_name":"JUSTICE, DEPARTMENT OF","sub_key":"s-1542","sub_name":"FEDERAL PRISON INDUSTRIES, INC","office_key":"o-15UCUM","office_name":"UNITED STATES DEPARTMENT OF JUSTICE, DBA FEDERAL PRISON INDUSTRIES","naics":"331315","psc":"9535","set_aside":"SBA","state":"MD","county":"24001","county_name":"Allegany County","city":"2421325","city_name":"Cumberland","country":"USA","place_scope":"nationwide","state_source":null,"state_evidence":null,"site":null,"site_key":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":true,"removed_at":null,"updated_at":"2026-10-24T04:53:47.871867Z"}],"similar_open":[{"key":"SV010227","latest_notice_id":"5da7b372a3b54841b493a1f9043f849d","title":"Aluminum Blanks","solicitation_number":"SV0102-27","notice_type":"k","first_type":"k","first_posted":"2026-10-22","last_posted":"2026-10-22","notices":1,"due_at":"2026-11-20T19:00:00Z","due_date":"2026-11-20","closes_at":"2026-11-20T19:00:00Z","awardable":true,"open":true,"removed":false,"dept_key":"d-015","dept_name":"JUSTICE, DEPARTMENT OF","sub_key":"s-1542","sub_name":"FEDERAL PRISON INDUSTRIES, INC","office_key":"o-15UCUM","office_name":"UNITED STATES DEPARTMENT OF JUSTICE, DBA FEDERAL PRISON INDUSTRIES","naics":"331315","psc":"9535","set_aside":"SBA","state":"MD","county":"24001","county_name":"Allegany County","city":"2421325","city_name":"Cumberland","country":"USA","place_scope":"nationwide","state_source":null,"state_evidence":null,"site":null,"site_key":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":true,"removed_at":null,"updated_at":"2026-10-24T04:53:47.871867Z"},{"key":"SPE7MC27T1171","latest_notice_id":"5ea04807fed2430ba5afd9798422130e","title":"53--INSERT,SCREW THREAD","solicitation_number":"SPE7MC27T1171","notice_type":"k","first_type":"k","first_posted":"2026-10-25","last_posted":"2026-10-25","notices":1,"due_at":null,"due_date":"2026-11-02","closes_at":"2026-11-03T00:00:00Z","awardable":true,"open":true,"removed":false,"dept_key":"d-097","dept_name":"DEPT OF DEFENSE","sub_key":"s-97AS","sub_name":"DEFENSE LOGISTICS AGENCY","office_key":"o-SPE7MC","office_name":"DLA WEAPONS SUPPORT","naics":"331315","psc":"53","set_aside":null,"state":null,"county":null,"county_name":null,"city":null,"city_name":null,"country":null,"place_scope":"nationwide","state_source":null,"state_evidence":"READ: LINE 0001 QTY 36 UI EA DELIVER TO: W1A8 DLA DIST SAN JOAQUIN BY:","site":null,"site_key":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"removed_at":null,"updated_at":"2026-10-26T04:16:24.193534Z"},{"key":"80NSSC27948324Q","latest_notice_id":"2d6b730cc5d44a419cd68bcf6d3c3f68","title":"HPG Vaporizer Fan Shroud Smooth Grating","solicitation_number":"80NSSC27948324Q","notice_type":"k","first_type":"k","first_posted":"2026-10-28","last_posted":"2026-10-28","notices":1,"due_at":"2026-11-04T22:00:00Z","due_date":"2026-11-04","closes_at":"2026-11-04T22:00:00Z","awardable":true,"open":true,"removed":false,"dept_key":"d-080","dept_name":"NATIONAL AERONAUTICS AND SPACE ADMINISTRATION","sub_key":"s-8000","sub_name":"NATIONAL AERONAUTICS AND SPACE ADMINISTRATION","office_key":"o-80NSSC","office_name":"NASA SHARED SERVICES CENTER","naics":"331315","psc":"9515","set_aside":"SBA","state":"MS","county":"28045","county_name":"Hancock County","city":null,"city_name":null,"country":"USA","place_scope":"nationwide","state_source":null,"state_evidence":null,"site":null,"site_key":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"removed_at":null,"updated_at":"2026-10-29T04:15:54.363094Z"}],"similar_open_total":3}