{"canonical":"https://abierto.us/opportunities/n6449825r4009","key":"N6449825R4009","url":"https://abierto.us/opportunities/n6449825r4009","title":"NSWCPD Bldg 1000 – Substations Ventilation and DDC Monitoring","solicitation_number":"N64498-25-R-4009","notice_type":"a","open":false,"response_deadline":"2025-03-04T21:00:00Z","first_posted":"2024-11-12","last_posted":"2025-04-08","department":"DEPT OF DEFENSE","subagency":"DEPT OF THE NAVY","office":"NSWC PHILADELPHIA DIV","naics":"238210","psc":"Y1HB","set_aside":null,"place_state":"PA","place_county":"42101","place_county_name":"Philadelphia County","place_city":"4260000","place_city_name":"Philadelphia","winner":"RIGGS DISTLER & COMPANY, INC.","award_amount":"405910.00","publications":[{"notice_id":"ee9089adce084526a4c94c88b169344b","title":"NSWCPD Bldg 1000 – Substations Ventilation and DDC Monitoring","solicitation_number":"N64498-25-R-4009","notice_type":"p","base_type":"r","posted":"2024-11-12","posted_at":null,"due_at":"2024-11-27T21:00:00Z","due_date":"2024-11-27","cancelled":null,"archived":null,"archive_date":"2024-12-12","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/ee9089adce084526a4c94c88b169344b/view","enriched":false,"history":[]},{"notice_id":"eba3a268c999465f9fe694bc6330d3d3","title":"NSWCPD Bldg 1000 – Substations Ventilation and DDC Monitoring","solicitation_number":"N64498-25-R-4009","notice_type":"o","base_type":"p","posted":"2025-01-29","posted_at":null,"due_at":"2025-02-28T21:00:00Z","due_date":"2025-02-28","cancelled":null,"archived":null,"archive_date":"2025-03-15","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/eba3a268c999465f9fe694bc6330d3d3/view","enriched":false,"history":[]},{"notice_id":"319feeb98a36483ea18abd13da4b2091","title":"NSWCPD Bldg 1000 – Substations Ventilation and DDC Monitoring","solicitation_number":"N64498-25-R-4009","notice_type":"o","base_type":"o","posted":"2025-02-11","posted_at":null,"due_at":"2025-02-28T21:00:00Z","due_date":"2025-02-28","cancelled":null,"archived":null,"archive_date":"2025-03-15","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/319feeb98a36483ea18abd13da4b2091/view","enriched":false,"history":[]},{"notice_id":"589ea7ded37645fab8ce091755f548a0","title":"NSWCPD Bldg 1000 – Substations Ventilation and DDC Monitoring","solicitation_number":"N64498-25-R-4009","notice_type":"o","base_type":"o","posted":"2025-02-24","posted_at":null,"due_at":"2025-03-03T17:00:00Z","due_date":"2025-03-03","cancelled":null,"archived":null,"archive_date":"2025-03-18","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/589ea7ded37645fab8ce091755f548a0/view","enriched":false,"history":[]},{"notice_id":"fff59189387447c2bd645c2cc61e7142","title":"NSWCPD Bldg 1000 – Substations Ventilation and DDC Monitoring","solicitation_number":"N64498-25-R-4009","notice_type":"o","base_type":"o","posted":"2025-02-25","posted_at":null,"due_at":"2025-03-03T17:00:00Z","due_date":"2025-03-03","cancelled":null,"archived":null,"archive_date":"2025-03-18","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/fff59189387447c2bd645c2cc61e7142/view","enriched":false,"history":[]},{"notice_id":"93550709235b403dbcc27186c8a86455","title":"NSWCPD Bldg 1000 – Substations Ventilation and DDC Monitoring","solicitation_number":"N64498-25-R-4009","notice_type":"o","base_type":"o","posted":"2025-03-03","posted_at":null,"due_at":"2025-03-04T21:00:00Z","due_date":"2025-03-04","cancelled":null,"archived":null,"archive_date":"2025-03-19","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/93550709235b403dbcc27186c8a86455/view","enriched":false,"history":[]},{"notice_id":"f06c2fef7e4a4fe99dc8a9e649c9a583","title":"NSWCPD Bldg 1000 – Substations Ventilation and DDC Monitoring","solicitation_number":"N6449825C0004","notice_type":"a","base_type":"o","posted":"2025-04-08","posted_at":null,"due_at":null,"due_date":null,"cancelled":null,"archived":null,"archive_date":"2025-04-23","award_number":"N6449825C0004","awardee_name":"RIGGS DISTLER & COMPANY, INC. Cherry Hill","amount":"405910.00","link_sam":"https://sam.gov/workspace/contract/opp/f06c2fef7e4a4fe99dc8a9e649c9a583/view","enriched":false,"history":[]}],"latest_notice_id":"f06c2fef7e4a4fe99dc8a9e649c9a583","first_type":"p","notices":[{"dates":{"posted":"2024-11-12","response_deadline":{"raw":"2024-11-27T16:00:00-05:00","utc":"2024-11-27T21:00:00Z","date":"2024-11-27","time":"16:00:00","utc_offset_seconds":-18000}},"links":{"sam":"https://sam.gov/workspace/contract/opp/ee9089adce084526a4c94c88b169344b/view"},"naics":{"codes":["238210"],"primary":"238210"},"title":"NSWCPD Bldg 1000 – Substations Ventilation and DDC Monitoring","agency":{"office":{"code":"N64498","name":"NSWC PHILADELPHIA DIV"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"19112-1403","city":"PHILADELPHIA","state":"PA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-12-12","archive_type":"auto15"},"contacts":[{"name":"Rishi Mathur","role":"primary","email":"rishi.m.mathur.civ@us.navy.mil","phone":"215-600-9078"},{"name":"David Rhoads","role":"secondary","email":"david.a.rhoads8.civ@us.navy.mil","phone":"215-880-8424"}],"base_type":{"code":"r","label":"Sources Sought"},"notice_id":"ee9089adce084526a4c94c88b169344b","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T19:12:38.374141Z","row_sha256":"7c50b473e343055632becc0b04b3443760ec5a6d1db1e5cfe518a8d51c73fb6d","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T19:12:38.374141Z","first_seen_at":"2026-09-16T19:12:38.374141Z"},"description":{"text":"The Naval Surface Warfare Center, Philadelphia Division intends to initiate a Full and Open Request for Proposal (RFP) for the removal and replacement of substation, ventilation and DDC monitoring BLDG 1000 located in the Philadelphia Naval Business Center (PNBC), Philadelphia, PA 19112. The scope of work includes the installation of remote power meters at fourteen (14) electrical substations in Building 1000; and the integration of these power meters through BACnet/IP Ethernet to a Direct Digital Controls (DDC) Building Automation System. The scope of work also includes connecting one electric heater, one damper, and one exhaust far to this existing DDC system. Work shall be performed between 0700 to 1600 Monday through Friday unless otherwise specified. No work shall be performed outside of these hours or on Government holidays unless authorized by the NSWCPD TPOC and Contracting Officer in advance. Contract Completion Date (CCD) is 130 Days after Award. FAR Clause 52.228-1 Bid Guarantee will be included. Performance and Payment bonding is a requirement for this procurement and Liquidated Damages are applicable. The acquisition will be a negotiated, best-value procurement using the Contracting by Negotiation process prescribed in FAR 15.101-2. The source selection process will be based on a Lowest Price, Technically Acceptable (LPTA) evaluation. Narratives must clearly demonstrate acceptability in enough detail for the Government to understand whether the proposal meets or exceeds the minimum solicitation requirements. Detailed evaluation criteria will be included in the RFP package. Initial price proposals must be submitted along with initial technical proposal to the Contracting Officer in accordance with the requirements of the RFP. Offerors are advised that the Government intends to award a contract based on initial proposals received without discussions or any contact concerning the proposal received. Therefore, each proposal should contain the offeror's best terms. The Government reserves the right to hold discussions at its discretion. The Solicitation N6449825R4009 is expected to be issued on or about Mid-December 2024 with a closing date on or about Mid-January 2025. The official media of distribution for this RFP is at SAM.gov. Contractors may download the solicitation (including any attachments) and any amendments via the SAM.gov website on or after the issue date. It is the offeror's responsibility to monitor the SAM.gov website for any amendments. A site visit will be held and is strongly encouraged. Date/time will be available in the solicitation. All contractors are required to be registered in the System for Award Management (SAM) before award as required by FAR 4.1102. Firms are required by legislation to submit an annual VETS-4212 Report on your employment of targeted veterans. Information on submitting your report may be obtained by accessing the following internet web site: https://www.dol.gov/agencies/vets/programs/vets4212#howtofile","origin":"extract"},"notice_type":{"code":"p","label":"Presolicitation"},"schema_version":1,"solicitation_number":"N64498-25-R-4009","place_of_performance":{"city":{"name":"Philadelphia"},"state":{"code":"PA"},"country":{"code":"USA"}},"product_service_code":"Y1HB"},{"dates":{"posted":"2025-01-29","response_deadline":{"raw":"2025-02-28T16:00:00-05:00","utc":"2025-02-28T21:00:00Z","date":"2025-02-28","time":"16:00:00","utc_offset_seconds":-18000}},"links":{"sam":"https://sam.gov/workspace/contract/opp/eba3a268c999465f9fe694bc6330d3d3/view"},"naics":{"codes":["238210"],"primary":"238210"},"title":"NSWCPD Bldg 1000 – Substations Ventilation and DDC Monitoring","agency":{"office":{"code":"N64498","name":"NSWC PHILADELPHIA DIV"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"19112-1403","city":"PHILADELPHIA","state":"PA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-03-15","archive_type":"auto15"},"contacts":[{"name":"Rishi Mathur","role":"primary","email":"rishi.m.mathur.civ@us.navy.mil","phone":"215-600-9078"},{"name":"David Rhoads","role":"secondary","email":"david.a.rhoads8.civ@us.navy.mil","phone":"215-880-8424"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"eba3a268c999465f9fe694bc6330d3d3","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"36845452b1b803634e4e2b3bb625502033c9324732b34cf53a8b57f1ec799058","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"The Naval Surface Warfare Center, Philadelphia Division is initiating a Full and Open Request for Proposal (RFP) for the removal and replacement of substation, ventilation and DOC monitoring BLDG 1000 located in the Philadelphia Naval Business Center (PNBC), Philadelphia, PA 19112. The scope of work includes the installation of remote power meters at fourteen (14) electrical substations in Building 1000; and the integration of these power meters through BACnet/lP Ethernet to a Direct Digital Controls (DOC) Building Automation System. The scope of work also includes connecting one electric heater, one damper, and one exhaust far to this existing DOC system. Contract Completion Date (CCD) is 290 Days after Award. FAR Clause 52.228-1 Bid Guarantee will be included. Performance and Payment bonding is a requirement for this procurement and Liquidated Damages are applicable. The acquisition will be a negotiated, best-value procurement using the Contracting by Negotiation process prescribed in FAR 15.101-2. The source selection process will be based on a Lowest Price, Technically Acceptable (LPTA) evaluation. Narratives must clearly demonstrate acceptability in enough detail for the Government to understand whether the proposal meets or exceeds the minimum solicitation requirements. Detailed evaluation criteria will be included in the RFP package. Initial price proposals must be submitted along with initial technical proposal to the Contracting Officer in accordance with the requirements of the RFP. Offerers are advised that the Government intends to award a contract based on initial proposals received without discussions or any contact concerning the proposal received. Therefore, each proposal should contain the offerer's best terms. The Government reserves the right to hold discussions at its discretion. The official media of distribution for this RFP is at SAM.gov. Contractors may download the solicitation (including any attachments) and any amendments via the SAM.gov website on or after the issue date. It is the offerer's responsibility to monitor the SAM.gov website for any amendments. A site visit will be held and is strongly encouraged. Date/time is available in the solicitation. All contractors are required to be registered in the System for Award Management (SAM) before award as required by FAR 4.1102. Firms are required by legislation to submit an annual VETS-4212 Report on your employment of targeted veterans. Information on submitting your report may be obtained by accessing the following internet web site: https://www.doI.gov/agencies/vets/progra ms/vets4212#howtofile","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"N64498-25-R-4009","place_of_performance":{"city":{"name":"Philadelphia"},"state":{"code":"PA"},"country":{"code":"USA"}},"product_service_code":"Y1HB"},{"dates":{"posted":"2025-02-11","response_deadline":{"raw":"2025-02-28T16:00:00-05:00","utc":"2025-02-28T21:00:00Z","date":"2025-02-28","time":"16:00:00","utc_offset_seconds":-18000}},"links":{"sam":"https://sam.gov/workspace/contract/opp/319feeb98a36483ea18abd13da4b2091/view"},"naics":{"codes":["238210"],"primary":"238210"},"title":"NSWCPD Bldg 1000 – Substations Ventilation and DDC Monitoring","agency":{"office":{"code":"N64498","name":"NSWC PHILADELPHIA DIV"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"19112-1403","city":"PHILADELPHIA","state":"PA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-03-15","archive_type":"auto15"},"contacts":[{"name":"Rishi Mathur","role":"primary","email":"rishi.m.mathur.civ@us.navy.mil","phone":"215-600-9078"},{"name":"David Rhoads","role":"secondary","email":"david.a.rhoads8.civ@us.navy.mil","phone":"215-880-8424"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"319feeb98a36483ea18abd13da4b2091","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"3884539365a951aa81e39de146d1612f54efe950013f62f3f55d9eb30ba1997b","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"The Naval Surface Warfare Center, Philadelphia Division is initiating a Full and Open Request for Proposal (RFP) for the removal and replacement of substation, ventilation and DOC monitoring BLDG 1000 located in the Philadelphia Naval Business Center (PNBC), Philadelphia, PA 19112. The scope of work includes the installation of remote power meters at fourteen (14) electrical substations in Building 1000; and the integration of these power meters through BACnet/lP Ethernet to a Direct Digital Controls (DOC) Building Automation System. The scope of work also includes connecting one electric heater, one damper, and one exhaust far to this existing DOC system. Contract Completion Date (CCD) is 290 Days after Award. FAR Clause 52.228-1 Bid Guarantee will be included. Performance and Payment bonding is a requirement for this procurement and Liquidated Damages are applicable. The acquisition will be a negotiated, best-value procurement using the Contracting by Negotiation process prescribed in FAR 15.101-2. The source selection process will be based on a Lowest Price, Technically Acceptable (LPTA) evaluation. Narratives must clearly demonstrate acceptability in enough detail for the Government to understand whether the proposal meets or exceeds the minimum solicitation requirements. Detailed evaluation criteria will be included in the RFP package. Initial price proposals must be submitted along with initial technical proposal to the Contracting Officer in accordance with the requirements of the RFP. Offerers are advised that the Government intends to award a contract based on initial proposals received without discussions or any contact concerning the proposal received. Therefore, each proposal should contain the offerer's best terms. The Government reserves the right to hold discussions at its discretion. The official media of distribution for this RFP is at SAM.gov. Contractors may download the solicitation (including any attachments) and any amendments via the SAM.gov website on or after the issue date. It is the offerer's responsibility to monitor the SAM.gov website for any amendments. A site visit will be held and is strongly encouraged. Date/time is available in the solicitation. All contractors are required to be registered in the System for Award Management (SAM) before award as required by FAR 4.1102. Firms are required by legislation to submit an annual VETS-4212 Report on your employment of targeted veterans. Information on submitting your report may be obtained by accessing the following internet web site: https://www.doI.gov/agencies/vets/progra ms/vets4212#howtofile **Update** Please see amendment 0001 attached","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"N64498-25-R-4009","place_of_performance":{"city":{"name":"Philadelphia"},"state":{"code":"PA"},"country":{"code":"USA"}},"product_service_code":"Y1HB"},{"dates":{"posted":"2025-02-24","response_deadline":{"raw":"2025-03-03T12:00:00-05:00","utc":"2025-03-03T17:00:00Z","date":"2025-03-03","time":"12:00:00","utc_offset_seconds":-18000}},"links":{"sam":"https://sam.gov/workspace/contract/opp/589ea7ded37645fab8ce091755f548a0/view"},"naics":{"codes":["238210"],"primary":"238210"},"title":"NSWCPD Bldg 1000 – Substations Ventilation and DDC Monitoring","agency":{"office":{"code":"N64498","name":"NSWC PHILADELPHIA DIV"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"19112-1403","city":"PHILADELPHIA","state":"PA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-03-18","archive_type":"auto15"},"contacts":[{"name":"Rishi Mathur","role":"primary","email":"rishi.m.mathur.civ@us.navy.mil","phone":"215-600-9078"},{"name":"David Rhoads","role":"secondary","email":"david.a.rhoads8.civ@us.navy.mil","phone":"215-880-8424"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"589ea7ded37645fab8ce091755f548a0","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"c04570a43dee404d959c9e9ef17d967f5a43abad4a4a1a72fc75eb1fa78150d6","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"The Naval Surface Warfare Center, Philadelphia Division is initiating a Full and Open Request for Proposal (RFP) for the removal and replacement of substation, ventilation and DOC monitoring BLDG 1000 located in the Philadelphia Naval Business Center (PNBC), Philadelphia, PA 19112. The scope of work includes the installation of remote power meters at fourteen (14) electrical substations in Building 1000; and the integration of these power meters through BACnet/lP Ethernet to a Direct Digital Controls (DOC) Building Automation System. The scope of work also includes connecting one electric heater, one damper, and one exhaust far to this existing DOC system. Contract Completion Date (CCD) is 290 Days after Award. FAR Clause 52.228-1 Bid Guarantee will be included. Performance and Payment bonding is a requirement for this procurement and Liquidated Damages are applicable. The acquisition will be a negotiated, best-value procurement using the Contracting by Negotiation process prescribed in FAR 15.101-2. The source selection process will be based on a Lowest Price, Technically Acceptable (LPTA) evaluation. Narratives must clearly demonstrate acceptability in enough detail for the Government to understand whether the proposal meets or exceeds the minimum solicitation requirements. Detailed evaluation criteria will be included in the RFP package. Initial price proposals must be submitted along with initial technical proposal to the Contracting Officer in accordance with the requirements of the RFP. Offerers are advised that the Government intends to award a contract based on initial proposals received without discussions or any contact concerning the proposal received. Therefore, each proposal should contain the offerer's best terms. The Government reserves the right to hold discussions at its discretion. The official media of distribution for this RFP is at SAM.gov. Contractors may download the solicitation (including any attachments) and any amendments via the SAM.gov website on or after the issue date. It is the offerer's responsibility to monitor the SAM.gov website for any amendments. A site visit will be held and is strongly encouraged. Date/time is available in the solicitation. All contractors are required to be registered in the System for Award Management (SAM) before award as required by FAR 4.1102. Firms are required by legislation to submit an annual VETS-4212 Report on your employment of targeted veterans. Information on submitting your report may be obtained by accessing the following internet web site: https://www.doI.gov/agencies/vets/progra ms/vets4212#howtofile **Update** Please see amendment 0001 attached Please see amendment 0002 attached","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"N64498-25-R-4009","place_of_performance":{"city":{"name":"Philadelphia"},"state":{"code":"PA"},"country":{"code":"USA"}},"product_service_code":"Y1HB"},{"dates":{"posted":"2025-02-25","response_deadline":{"raw":"2025-03-03T12:00:00-05:00","utc":"2025-03-03T17:00:00Z","date":"2025-03-03","time":"12:00:00","utc_offset_seconds":-18000}},"links":{"sam":"https://sam.gov/workspace/contract/opp/fff59189387447c2bd645c2cc61e7142/view"},"naics":{"codes":["238210"],"primary":"238210"},"title":"NSWCPD Bldg 1000 – Substations Ventilation and DDC Monitoring","agency":{"office":{"code":"N64498","name":"NSWC PHILADELPHIA DIV"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"19112-1403","city":"PHILADELPHIA","state":"PA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-03-18","archive_type":"auto15"},"contacts":[{"name":"Rishi Mathur","role":"primary","email":"rishi.m.mathur.civ@us.navy.mil","phone":"215-600-9078"},{"name":"David Rhoads","role":"secondary","email":"david.a.rhoads8.civ@us.navy.mil","phone":"215-880-8424"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"fff59189387447c2bd645c2cc61e7142","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"25532a9655c0f17a36b3a36cef7a3a799700cd2b7695559d7b4d1584b87edbc4","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"The Naval Surface Warfare Center, Philadelphia Division is initiating a Full and Open Request for Proposal (RFP) for the removal and replacement of substation, ventilation and DOC monitoring BLDG 1000 located in the Philadelphia Naval Business Center (PNBC), Philadelphia, PA 19112. The scope of work includes the installation of remote power meters at fourteen (14) electrical substations in Building 1000; and the integration of these power meters through BACnet/lP Ethernet to a Direct Digital Controls (DOC) Building Automation System. The scope of work also includes connecting one electric heater, one damper, and one exhaust far to this existing DOC system. Contract Completion Date (CCD) is 290 Days after Award. FAR Clause 52.228-1 Bid Guarantee will be included. Performance and Payment bonding is a requirement for this procurement and Liquidated Damages are applicable. The acquisition will be a negotiated, best-value procurement using the Contracting by Negotiation process prescribed in FAR 15.101-2. The source selection process will be based on a Lowest Price, Technically Acceptable (LPTA) evaluation. Narratives must clearly demonstrate acceptability in enough detail for the Government to understand whether the proposal meets or exceeds the minimum solicitation requirements. Detailed evaluation criteria will be included in the RFP package. Initial price proposals must be submitted along with initial technical proposal to the Contracting Officer in accordance with the requirements of the RFP. Offerers are advised that the Government intends to award a contract based on initial proposals received without discussions or any contact concerning the proposal received. Therefore, each proposal should contain the offerer's best terms. The Government reserves the right to hold discussions at its discretion. The official media of distribution for this RFP is at SAM.gov. Contractors may download the solicitation (including any attachments) and any amendments via the SAM.gov website on or after the issue date. It is the offerer's responsibility to monitor the SAM.gov website for any amendments. A site visit will be held and is strongly encouraged. Date/time is available in the solicitation. All contractors are required to be registered in the System for Award Management (SAM) before award as required by FAR 4.1102. Firms are required by legislation to submit an annual VETS-4212 Report on your employment of targeted veterans. Information on submitting your report may be obtained by accessing the following internet web site: https://www.doI.gov/agencies/vets/progra ms/vets4212#howtofile **Update** Please see amendment 0001 attached Please see amendment 0002 attached Please see amendment 0003 attached","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"N64498-25-R-4009","place_of_performance":{"city":{"name":"Philadelphia"},"state":{"code":"PA"},"country":{"code":"USA"}},"product_service_code":"Y1HB"},{"dates":{"posted":"2025-03-03","response_deadline":{"raw":"2025-03-04T16:00:00-05:00","utc":"2025-03-04T21:00:00Z","date":"2025-03-04","time":"16:00:00","utc_offset_seconds":-18000}},"links":{"sam":"https://sam.gov/workspace/contract/opp/93550709235b403dbcc27186c8a86455/view"},"naics":{"codes":["238210"],"primary":"238210"},"title":"NSWCPD Bldg 1000 – Substations Ventilation and DDC Monitoring","agency":{"office":{"code":"N64498","name":"NSWC PHILADELPHIA DIV"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"19112-1403","city":"PHILADELPHIA","state":"PA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-03-19","archive_type":"auto15"},"contacts":[{"name":"Rishi Mathur","role":"primary","email":"rishi.m.mathur.civ@us.navy.mil","phone":"215-600-9078"},{"name":"David Rhoads","role":"secondary","email":"david.a.rhoads8.civ@us.navy.mil","phone":"215-880-8424"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"93550709235b403dbcc27186c8a86455","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"f670d23ee1ab184409a1e1fdf1978e14f4b1601acfb9a7aad7f68f8094213c98","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"The Naval Surface Warfare Center, Philadelphia Division is initiating a Full and Open Request for Proposal (RFP) for the removal and replacement of substation, ventilation and DOC monitoring BLDG 1000 located in the Philadelphia Naval Business Center (PNBC), Philadelphia, PA 19112. The scope of work includes the installation of remote power meters at fourteen (14) electrical substations in Building 1000; and the integration of these power meters through BACnet/lP Ethernet to a Direct Digital Controls (DOC) Building Automation System. The scope of work also includes connecting one electric heater, one damper, and one exhaust far to this existing DOC system. Contract Completion Date (CCD) is 290 Days after Award. FAR Clause 52.228-1 Bid Guarantee will be included. Performance and Payment bonding is a requirement for this procurement and Liquidated Damages are applicable. The acquisition will be a negotiated, best-value procurement using the Contracting by Negotiation process prescribed in FAR 15.101-2. The source selection process will be based on a Lowest Price, Technically Acceptable (LPTA) evaluation. Narratives must clearly demonstrate acceptability in enough detail for the Government to understand whether the proposal meets or exceeds the minimum solicitation requirements. Detailed evaluation criteria will be included in the RFP package. Initial price proposals must be submitted along with initial technical proposal to the Contracting Officer in accordance with the requirements of the RFP. Offerers are advised that the Government intends to award a contract based on initial proposals received without discussions or any contact concerning the proposal received. Therefore, each proposal should contain the offerer's best terms. The Government reserves the right to hold discussions at its discretion. The official media of distribution for this RFP is at SAM.gov. Contractors may download the solicitation (including any attachments) and any amendments via the SAM.gov website on or after the issue date. It is the offerer's responsibility to monitor the SAM.gov website for any amendments. A site visit will be held and is strongly encouraged. Date/time is available in the solicitation. All contractors are required to be registered in the System for Award Management (SAM) before award as required by FAR 4.1102. Firms are required by legislation to submit an annual VETS-4212 Report on your employment of targeted veterans. Information on submitting your report may be obtained by accessing the following internet web site: https://www.doI.gov/agencies/vets/progra ms/vets4212#howtofile **Update** Please see amendment 0001 attached Please see amendment 0002 attached Please see amendment 0003 attached Please see amendment 0004 attached","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"N64498-25-R-4009","place_of_performance":{"city":{"name":"Philadelphia"},"state":{"code":"PA"},"country":{"code":"USA"}},"product_service_code":"Y1HB"},{"award":{"date":"2025-04-08","amount":"405910.00","number":"N6449825C0004","awardee":{"raw":"RIGGS DISTLER & COMPANY, INC. Cherry Hill NJ 08003 USA","name":"RIGGS DISTLER & COMPANY, INC. Cherry Hill","location":{"zip":"08003","state":{"code":"NJ"},"country":{"code":"USA"}}}},"dates":{"posted":"2025-04-08","award_date":"2025-04-08"},"links":{"sam":"https://sam.gov/workspace/contract/opp/f06c2fef7e4a4fe99dc8a9e649c9a583/view"},"naics":{"codes":["238210"],"primary":"238210"},"title":"NSWCPD Bldg 1000 – Substations Ventilation and DDC Monitoring","agency":{"office":{"code":"N64498","name":"NSWC PHILADELPHIA DIV"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"19112-1403","city":"PHILADELPHIA","state":"PA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-04-23","archive_type":"auto15"},"contacts":[{"name":"Rishi Mathur","role":"primary","email":"rishi.m.mathur.civ@us.navy.mil","phone":"215-600-9078"},{"name":"David Rhoads","role":"secondary","email":"david.a.rhoads8.civ@us.navy.mil","phone":"215-880-8424"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"f06c2fef7e4a4fe99dc8a9e649c9a583","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"9dca8ac38f04824cc12ed98678aed5f0024aac8e199cc5cdfb7bc09892f076a5","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"notice_type":{"code":"a","label":"Award Notice"},"schema_version":1,"solicitation_number":"N6449825C0004","place_of_performance":{"zip":"19112","city":{"name":"Philadelphia"},"state":{"code":"PA"},"country":{"code":"USA"}},"product_service_code":"Y1HB"}],"due_at":"2025-03-04T21:00:00Z","due_date":"2025-03-04","closes_at":"2025-03-04T21:00:00Z","awardable":false,"dept_key":"d-017","dept_name":"DEPT OF DEFENSE","sub_key":"s-1700","sub_name":"DEPT OF THE NAVY","office_key":"o-N64498","office_name":"NSWC PHILADELPHIA DIV","state":"PA","county":"42101","county_name":"Philadelphia County","city":"4260000","city_name":"Philadelphia","country":"USA","winner_key":"KNJ1EQ8L47U3","amount":"405910.00","linked_awards":7,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z","principal_notice_id":"93550709235b403dbcc27186c8a86455","description":{"text":"The Naval Surface Warfare Center, Philadelphia Division is initiating a Full and Open Request for Proposal (RFP) for the removal and replacement of substation, ventilation and DOC monitoring BLDG 1000 located in the Philadelphia Naval Business Center (PNBC), Philadelphia, PA 19112. The scope of work includes the installation of remote power meters at fourteen (14) electrical substations in Building 1000; and the integration of these power meters through BACnet/lP Ethernet to a Direct Digital Controls (DOC) Building Automation System. The scope of work also includes connecting one electric heater, one damper, and one exhaust far to this existing DOC system. Contract Completion Date (CCD) is 290 Days after Award. FAR Clause 52.228-1 Bid Guarantee will be included. Performance and Payment bonding is a requirement for this procurement and Liquidated Damages are applicable. The acquisition will be a negotiated, best-value procurement using the Contracting by Negotiation process prescribed in FAR 15.101-2. The source selection process will be based on a Lowest Price, Technically Acceptable (LPTA) evaluation. Narratives must clearly demonstrate acceptability in enough detail for the Government to understand whether the proposal meets or exceeds the minimum solicitation requirements. Detailed evaluation criteria will be included in the RFP package. Initial price proposals must be submitted along with initial technical proposal to the Contracting Officer in accordance with the requirements of the RFP. Offerers are advised that the Government intends to award a contract based on initial proposals received without discussions or any contact concerning the proposal received. Therefore, each proposal should contain the offerer's best terms. The Government reserves the right to hold discussions at its discretion. The official media of distribution for this RFP is at SAM.gov. Contractors may download the solicitation (including any attachments) and any amendments via the SAM.gov website on or after the issue date. It is the offerer's responsibility to monitor the SAM.gov website for any amendments. A site visit will be held and is strongly encouraged. Date/time is available in the solicitation. All contractors are required to be registered in the System for Award Management (SAM) before award as required by FAR 4.1102. Firms are required by legislation to submit an annual VETS-4212 Report on your employment of targeted veterans. Information on submitting your report may be obtained by accessing the following internet web site: https://www.doI.gov/agencies/vets/progra ms/vets4212#howtofile **Update** Please see amendment 0001 attached Please see amendment 0002 attached Please see amendment 0003 attached Please see amendment 0004 attached","html":null,"origin":"extract"},"contacts":[{"name":"Rishi Mathur","role":"primary","email":"rishi.m.mathur.civ@us.navy.mil","phone":"215-600-9078"},{"name":"David Rhoads","role":"secondary","email":"david.a.rhoads8.civ@us.navy.mil","phone":"215-880-8424"}],"place_of_performance":{"city":{"name":"Philadelphia"},"state":{"code":"PA"},"country":{"code":"USA"}},"office_address":{"zip":"19112-1403","city":"PHILADELPHIA","state":"PA","country":"USA"},"naics_codes":["238210"],"award":null,"attachments":[],"awards":[{"award_key":"CONT_AWD_N6449825C0004_9700_-NONE-_-NONE-","permalink":"https://www.usaspending.gov/award/CONT_AWD_N6449825C0004_9700_-NONE-_-NONE-/","piid":"N6449825C0004","parent_piid":null,"award_type":"DEFINITIVE CONTRACT","vendor_key":"KNJ1EQ8L47U3","recipient_name":"RIGGS DISTLER & COMPANY, INC.","recipient_uei":"KNJ1EQ8L47U3","recipient_cage":"3SMZ2","recipient_city":"CHERRY HILL","recipient_state":"NJ","sub_name":"Department of the Navy","office_name":"NSWC PHILADELPHIA DIV","office_key":"o-N64498","first_action_date":"2025-04-08","last_action_date":"2026-01-23","actions":3,"obligated":"405910.00","current_total_value":"405910.00","potential_total_value":"405910.00","naics":"238210","psc":"Y1HB","extent_competed":"FULL AND OPEN COMPETITION","set_aside":"NO SET ASIDE USED.","offers_received":2,"description":"POWER METER INSTALLATION FOURTEEN SUBSTATIONS","method":"piid","confidence":"high","evidence":["award number N6449825C0004 equals the contract number","same awarding office N64498"],"opportunity_key":null,"opportunity_title":null}],"related":[{"key":"26VMRLPDMIDLIFE","latest_notice_id":"b8d99e53dd754742a4ee9d236f870051","title":"LPD 17 Electrical Plant Control Midlife Upgrade","solicitation_number":"26-VMR-LPDMidlife","notice_type":"k","first_type":"k","first_posted":"2026-09-14","last_posted":"2026-09-14","notices":1,"due_at":"2026-09-21T16:00:00Z","due_date":"2026-09-21","closes_at":"2026-09-21T16:00:00Z","awardable":true,"open":true,"dept_key":"d-017","dept_name":"DEPT OF DEFENSE","sub_key":"s-1700","sub_name":"DEPT OF THE NAVY","office_key":"o-N64498","office_name":"NSWC PHILADELPHIA DIV","naics":"541330","psc":"R425","set_aside":null,"state":"PA","county":"42101","county_name":"Philadelphia County","city":"4260000","city_name":"Philadelphia","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z"},{"key":"N6449826RFPREQPD600002","latest_notice_id":"d49030209d3e4e6f827c897e832ddd9d","title":"60-0002 Installation, Outfitting and Integration Support","solicitation_number":"N64498-26-RFPREQ-PD-60-0002","notice_type":"r","first_type":"r","first_posted":"2025-09-08","last_posted":"2026-09-14","notices":2,"due_at":"2026-09-21T19:00:00Z","due_date":"2026-09-21","closes_at":"2026-09-21T19:00:00Z","awardable":true,"open":true,"dept_key":"d-017","dept_name":"DEPT OF DEFENSE","sub_key":"s-1700","sub_name":"DEPT OF THE NAVY","office_key":"o-N64498","office_name":"NSWC PHILADELPHIA DIV","naics":"561210","psc":"H220","set_aside":null,"state":"PA","county":"42101","county_name":"Philadelphia County","city":"4260000","city_name":"Philadelphia","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z"},{"key":"N6449826SIMACQPD600099","latest_notice_id":"d291767e38104c3db9ea6afb6aabe494","title":"PD-60-0099; AVDB Dell Server Tech Refresh","solicitation_number":"N64498-26-SIMACQ-PD-60-0099","notice_type":"r","first_type":"r","first_posted":"2026-09-15","last_posted":"2026-09-15","notices":1,"due_at":"2026-09-21T22:00:00Z","due_date":"2026-09-21","closes_at":"2026-09-21T22:00:00Z","awardable":true,"open":true,"dept_key":"d-017","dept_name":"DEPT OF DEFENSE","sub_key":"s-1700","sub_name":"DEPT OF THE NAVY","office_key":"o-N64498","office_name":"NSWC PHILADELPHIA DIV","naics":"334111","psc":"7H20","set_aside":null,"state":"PA","county":"42101","county_name":"Philadelphia County","city":"4260000","city_name":"Philadelphia","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z"},{"key":"PD330128","latest_notice_id":"f9b4af7ae8634eae88e7f30b21ff81cd","title":"Mixed Solid Waste Processing Machine","solicitation_number":"PD-33-0128","notice_type":"p","first_type":"p","first_posted":"2026-09-15","last_posted":"2026-09-15","notices":1,"due_at":"2026-09-22T16:00:00Z","due_date":"2026-09-22","closes_at":"2026-09-22T16:00:00Z","awardable":true,"open":true,"dept_key":"d-017","dept_name":"DEPT OF DEFENSE","sub_key":"s-1700","sub_name":"DEPT OF THE NAVY","office_key":"o-N64498","office_name":"NSWC PHILADELPHIA DIV","naics":"562111","psc":"4540","set_aside":null,"state":"PA","county":"42101","county_name":"Philadelphia County","city":"4260000","city_name":"Philadelphia","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z"},{"key":"N6449826Q0056","latest_notice_id":"b000402f6a544482b0701625db85e89b","title":"Pickering module and 32CH Thermocouple Simulator","solicitation_number":"N6449826Q0056","notice_type":"k","first_type":"k","first_posted":"2026-09-17","last_posted":"2026-09-17","notices":1,"due_at":"2026-09-23T16:00:00Z","due_date":"2026-09-23","closes_at":"2026-09-23T16:00:00Z","awardable":true,"open":true,"dept_key":"d-017","dept_name":"DEPT OF DEFENSE","sub_key":"s-1700","sub_name":"DEPT OF THE NAVY","office_key":"o-N64498","office_name":"NSWC PHILADELPHIA DIV","naics":"334111","psc":"5963","set_aside":null,"state":null,"county":null,"county_name":null,"city":null,"city_name":null,"country":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-18T04:00:44.545196Z"}]}