{"canonical":"https://abierto.us/opportunities/panmcc25p0000011547","key":"PANMCC25P0000011547","url":"https://abierto.us/opportunities/panmcc25p0000011547","title":"Uninterrupted Power Supply (UPS)Battery Replacement_ MEDDAC Fort Carson, CO","solicitation_number":"PANMCC-25-P-0000-011547","notice_type":"r","open":false,"response_deadline":"2025-01-20T15:00:00Z","first_posted":"2025-01-14","last_posted":"2025-01-16","department":"DEPT OF DEFENSE","subagency":"DEPT OF THE ARMY","office":"W6QM MICC-FT CARSON","naics":"335910","psc":"6140","set_aside":null,"place_state":"CO","place_county":"08041","place_county_name":"El Paso County","place_city":"0816000","place_city_name":"Colorado Springs","winner":null,"award_amount":null,"publications":[{"notice_id":"94a4c83c4fb64747882e390f36ef2976","title":"Uninterrupted Power Supply (UPS)Battery Replacement_ MEDDAC Fort Carson, CO","solicitation_number":"PANMCC-25-P-0000-011547","notice_type":"r","base_type":"r","posted":"2025-01-14","posted_at":null,"due_at":"2025-01-20T15:00:00Z","due_date":"2025-01-20","cancelled":null,"archived":null,"archive_date":"2025-01-24","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/94a4c83c4fb64747882e390f36ef2976/view","enriched":false,"history":[]},{"notice_id":"309ccc99ccf54944a4022d4fb27c6db0","title":"Uninterrupted Power Supply (UPS)Battery Replacement_ MEDDAC Fort Carson, CO","solicitation_number":"PANMCC-25-P-0000-011547","notice_type":"r","base_type":"r","posted":"2025-01-15","posted_at":null,"due_at":"2025-01-20T15:00:00Z","due_date":"2025-01-20","cancelled":null,"archived":null,"archive_date":"2025-01-24","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/309ccc99ccf54944a4022d4fb27c6db0/view","enriched":false,"history":[]},{"notice_id":"0b4cff5104c1433fab9047b145a79950","title":"Uninterrupted Power Supply (UPS)Battery Replacement_ MEDDAC Fort Carson, CO","solicitation_number":"PANMCC-25-P-0000-011547","notice_type":"r","base_type":"r","posted":"2025-01-16","posted_at":null,"due_at":"2025-01-20T15:00:00Z","due_date":"2025-01-20","cancelled":null,"archived":null,"archive_date":"2025-01-24","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/0b4cff5104c1433fab9047b145a79950/view","enriched":false,"history":[]}],"latest_notice_id":"0b4cff5104c1433fab9047b145a79950","first_type":"r","notices":[{"dates":{"posted":"2025-01-14","response_deadline":{"raw":"2025-01-20T08:00:00-07:00","utc":"2025-01-20T15:00:00Z","date":"2025-01-20","time":"08:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/94a4c83c4fb64747882e390f36ef2976/view"},"naics":{"codes":["335910"],"primary":"335910"},"title":"Uninterrupted Power Supply (UPS)Battery Replacement_ MEDDAC Fort Carson, CO","agency":{"office":{"code":"W911RZ","name":"W6QM MICC-FT CARSON"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"80913-5198","city":"FORT CARSON","state":"CO","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-01-24","archive_type":"auto_custom"},"contacts":[{"name":"SSG Hernandez Emmanuel","role":"primary","email":"emmanuel.hernandezcasiano.mil@army.mil","phone":"7199522548"},{"name":"Julia Gomez","role":"secondary","email":"julia.e.gomez.civ@mail.mil"}],"base_type":{"code":"r","label":"Sources Sought"},"notice_id":"94a4c83c4fb64747882e390f36ef2976","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"0157ead6f36d4d896488685860217a695c418bc8240b8afc2dcb792fb3ae19bf","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"This is a non-personal services Sources Sought to replace a total of 80 UPS System Batteries for Evans Army Community Hospital at Fort Carson CO. Period of Performance 01 March 2025 to 30 May 2025. Contractor shall provide non-personal services replacing UPS-B Batteries to include LOTO (Lockout Tagout) with Evans Army Community Hospital (EACH) O&M Contractor and put the batteries in service after installation. UPS-B (Uninterruptible Power Supply) is Schneider Electric brand SKU GVSUPS100KD (GALAXY VS UPS 100KW) SN-ID2036007573. Battery type is DataSafe HX model 12HX400-FR (12V, 381W/cell, 15 min, Flame Retardant). The contractor shall provide battery parts warranty from the manufacturer and installation labor warranty. The contractor shall coordinate with EACH Health Information Technology (HIT) Department to schedule the battery replacement. The contractor shall coordinate with Schneider Electric to certify, test, verify, turn on and commission the UPS after the battery installation is completed. The contractor shall provide results of the UPS certification, verification, and testing to EACH Facilities Management. The contractor shall remove old batteries and dispose IAW federal and state regulations for battery disposal. THIS SOURCES SOUGHT IS FOR INFORMATIONAL PURPOSES ONLY. THIS IS NOT A \"REQUEST FOR PROPOSAL (RFP)\" TO BE SUBMITTED. IT DOES NOT CONSTITUTE A SOLICITATION AND SHALL NOT BE CONSTRUED AS A COMMITMENT BY THE GOVERNMENT. RESPONSES IN ANY FORM ARE NOT OFFERS AND THE GOVERNMENT IS UNDER NO OBLIGATION TO AWARD A CONTRACT AS A RESULT OF THIS ANNOUNCEMENT. NO FUNDS ARE AVAILABLE TO PAY FOR PREPARATION OF RESPONSES TO THIS ANNOUNCEMENT. ANY INFORMATION SUBMITTED BY RESPONDENTS TO THIS TECHNICAL DESCRIPTION IS STRICTLY VOLUNTARY. RESPONSES WILL NOT BE RETURNED TO THE RESPONDER. NOT RESPONDING TO THIS NOTICE DOES NOT PRECLUDE PARTICIPATION IN ANY FUTURE REQUEST FOR QUOTE (RFQ) OR INVITATION FOR BID (IFB) OR RFP, IF ANY ISSUED. IF A SOLICITATION IS RELEASED, IT WILL BE SYNOPSIZED ON THE GOVERNMENT-WIDE POINT OF ENTRY IGPE). IT IS THE RESPONSIBILITY OF POTENTIAL OFFERORS TO MONITOR THE GPE FOR ADDITIONAL INFORMMATION PERTAINING TO THIS REQUIREMENT","origin":"extract"},"notice_type":{"code":"r","label":"Sources Sought"},"schema_version":1,"solicitation_number":"PANMCC-25-P-0000-011547","place_of_performance":{"zip":"80913","city":{"name":"Colorado Springs"},"state":{"code":"CO"},"country":{"code":"USA"}},"product_service_code":"6140"},{"dates":{"posted":"2025-01-15","response_deadline":{"raw":"2025-01-20T08:00:00-07:00","utc":"2025-01-20T15:00:00Z","date":"2025-01-20","time":"08:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/309ccc99ccf54944a4022d4fb27c6db0/view"},"naics":{"codes":["335910"],"primary":"335910"},"title":"Uninterrupted Power Supply (UPS)Battery Replacement_ MEDDAC Fort Carson, CO","agency":{"office":{"code":"W911RZ","name":"W6QM MICC-FT CARSON"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"80913-5198","city":"FORT CARSON","state":"CO","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-01-24","archive_type":"auto_custom"},"contacts":[{"name":"SSG Hernandez Emmanuel","role":"primary","email":"emmanuel.hernandezcasiano.mil@army.mil","phone":"7199522548"},{"name":"Julia Gomez","role":"secondary","email":"julia.e.gomez.civ@mail.mil"}],"base_type":{"code":"r","label":"Sources Sought"},"notice_id":"309ccc99ccf54944a4022d4fb27c6db0","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"878b8bbb0a01edae1e6f80e3a4bf0fa83a42b7f60c334176ce294527885de303","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"This is a non-personal services Sources Sought to replace a total of 80 UPS System Batteries for Evans Army Community Hospital at Fort Carson CO. Period of Performance 01 March 2025 to 30 May 2025. Contractor shall provide non-personal services replacing UPS-B Batteries to include LOTO (Lockout Tagout) with Evans Army Community Hospital (EACH) O&M Contractor and put the batteries in service after installation. UPS-B (Uninterruptible Power Supply) is Schneider Electric brand SKU GVSUPS100KD (GALAXY VS UPS 100KW) SN-ID2036007573. Battery type is DataSafe HX model 12HX400-FR (12V, 381W/cell, 15 min, Flame Retardant). The contractor shall provide battery parts warranty from the manufacturer and installation labor warranty. The contractor shall coordinate with EACH Health Information Technology (HIT) Department to schedule the battery replacement. The contractor shall coordinate with Schneider Electric to certify, test, verify, turn on and commission the UPS after the battery installation is completed. The contractor shall provide results of the UPS certification, verification, and testing to EACH Facilities Management. The contractor shall remove old batteries and dispose IAW federal and state regulations for battery disposal. THIS SOURCES SOUGHT IS FOR INFORMATIONAL PURPOSES ONLY. THIS IS NOT A \"REQUEST FOR PROPOSAL (RFP)\" TO BE SUBMITTED. IT DOES NOT CONSTITUTE A SOLICITATION AND SHALL NOT BE CONSTRUED AS A COMMITMENT BY THE GOVERNMENT. RESPONSES IN ANY FORM ARE NOT OFFERS AND THE GOVERNMENT IS UNDER NO OBLIGATION TO AWARD A CONTRACT AS A RESULT OF THIS ANNOUNCEMENT. NO FUNDS ARE AVAILABLE TO PAY FOR PREPARATION OF RESPONSES TO THIS ANNOUNCEMENT. ANY INFORMATION SUBMITTED BY RESPONDENTS TO THIS TECHNICAL DESCRIPTION IS STRICTLY VOLUNTARY. RESPONSES WILL NOT BE RETURNED TO THE RESPONDER. NOT RESPONDING TO THIS NOTICE DOES NOT PRECLUDE PARTICIPATION IN ANY FUTURE REQUEST FOR QUOTE (RFQ) OR INVITATION FOR BID (IFB) OR RFP, IF ANY ISSUED. IF A SOLICITATION IS RELEASED, IT WILL BE SYNOPSIZED ON THE GOVERNMENT-WIDE POINT OF ENTRY IGPE). IT IS THE RESPONSIBILITY OF POTENTIAL OFFERORS TO MONITOR THE GPE FOR ADDITIONAL INFORMMATION PERTAINING TO THIS REQUIREMENT","origin":"extract"},"notice_type":{"code":"r","label":"Sources Sought"},"schema_version":1,"solicitation_number":"PANMCC-25-P-0000-011547","place_of_performance":{"zip":"80913","city":{"name":"Colorado Springs"},"state":{"code":"CO"},"country":{"code":"USA"}},"product_service_code":"6140"},{"dates":{"posted":"2025-01-16","response_deadline":{"raw":"2025-01-20T08:00:00-07:00","utc":"2025-01-20T15:00:00Z","date":"2025-01-20","time":"08:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/0b4cff5104c1433fab9047b145a79950/view"},"naics":{"codes":["335910"],"primary":"335910"},"title":"Uninterrupted Power Supply (UPS)Battery Replacement_ MEDDAC Fort Carson, CO","agency":{"office":{"code":"W911RZ","name":"W6QM MICC-FT CARSON"},"subtier":{"code":"2100","name":"DEPT OF THE ARMY"},"department":{"code":"021","name":"DEPT OF DEFENSE"},"office_address":{"zip":"80913-5198","city":"FORT CARSON","state":"CO","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-01-24","archive_type":"auto_custom"},"contacts":[{"name":"SSG Hernandez Emmanuel","role":"primary","email":"emmanuel.hernandezcasiano.mil@army.mil","phone":"7199522548"},{"name":"Julia Gomez","role":"secondary","email":"julia.e.gomez.civ@mail.mil"}],"base_type":{"code":"r","label":"Sources Sought"},"notice_id":"0b4cff5104c1433fab9047b145a79950","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"dd20dee6ef45b981d14122632bccde40a348a9ad16222c040fbaf0ad0f02c370","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"This is a non-personal services Sources Sought to replace a total of 80 UPS System Batteries for Evans Army Community Hospital at Fort Carson CO. Period of Performance 01 March 2025 to 30 May 2025. Contractor shall provide non-personal services replacing UPS-B Batteries to include LOTO (Lockout Tagout) with Evans Army Community Hospital (EACH) O&M Contractor and put the batteries in service after installation. UPS-B (Uninterruptible Power Supply) is Schneider Electric brand SKU GVSUPS100KD (GALAXY VS UPS 100KW) SN-ID2036007573. Battery type is12HRL400 Lead Acid High-Rate Series 12 Volt / 100 Ah @ 20 Hr with Recessed M6 Terminals and Flame Retardant ABS Plastic Case. Dimensions 12.8? (L) x 6.81? (W) x 8.39? (H). The contractor shall provide similar batteries or equal to; in addition to parts warranty from the manufacturer and installation labor warranty. The contractor shall coordinate with EACH Health Information Technology (HIT) Department to schedule the battery replacement. The contractor shall coordinate with Schneider Electric to certify, test, verify, turn on and commission the UPS after the battery installation is completed. The contractor shall provide results of the UPS certification, verification, and testing to EACH Facilities Management. The contractor shall remove old batteries and dispose IAW federal and state regulations for battery disposal. THIS SOURCES SOUGHT IS FOR INFORMATIONAL PURPOSES ONLY. THIS IS NOT A \"REQUEST FOR PROPOSAL (RFP)\" TO BE SUBMITTED. IT DOES NOT CONSTITUTE A SOLICITATION AND SHALL NOT BE CONSTRUED AS A COMMITMENT BY THE GOVERNMENT. RESPONSES IN ANY FORM ARE NOT OFFERS AND THE GOVERNMENT IS UNDER NO OBLIGATION TO AWARD A CONTRACT AS A RESULT OF THIS ANNOUNCEMENT. NO FUNDS ARE AVAILABLE TO PAY FOR PREPARATION OF RESPONSES TO THIS ANNOUNCEMENT. ANY INFORMATION SUBMITTED BY RESPONDENTS TO THIS TECHNICAL DESCRIPTION IS STRICTLY VOLUNTARY. RESPONSES WILL NOT BE RETURNED TO THE RESPONDER. NOT RESPONDING TO THIS NOTICE DOES NOT PRECLUDE PARTICIPATION IN ANY FUTURE REQUEST FOR QUOTE (RFQ) OR INVITATION FOR BID (IFB) OR RFP, IF ANY ISSUED. IF A SOLICITATION IS RELEASED, IT WILL BE SYNOPSIZED ON THE GOVERNMENT-WIDE POINT OF ENTRY IGPE). IT IS THE RESPONSIBILITY OF POTENTIAL OFFERORS TO MONITOR THE GPE FOR ADDITIONAL INFORMMATION PERTAINING TO THIS REQUIREMENT","origin":"extract"},"notice_type":{"code":"r","label":"Sources Sought"},"schema_version":1,"solicitation_number":"PANMCC-25-P-0000-011547","place_of_performance":{"zip":"80913","city":{"name":"Colorado Springs"},"state":{"code":"CO"},"country":{"code":"USA"}},"product_service_code":"6140"}],"due_at":"2025-01-20T15:00:00Z","due_date":"2025-01-20","closes_at":"2025-01-20T15:00:00Z","awardable":true,"dept_key":"d-021","dept_name":"DEPT OF DEFENSE","sub_key":"s-2100","sub_name":"DEPT OF THE ARMY","office_key":"o-W911RZ","office_name":"W6QM MICC-FT CARSON","state":"CO","county":"08041","county_name":"El Paso County","city":"0816000","city_name":"Colorado Springs","country":"USA","winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z","principal_notice_id":"0b4cff5104c1433fab9047b145a79950","description":{"text":"This is a non-personal services Sources Sought to replace a total of 80 UPS System Batteries for Evans Army Community Hospital at Fort Carson CO. Period of Performance 01 March 2025 to 30 May 2025. Contractor shall provide non-personal services replacing UPS-B Batteries to include LOTO (Lockout Tagout) with Evans Army Community Hospital (EACH) O&M Contractor and put the batteries in service after installation. UPS-B (Uninterruptible Power Supply) is Schneider Electric brand SKU GVSUPS100KD (GALAXY VS UPS 100KW) SN-ID2036007573. Battery type is12HRL400 Lead Acid High-Rate Series 12 Volt / 100 Ah @ 20 Hr with Recessed M6 Terminals and Flame Retardant ABS Plastic Case. Dimensions 12.8? (L) x 6.81? (W) x 8.39? (H). The contractor shall provide similar batteries or equal to; in addition to parts warranty from the manufacturer and installation labor warranty. The contractor shall coordinate with EACH Health Information Technology (HIT) Department to schedule the battery replacement. The contractor shall coordinate with Schneider Electric to certify, test, verify, turn on and commission the UPS after the battery installation is completed. The contractor shall provide results of the UPS certification, verification, and testing to EACH Facilities Management. The contractor shall remove old batteries and dispose IAW federal and state regulations for battery disposal. THIS SOURCES SOUGHT IS FOR INFORMATIONAL PURPOSES ONLY. THIS IS NOT A \"REQUEST FOR PROPOSAL (RFP)\" TO BE SUBMITTED. IT DOES NOT CONSTITUTE A SOLICITATION AND SHALL NOT BE CONSTRUED AS A COMMITMENT BY THE GOVERNMENT. RESPONSES IN ANY FORM ARE NOT OFFERS AND THE GOVERNMENT IS UNDER NO OBLIGATION TO AWARD A CONTRACT AS A RESULT OF THIS ANNOUNCEMENT. NO FUNDS ARE AVAILABLE TO PAY FOR PREPARATION OF RESPONSES TO THIS ANNOUNCEMENT. ANY INFORMATION SUBMITTED BY RESPONDENTS TO THIS TECHNICAL DESCRIPTION IS STRICTLY VOLUNTARY. RESPONSES WILL NOT BE RETURNED TO THE RESPONDER. NOT RESPONDING TO THIS NOTICE DOES NOT PRECLUDE PARTICIPATION IN ANY FUTURE REQUEST FOR QUOTE (RFQ) OR INVITATION FOR BID (IFB) OR RFP, IF ANY ISSUED. IF A SOLICITATION IS RELEASED, IT WILL BE SYNOPSIZED ON THE GOVERNMENT-WIDE POINT OF ENTRY IGPE). IT IS THE RESPONSIBILITY OF POTENTIAL OFFERORS TO MONITOR THE GPE FOR ADDITIONAL INFORMMATION PERTAINING TO THIS REQUIREMENT","html":null,"origin":"extract"},"contacts":[{"name":"SSG Hernandez Emmanuel","role":"primary","email":"emmanuel.hernandezcasiano.mil@army.mil","phone":"7199522548"},{"name":"Julia Gomez","role":"secondary","email":"julia.e.gomez.civ@mail.mil"}],"place_of_performance":{"zip":"80913","city":{"name":"Colorado Springs"},"state":{"code":"CO"},"country":{"code":"USA"}},"office_address":{"zip":"80913-5198","city":"FORT CARSON","state":"CO","country":"USA"},"naics_codes":["335910"],"award":null,"attachments":[],"awards":[],"related":[{"key":"PANMCC26P0000036706","latest_notice_id":"2942906e84ea44b2b8ed625217621c7c","title":"4/10 C CO Austere Care and EMT Training","solicitation_number":"PANMCC-26-P-0000_036706","notice_type":"r","first_type":"r","first_posted":"2025-12-19","last_posted":"2025-12-19","notices":2,"due_at":"2026-12-23T17:00:00Z","due_date":"2026-12-23","closes_at":"2026-12-23T17:00:00Z","awardable":true,"open":true,"dept_key":"d-021","dept_name":"DEPT OF DEFENSE","sub_key":"s-2100","sub_name":"DEPT OF THE ARMY","office_key":"o-W911RZ","office_name":"W6QM MICC-FT CARSON","naics":"611699","psc":"U099","set_aside":"SBA","state":"CO","county":"08041","county_name":"El Paso County","city":"0816000","city_name":"Colorado Springs","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z"}]}