This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.2 of the Revolutionary FAR Overhaul (RFO), as supplemented with additional information included in this notice.
\n\n\n\nQuotes are being requested and a written solicitation will not be issued. The purchase order resulting from this procurement will be a firm fixed-price Purchase Order. This opportunity is restricted to 100% Set Aside for Small Business Award. NAICS code 324110 size standard is 1,500 employees. The solicitation, SPE605-26-Q-0269, is issued as a Request for Quotation (RFQ), under RFO part 12 (Acquisition of Commercial Products and Commercial Services). This document and incorporated provisions and clauses are those in effect through the Revolutionary Federal Acquisition Regulation Overhaul (RFO) Effective Date 02/01/2026, and Defense Federal Acquisition Regulation Supplement (DFARS): DFARS Change 05/07/2026, effective date 05/07/2026; DPAS rating for potential award is PO. The clauses and provisions referenced in this solicitation may be reviewed/obtained in full text form at https://www.acquisition.gov. The prompt payment act is applicable.
\n\n\n\n\n\nNOTE: All offers shall be registered in System of Award Management (SAM), Small Business Administration (SBA), under NACIS 324110.
\n\n\n\nScope of Contract:
\n\n\n\nCLIN 0001 – The contractor shall provide under line item 0001:
\n\n\n\nFuel Type: Gasoline, Automotive (MUR)
\n\n\n\nNSN: 9130-00-148-7103
\n\n\n\nDelivery Address: Bldg 1860 SF 40 Tank Trail Fort Stewart GA 31314
\n\n\n\nQuantity: 8,500 USG
\n\n\n\nRequired Delivery Date: 17 September 2026
\n\n\n\nDelivery Hours: Between 7:30 AM and not later than 2:30 PM (Fort Belvoir, VA Time)
\n\n\n\nDelivery Mode: Tank Truck w/ Pump
\n\n\n\nDelivery Note: "VAPOR RECOVERY REQUIRES 4 1/2" FEMALE ADAPTER 4"HOSE TO UNLOAD FUEL
\n\n\n\nNo. of Tanks Capacity Type Tank Location
\n\n1 20000 ABOVE GROUND TANK(S) BLDG 1860
\n\n\n\n\n\nSpecial Note:
\n\n1. Inspection and Acceptance at Destination
\n\n2. Ensure driver carries two forms of I.D.
\n\n\n\nFOB Destination.
\n\n\n\nElectronic Funds Transfer as a means of payment will be made upon receipt and acceptance of all products through Wide Area WorkFlow (WAWF).
\n\n\n\nThe following provisions and clauses apply to this acquisition:
\n\n\n\nFAR 52-212- 1, Instructions to Offerors Commercial Products and Commercial Services; FAR 52.212-2 Evaluation of Commercial Products and Commercial Services; the evaluation criteria stated in paragraph (a) of the provision are as follows: Lowest Price Technically Acceptable. The contract award will be offered to the best value offer made to the Government, considering price, technical capability, and past performance. FAR 52.212-4, Terms and Conditions—Commercial Products and Commercial Services. FAR 52.246-2, and the following apply: FAR 52.211-11, DFARS 252.203-7000, 252.225-7021, and 252.232-7003 shall be applicable.
\n\n\n\n*Note: The government will not assume any responsibility above the 10% variance authorized by the contract.*
\n\n\n\nVariation in Quantity
\n\n(a) A variation in the quantity of any item called for by this contract will not be accepted unless the variation has been caused by conditions of loading, shipping, or packing, or allowances in manufacturing processes, and then only to the extent, if any, specified in paragraph (b).
\n\n(b) The permissible variation shall be limited to:
\n\n_10__ Percent increase
\n\n_10__ Percent decrease
\n\nThis increase or decrease shall apply to ____________.*
\n\n* Contracting Officer shall insert in the blank the designation(s) to which the percentages apply, such as-
\n\n(1) The total contract quantity;
\n\n(2) Item1 only;
\n\n(3) Each quantity specified in the delivery schedule;
\n\n(4) The total item quantity for each destination; or
\n\n(5) The total quantity of each item without regard to destination.
\n\n\n\nPLEASE NOTE: DoD installations and Federal Government facilities have access control measures and procedures in place. You and your subcontractor are responsible for knowing and complying with all physical security measures and access control procedures on the DoD installation or Federal Government facility you are delivering to. Be aware that gaining access to a DoD installation or Federal Government facility can be a lengthy process. DLA Energy is not responsible for any delays at physical security check points and will not pay for any costs incurred as a result of delays at physical security check points.
\n\n\n\nQuotes containing accelerated payment terms or additional fees/costs for delays caused at government physical security check points will not be considered.
\n\n\n\n\n\nResponsible offerors shall submit quotes to Jermaine Smith, Contract Specialist, at email jermaine.smith@dla.mil and DLAEnergyFEPCB@dla.mil.Offers are due by Wednesday, September 16, 2026, 12:00 P.M., Fort Belvoir, VA, time.
\n\n\n\nOfferors shall include all applicable taxes and fees in the offer price. DLA Energy appreciates your interest in this requirement.
","text":"This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.2 of the Revolutionary FAR Overhaul (RFO), as supplemented with additional information included in this notice.\n\nQuotes are being requested and a written solicitation will not be issued. The purchase order resulting from this procurement will be a firm fixed-price Purchase Order. This opportunity is restricted to 100% Set Aside for Small Business Award. NAICS code 324110 size standard is 1,500 employees. The solicitation, SPE605-26-Q-0269, is issued as a Request for Quotation (RFQ), under RFO part 12 (Acquisition of Commercial Products and Commercial Services). This document and incorporated provisions and clauses are those in effect through the Revolutionary Federal Acquisition Regulation Overhaul (RFO) Effective Date 02/01/2026, and Defense Federal Acquisition Regulation Supplement (DFARS): DFARS Change 05/07/2026, effective date 05/07/2026; DPAS rating for potential award is PO. The clauses and provisions referenced in this solicitation may be reviewed/obtained in full text form at https://www.acquisition.gov. The prompt payment act is applicable.\n\nNOTE: All offers shall be registered in System of Award Management (SAM), Small Business Administration (SBA), under NACIS 324110.\n\nScope of Contract:\n\nCLIN 0001 – The contractor shall provide under line item 0001:\n\nFuel Type: Gasoline, Automotive (MUR)\n\nNSN: 9130-00-148-7103\n\nDelivery Address: Bldg 1860 SF 40 Tank Trail Fort Stewart GA 31314\n\nQuantity: 8,500 USG\n\nRequired Delivery Date: 17 September 2026\n\nDelivery Hours: Between 7:30 AM and not later than 2:30 PM (Fort Belvoir, VA Time)\n\nDelivery Mode: Tank Truck w/ Pump\n\nDelivery Note: \"VAPOR RECOVERY REQUIRES 4 1/2\" FEMALE ADAPTER 4\"HOSE TO UNLOAD FUEL\n\nNo. of Tanks Capacity Type Tank Location\n\n1 20000 ABOVE GROUND TANK(S) BLDG 1860\n\nSpecial Note:\n\n1. Inspection and Acceptance at Destination\n\n2. Ensure driver carries two forms of I.D.\n\nFOB Destination.\n\nElectronic Funds Transfer as a means of payment will be made upon receipt and acceptance of all products through Wide Area WorkFlow (WAWF).\n\nThe following provisions and clauses apply to this acquisition:\n\nFAR 52-212- 1, Instructions to Offerors Commercial Products and Commercial Services; FAR 52.212-2 Evaluation of Commercial Products and Commercial Services; the evaluation criteria stated in paragraph (a) of the provision are as follows: Lowest Price Technically Acceptable. The contract award will be offered to the best value offer made to the Government, considering price, technical capability, and past performance. FAR 52.212-4, Terms and Conditions—Commercial Products and Commercial Services. FAR 52.246-2, and the following apply: FAR 52.211-11, DFARS 252.203-7000, 252.225-7021, and 252.232-7003 shall be applicable.\n\n*Note: The government will not assume any responsibility above the 10% variance authorized by the contract.*\n\nVariation in Quantity\n\n(a) A variation in the quantity of any item called for by this contract will not be accepted unless the variation has been caused by conditions of loading, shipping, or packing, or allowances in manufacturing processes, and then only to the extent, if any, specified in paragraph (b).\n\n(b) The permissible variation shall be limited to:\n\n_10__ Percent increase\n\n_10__ Percent decrease\n\nThis increase or decrease shall apply to ____________.*\n\n* Contracting Officer shall insert in the blank the designation(s) to which the percentages apply, such as-\n\n(1) The total contract quantity;\n\n(2) Item1 only;\n\n(3) Each quantity specified in the delivery schedule;\n\n(4) The total item quantity for each destination; or\n\n(5) The total quantity of each item without regard to destination.\n\nPLEASE NOTE: DoD installations and Federal Government facilities have access control measures and procedures in place. You and your subcontractor are responsible for knowing and complying with all physical security measures and access control procedures on the DoD installation or Federal Government facility you are delivering to. Be aware that gaining access to a DoD installation or Federal Government facility can be a lengthy process. DLA Energy is not responsible for any delays at physical security check points and will not pay for any costs incurred as a result of delays at physical security check points.\n\nQuotes containing accelerated payment terms or additional fees/costs for delays caused at government physical security check points will not be considered.\n\nResponsible offerors shall submit quotes to Jermaine Smith, Contract Specialist, at email jermaine.smith@dla.mil and DLAEnergyFEPCB@dla.mil.Offers are due by Wednesday, September 16, 2026, 12:00 P.M., Fort Belvoir, VA, time.\n\nOfferors shall include all applicable taxes and fees in the offer price. DLA Energy appreciates your interest in this requirement.","origin":"detail"},"notice_type":{"code":"k","label":"Combined Synopsis/Solicitation"},"schema_version":1,"solicitation_number":"SPE60526Q0269","place_of_performance":{"city":{"code":"91236","name":"Fort Stewart"},"state":{"code":"GA","name":"Georgia"},"country":{"code":"USA","name":"UNITED STATES"}},"product_service_code":"9130"}],"due_at":"2026-09-17T16:00:00Z","due_date":"2026-09-17","closes_at":"2026-09-17T16:00:00Z","awardable":true,"dept_key":"d-097","dept_name":"DEPT OF DEFENSE","sub_key":"s-97AS","sub_name":"DEFENSE LOGISTICS AGENCY","office_key":"o-SPE605","office_name":"DLA ENERGY","state":"GA","country":"USA","winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T07:50:43.959643Z","principal_notice_id":"f42af382ebfc4cde8b93c911e7070283","description":{"text":"This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.2 of the Revolutionary FAR Overhaul (RFO), as supplemented with additional information included in this notice.\n\nQuotes are being requested and a written solicitation will not be issued. The purchase order resulting from this procurement will be a firm fixed-price Purchase Order. This opportunity is restricted to 100% Set Aside for Small Business Award. NAICS code 324110 size standard is 1,500 employees. The solicitation, SPE605-26-Q-0269, is issued as a Request for Quotation (RFQ), under RFO part 12 (Acquisition of Commercial Products and Commercial Services). This document and incorporated provisions and clauses are those in effect through the Revolutionary Federal Acquisition Regulation Overhaul (RFO) Effective Date 02/01/2026, and Defense Federal Acquisition Regulation Supplement (DFARS): DFARS Change 05/07/2026, effective date 05/07/2026; DPAS rating for potential award is PO. The clauses and provisions referenced in this solicitation may be reviewed/obtained in full text form at https://www.acquisition.gov. The prompt payment act is applicable.\n\nNOTE: All offers shall be registered in System of Award Management (SAM), Small Business Administration (SBA), under NACIS 324110.\n\nScope of Contract:\n\nCLIN 0001 – The contractor shall provide under line item 0001:\n\nFuel Type: Gasoline, Automotive (MUR)\n\nNSN: 9130-00-148-7103\n\nDelivery Address: Bldg 1860 SF 40 Tank Trail Fort Stewart GA 31314\n\nQuantity: 8,500 USG\n\nRequired Delivery Date: 17 September 2026\n\nDelivery Hours: Between 7:30 AM and not later than 2:30 PM (Fort Belvoir, VA Time)\n\nDelivery Mode: Tank Truck w/ Pump\n\nDelivery Note: \"VAPOR RECOVERY REQUIRES 4 1/2\" FEMALE ADAPTER 4\"HOSE TO UNLOAD FUEL\n\nNo. of Tanks Capacity Type Tank Location\n\n1 20000 ABOVE GROUND TANK(S) BLDG 1860\n\nSpecial Note:\n\n1. Inspection and Acceptance at Destination\n\n2. Ensure driver carries two forms of I.D.\n\nFOB Destination.\n\nElectronic Funds Transfer as a means of payment will be made upon receipt and acceptance of all products through Wide Area WorkFlow (WAWF).\n\nThe following provisions and clauses apply to this acquisition:\n\nFAR 52-212- 1, Instructions to Offerors Commercial Products and Commercial Services; FAR 52.212-2 Evaluation of Commercial Products and Commercial Services; the evaluation criteria stated in paragraph (a) of the provision are as follows: Lowest Price Technically Acceptable. The contract award will be offered to the best value offer made to the Government, considering price, technical capability, and past performance. FAR 52.212-4, Terms and Conditions—Commercial Products and Commercial Services. FAR 52.246-2, and the following apply: FAR 52.211-11, DFARS 252.203-7000, 252.225-7021, and 252.232-7003 shall be applicable.\n\n*Note: The government will not assume any responsibility above the 10% variance authorized by the contract.*\n\nVariation in Quantity\n\n(a) A variation in the quantity of any item called for by this contract will not be accepted unless the variation has been caused by conditions of loading, shipping, or packing, or allowances in manufacturing processes, and then only to the extent, if any, specified in paragraph (b).\n\n(b) The permissible variation shall be limited to:\n\n_10__ Percent increase\n\n_10__ Percent decrease\n\nThis increase or decrease shall apply to ____________.*\n\n* Contracting Officer shall insert in the blank the designation(s) to which the percentages apply, such as-\n\n(1) The total contract quantity;\n\n(2) Item1 only;\n\n(3) Each quantity specified in the delivery schedule;\n\n(4) The total item quantity for each destination; or\n\n(5) The total quantity of each item without regard to destination.\n\nPLEASE NOTE: DoD installations and Federal Government facilities have access control measures and procedures in place. You and your subcontractor are responsible for knowing and complying with all physical security measures and access control procedures on the DoD installation or Federal Government facility you are delivering to. Be aware that gaining access to a DoD installation or Federal Government facility can be a lengthy process. DLA Energy is not responsible for any delays at physical security check points and will not pay for any costs incurred as a result of delays at physical security check points.\n\nQuotes containing accelerated payment terms or additional fees/costs for delays caused at government physical security check points will not be considered.\n\nResponsible offerors shall submit quotes to Jermaine Smith, Contract Specialist, at email jermaine.smith@dla.mil and DLAEnergyFEPCB@dla.mil.Offers are due by Wednesday, September 16, 2026, 12:00 P.M., Fort Belvoir, VA, time.\n\nOfferors shall include all applicable taxes and fees in the offer price. DLA Energy appreciates your interest in this requirement.","html":"This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.2 of the Revolutionary FAR Overhaul (RFO), as supplemented with additional information included in this notice.
\n\n\n\nQuotes are being requested and a written solicitation will not be issued. The purchase order resulting from this procurement will be a firm fixed-price Purchase Order. This opportunity is restricted to 100% Set Aside for Small Business Award. NAICS code 324110 size standard is 1,500 employees. The solicitation, SPE605-26-Q-0269, is issued as a Request for Quotation (RFQ), under RFO part 12 (Acquisition of Commercial Products and Commercial Services). This document and incorporated provisions and clauses are those in effect through the Revolutionary Federal Acquisition Regulation Overhaul (RFO) Effective Date 02/01/2026, and Defense Federal Acquisition Regulation Supplement (DFARS): DFARS Change 05/07/2026, effective date 05/07/2026; DPAS rating for potential award is PO. The clauses and provisions referenced in this solicitation may be reviewed/obtained in full text form at https://www.acquisition.gov. The prompt payment act is applicable.
\n\n\n\n\n\nNOTE: All offers shall be registered in System of Award Management (SAM), Small Business Administration (SBA), under NACIS 324110.
\n\n\n\nScope of Contract:
\n\n\n\nCLIN 0001 – The contractor shall provide under line item 0001:
\n\n\n\nFuel Type: Gasoline, Automotive (MUR)
\n\n\n\nNSN: 9130-00-148-7103
\n\n\n\nDelivery Address: Bldg 1860 SF 40 Tank Trail Fort Stewart GA 31314
\n\n\n\nQuantity: 8,500 USG
\n\n\n\nRequired Delivery Date: 17 September 2026
\n\n\n\nDelivery Hours: Between 7:30 AM and not later than 2:30 PM (Fort Belvoir, VA Time)
\n\n\n\nDelivery Mode: Tank Truck w/ Pump
\n\n\n\nDelivery Note: "VAPOR RECOVERY REQUIRES 4 1/2" FEMALE ADAPTER 4"HOSE TO UNLOAD FUEL
\n\n\n\nNo. of Tanks Capacity Type Tank Location
\n\n1 20000 ABOVE GROUND TANK(S) BLDG 1860
\n\n\n\n\n\nSpecial Note:
\n\n1. Inspection and Acceptance at Destination
\n\n2. Ensure driver carries two forms of I.D.
\n\n\n\nFOB Destination.
\n\n\n\nElectronic Funds Transfer as a means of payment will be made upon receipt and acceptance of all products through Wide Area WorkFlow (WAWF).
\n\n\n\nThe following provisions and clauses apply to this acquisition:
\n\n\n\nFAR 52-212- 1, Instructions to Offerors Commercial Products and Commercial Services; FAR 52.212-2 Evaluation of Commercial Products and Commercial Services; the evaluation criteria stated in paragraph (a) of the provision are as follows: Lowest Price Technically Acceptable. The contract award will be offered to the best value offer made to the Government, considering price, technical capability, and past performance. FAR 52.212-4, Terms and Conditions—Commercial Products and Commercial Services. FAR 52.246-2, and the following apply: FAR 52.211-11, DFARS 252.203-7000, 252.225-7021, and 252.232-7003 shall be applicable.
\n\n\n\n*Note: The government will not assume any responsibility above the 10% variance authorized by the contract.*
\n\n\n\nVariation in Quantity
\n\n(a) A variation in the quantity of any item called for by this contract will not be accepted unless the variation has been caused by conditions of loading, shipping, or packing, or allowances in manufacturing processes, and then only to the extent, if any, specified in paragraph (b).
\n\n(b) The permissible variation shall be limited to:
\n\n_10__ Percent increase
\n\n_10__ Percent decrease
\n\nThis increase or decrease shall apply to ____________.*
\n\n* Contracting Officer shall insert in the blank the designation(s) to which the percentages apply, such as-
\n\n(1) The total contract quantity;
\n\n(2) Item1 only;
\n\n(3) Each quantity specified in the delivery schedule;
\n\n(4) The total item quantity for each destination; or
\n\n(5) The total quantity of each item without regard to destination.
\n\n\n\nPLEASE NOTE: DoD installations and Federal Government facilities have access control measures and procedures in place. You and your subcontractor are responsible for knowing and complying with all physical security measures and access control procedures on the DoD installation or Federal Government facility you are delivering to. Be aware that gaining access to a DoD installation or Federal Government facility can be a lengthy process. DLA Energy is not responsible for any delays at physical security check points and will not pay for any costs incurred as a result of delays at physical security check points.
\n\n\n\nQuotes containing accelerated payment terms or additional fees/costs for delays caused at government physical security check points will not be considered.
\n\n\n\n\n\nResponsible offerors shall submit quotes to Jermaine Smith, Contract Specialist, at email jermaine.smith@dla.mil and DLAEnergyFEPCB@dla.mil.Offers are due by Wednesday, September 16, 2026, 12:00 P.M., Fort Belvoir, VA, time.
\n\n\n\nOfferors shall include all applicable taxes and fees in the offer price. DLA Energy appreciates your interest in this requirement.
","origin":"detail"},"contacts":[{"name":"Jermaine Smith","role":"primary","email":"Jermaine.Smith@dla.mil","phone":"7034089768"}],"place_of_performance":{"city":{"code":"91236","name":"Fort Stewart"},"state":{"code":"GA","name":"Georgia"},"country":{"code":"USA","name":"UNITED STATES"}},"office_address":{"zip":"22060","city":"FORT BELVOIR","state":"VA","country":"USA"},"naics_codes":["324110"],"award":null,"attachments":[],"awards":[],"related":[{"key":"SPE60526Q0270","latest_notice_id":"f41b8be72eb3410d8098df5bee954dd4","title":"SPE60526Q0270 - CAMP LEJEUNE, NC 16,000 USG GASOLINE, AUTOMOTIVE (MUR) REQUIRED DELIVERY DATE (RDD) 17 SEPTEMBER 2026","solicitation_number":"SPE60526Q0270","notice_type":"k","first_type":"k","first_posted":"2026-09-15","last_posted":"2026-09-15","notices":1,"due_at":"2026-09-17T16:00:00Z","due_date":"2026-09-17","closes_at":"2026-09-17T16:00:00Z","awardable":true,"open":true,"dept_key":"d-097","dept_name":"DEPT OF DEFENSE","sub_key":"s-97AS","sub_name":"DEFENSE LOGISTICS AGENCY","office_key":"o-SPE605","office_name":"DLA ENERGY","naics":"324110","psc":"9130","set_aside":"SBA","state":"NC","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T07:50:43.959643Z"},{"key":"SPE60526RDOSERBIL","latest_notice_id":"eaedcf23cbd340a9ad02e7f2460ebbaa","title":"Department of State (Erbil, Iraq)","solicitation_number":"SPE60526RDOSERBIL","notice_type":"p","first_type":"p","first_posted":"2026-08-25","last_posted":"2026-08-25","notices":1,"due_at":"2026-09-24T19:00:00Z","due_date":"2026-09-24","closes_at":"2026-09-24T19:00:00Z","awardable":true,"open":true,"dept_key":"d-097","dept_name":"DEPT OF DEFENSE","sub_key":"s-97AS","sub_name":"DEFENSE LOGISTICS AGENCY","office_key":"o-SPE605","office_name":"DLA ENERGY","naics":"324110","psc":"9140","set_aside":null,"state":null,"country":"IRQ","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T07:31:38.954589Z"}]}