{"canonical":"https://abierto.us/opportunities/n4008425r0066","key":"N4008425R0066","url":"https://abierto.us/opportunities/n4008425r0066","title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","solicitation_number":"N4008425R0066","notice_type":"a","open":false,"response_deadline":"2025-04-18T05:30:00Z","first_posted":"2025-02-07","last_posted":"2025-09-23","department":"DEPT OF DEFENSE","subagency":"DEPT OF THE NAVY","office":"NAVFACSYSCOM FAR EAST","naics":"236220","psc":"Z2JZ","set_aside":null,"place_state":null,"place_county":null,"place_county_name":null,"place_city":null,"place_city_name":null,"winner":"KANAGAWA NABCO PTY. LTD.","award_amount":"99000000.00","publications":[{"notice_id":"1ecb8fe753894822acbc97f4c9ef2af5","title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","solicitation_number":"N4008425R0066","notice_type":"p","base_type":"p","posted":"2025-02-07","posted_at":null,"due_at":"2025-02-21T23:30:00Z","due_date":"2025-02-21","cancelled":null,"archived":null,"archive_date":"2026-02-07","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/1ecb8fe753894822acbc97f4c9ef2af5/view","enriched":false,"history":[]},{"notice_id":"5a3eeabc3fce4fb0ab8796242150df55","title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","solicitation_number":"N4008425R0066","notice_type":"p","base_type":"p","posted":"2025-02-07","posted_at":null,"due_at":"2025-02-21T23:30:00Z","due_date":"2025-02-21","cancelled":null,"archived":null,"archive_date":"2026-02-07","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/5a3eeabc3fce4fb0ab8796242150df55/view","enriched":false,"history":[]},{"notice_id":"282290bb11e7452fa2fbc00dea9c5dfd","title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","solicitation_number":"N4008425R0066","notice_type":"p","base_type":"p","posted":"2025-02-09","posted_at":null,"due_at":"2025-02-21T23:30:00Z","due_date":"2025-02-21","cancelled":null,"archived":null,"archive_date":"2026-02-07","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/282290bb11e7452fa2fbc00dea9c5dfd/view","enriched":false,"history":[]},{"notice_id":"46f81c7e0ef44c5eb02167fc8052d6d1","title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","solicitation_number":"N4008425R0066","notice_type":"o","base_type":"o","posted":"2025-02-28","posted_at":null,"due_at":"2025-04-18T05:30:00Z","due_date":"2025-04-18","cancelled":null,"archived":null,"archive_date":"2026-02-28","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/46f81c7e0ef44c5eb02167fc8052d6d1/view","enriched":false,"history":[]},{"notice_id":"87bb17a6c9c14fa1bfee761b87c6a806","title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","solicitation_number":"N4008425R0066","notice_type":"o","base_type":"p","posted":"2025-02-28","posted_at":null,"due_at":"2025-04-18T05:30:00Z","due_date":"2025-04-18","cancelled":null,"archived":null,"archive_date":"2026-02-28","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/87bb17a6c9c14fa1bfee761b87c6a806/view","enriched":false,"history":[]},{"notice_id":"70ff9237bf41471bba5e52c4448ba6a6","title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","solicitation_number":"N4008425R0066","notice_type":"o","base_type":"o","posted":"2025-03-04","posted_at":null,"due_at":"2025-04-18T05:30:00Z","due_date":"2025-04-18","cancelled":null,"archived":null,"archive_date":"2026-03-05","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/70ff9237bf41471bba5e52c4448ba6a6/view","enriched":false,"history":[]},{"notice_id":"7ed99ab94b5c4b09ac1e032ddccef542","title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","solicitation_number":"N4008425R0066","notice_type":"o","base_type":"o","posted":"2025-03-04","posted_at":null,"due_at":"2025-04-18T05:30:00Z","due_date":"2025-04-18","cancelled":null,"archived":null,"archive_date":"2026-03-05","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/7ed99ab94b5c4b09ac1e032ddccef542/view","enriched":false,"history":[]},{"notice_id":"7a4f8a20498e4595b0f3f8b03ae22c7d","title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","solicitation_number":"N4008425R0066","notice_type":"o","base_type":"o","posted":"2025-03-21","posted_at":null,"due_at":"2025-04-18T05:30:00Z","due_date":"2025-04-18","cancelled":null,"archived":null,"archive_date":"2026-03-21","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/7a4f8a20498e4595b0f3f8b03ae22c7d/view","enriched":false,"history":[]},{"notice_id":"8d4630317f6f4cc6b36fef218ef98056","title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","solicitation_number":"N4008425R0066","notice_type":"o","base_type":"o","posted":"2025-03-21","posted_at":null,"due_at":"2025-04-18T05:30:00Z","due_date":"2025-04-18","cancelled":null,"archived":null,"archive_date":"2026-03-21","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/8d4630317f6f4cc6b36fef218ef98056/view","enriched":false,"history":[]},{"notice_id":"690c657c67dd4afebf6d952fb22b5249","title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","solicitation_number":"N4008425R0066","notice_type":"o","base_type":"o","posted":"2025-03-25","posted_at":null,"due_at":"2025-04-18T05:30:00Z","due_date":"2025-04-18","cancelled":null,"archived":null,"archive_date":"2026-03-21","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/690c657c67dd4afebf6d952fb22b5249/view","enriched":false,"history":[]},{"notice_id":"2daaa2a4381947be968d0b67eeb06c21","title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","solicitation_number":"N4008425R0066","notice_type":"o","base_type":"o","posted":"2025-04-10","posted_at":null,"due_at":"2025-04-18T05:30:00Z","due_date":"2025-04-18","cancelled":null,"archived":null,"archive_date":"2026-04-10","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/2daaa2a4381947be968d0b67eeb06c21/view","enriched":false,"history":[]},{"notice_id":"bf5655b2ed954fd5b10f2d5e9841aa16","title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","solicitation_number":"N4008425R0066","notice_type":"o","base_type":"o","posted":"2025-04-10","posted_at":null,"due_at":"2025-04-18T05:30:00Z","due_date":"2025-04-18","cancelled":null,"archived":null,"archive_date":"2026-04-10","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/bf5655b2ed954fd5b10f2d5e9841aa16/view","enriched":false,"history":[]},{"notice_id":"0ee6436392c24d968c738e027eee7fcd","title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","solicitation_number":"N4008425R0066","notice_type":"o","base_type":"o","posted":"2025-04-14","posted_at":null,"due_at":"2025-04-18T05:30:00Z","due_date":"2025-04-18","cancelled":null,"archived":null,"archive_date":"2026-04-15","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/0ee6436392c24d968c738e027eee7fcd/view","enriched":false,"history":[]},{"notice_id":"840c7dc2309049b8bb17248cfc42ea21","title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","solicitation_number":"N4008425R0066","notice_type":"o","base_type":"o","posted":"2025-04-15","posted_at":null,"due_at":"2025-04-18T05:30:00Z","due_date":"2025-04-18","cancelled":null,"archived":null,"archive_date":"2026-04-15","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/840c7dc2309049b8bb17248cfc42ea21/view","enriched":false,"history":[]},{"notice_id":"6ff43590ab724b8e9829d957c92bdf54","title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","solicitation_number":"N4008425R0066","notice_type":"a","base_type":"o","posted":"2025-09-23","posted_at":null,"due_at":null,"due_date":null,"cancelled":null,"archived":null,"archive_date":"2025-10-04","award_number":"N4008425D0066-N4008425D0069","awardee_name":"KANAGAWA NABCO PTY. LTD. Yokohama-shi JPN","amount":"99000000.00","link_sam":"https://sam.gov/workspace/contract/opp/6ff43590ab724b8e9829d957c92bdf54/view","enriched":false,"history":[]}],"latest_notice_id":"6ff43590ab724b8e9829d957c92bdf54","first_type":"p","notices":[{"dates":{"posted":"2025-02-07","response_deadline":{"raw":"2025-02-21T14:30:00-09:00","utc":"2025-02-21T23:30:00Z","date":"2025-02-21","time":"14:30:00","utc_offset_seconds":-32400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/1ecb8fe753894822acbc97f4c9ef2af5/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","agency":{"office":{"code":"N40084","name":"NAVFACSYSCOM FAR EAST"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"96349-0013","city":"FPO","state":"AP","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-02-07","archive_type":"auto_custom"},"contacts":[{"name":"Emiko Uyama","role":"primary","email":"emiko.uyama2.ln@us.navy.mil","phone":"046-816-2874"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"1ecb8fe753894822acbc97f4c9ef2af5","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"d0ffdbae161be75c3c3717000fb89a152db14caa852317fe366590fb9a409eae","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"Pre-Solicitation Notice for Solicitation No. N4008425R0066 The Naval Facilities Engineering Systems Command, Far East (NAVFAC FE) is issuing this pre-solicitation notice in accordance with FAR 36.213-2.This pre-solicitation notice does NOT constitute a request for proposal, request for quote, or invitation for bid. This notice shall NOT be construed as a commitment by the Government for any purpose.Interested Offerors can view and/or download the solicitation from the Government-wide point of entry (GPE), currently the Solicitation Module in the Procurement Integrated Enterprise Environment (PIEE) website (https://piee.eb.mil/sol/xhtml/unauth/index.xhtml) and/or Contract Opportunities in the System for Award Management (SAM) website (https://sam.gov) when it becomes available on or about 25 Feb 2025.DESCRIPTION OF PROPOSED WORKThis acquisition is for an Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan; U.S. Marine Corps Combined Arms Training Center (CATC), Camp Fuji, Japan; and various locations in the Atsugi Area of Responsibility (AOR), Japan.The Contractor must furnish all labor, management, supervision, tools, materials, equipment, incidental engineering, and transportation, except otherwise specified in each task order necessary to perform the various projects.The proposed scope of work will be specified in each task order and may include, but is not limited to, facility repair/ renovation, demolition, built-in equipment repair/replacement, piping repair/replacement, pipe insulation, electrical work, mechanical work, road pavement, fencing roofing, painting, site work, utilities, removal and disposal of material containing lead paint with lead, cadmium, chromium (VI) and asbestos containing material, welding, and masonry.This requirement is anticipated to result in approximately five (5) Firm-Fixed-Price (FFP) IDIQ contract awards where the maximum aggregate value of all contracts will not exceed $99,000,000 or Japanese yen equivalent over an eight-year period, consisting of one four (4) year base period and one four (4) year option period, for a maximum duration of 96 months. The anticipated task orders will be FFP ranging from 300,000 JPY to 75,000,000 JPY. However, task orders under or over these amounts may be considered if it is determined to be in the Government?s best interest and approved by the Contracting Officer.Task orders for the minimum guarantee of 400,000 JPY / $2,744.76 (FY25 Budget Exchange Rate at 145.7323 JPY) each will be issued concurrently with the award of the basic contract for the Offerors awarded a MACC, but not awarded the seed project. Only the base period of the contract will offer a minimum guarantee.There will be one (1) Design-Bid-Build seed project included in this solicitation. Title: B84 Replace Metal Roof Naval Air Facility (NAF) AtsugiThe project was selected as the seed project from existing requirements to best represent the nature of potential work under this contract. Per FAR 36.204, the magnitude of the seed project is between $250,000 and $500,000, or Japanese Yen equivalent using the Fiscal Year 2025 Budget Exchange Rate of ?145.7323 / $1.00.Award will be made to the responsible Offerors whose proposals, conforming to the solicitation, are the most advantageous and offers the best value to the Government considering price and non-price evaluation factors.PLANS AND SPECIFICATIONSThe RFP including the plans and specifications will be posted on the Government-wide point of entry (GPE), currently DoD Solicitation Module in the PIEE website and/or ContractOpportunities in the SAM website. When posted, all RFP documents may be downloaded from the website free of charge.CONTRACTOR LICENSING REQUIREMENTSAny contract resulting from this solicitation will be awarded and performed in its entirety in the country of Japan. Contractors must be duly authorized to operate and conduct business in Japan and must fully comply with all laws, decrees, labor standards, and regulations of Japan during the performance of the contract. Prior to award of any contract, Offerors must be registered to do business and possess a construction license (Kensetsu Gyo Kyoka) issued by the Ministry of Land, Infrastructure and Transport, or prefectural government. Offerors will be required to provide verification on such construction license prior to award of any contract to the contracting officer if such information is not already on file with or available to the contracting officer.STATUS OF FORCES AGREEMENTThe U.S. Government will not offer ?United States Official Contractor? status under Article XIV of the U.S.-Japan Status of Forces Agreement (SOFA) to any Offeror awarded a contract under this solicitation; however, the U.S. Government may consider designating eligible employee(s) as ?Members of the Civilian Component? under Article I(b) of the SOFA.SYSTEM FOR AWARD MANAGEMENT (SAM) REGISTRATIONAll Offerors (i.e., whether individually or as a joint venture, et.) responding to this solicitation must be registered in the SAM database at https://sam.gov prior to the closing date for receipt of proposals to be eligible for award and must have active Representation and Certifications in SAM. Interested Offerors are encouraged to register as soon as possible.An Offeror is required to be registered in SAM when submitting its proposal, and shall continue to be registered at all relevant times, i.e., time of award, during contract performance, and through final payment of the contract resulting from the solicitation. Offerors with no active registration in SAM or an Offeror whose SAM online Representations and Certifications are not current will not be eligible for award.PROCUREMENT INTEGRATED ENTERPRISE ENVIRONMENT (PIEE) REGISTRATIONThis solicitation will require electronic submittal of proposals through the DoD Solicitation Module in PIEE or via other methods, if specified by the Government. In order to submit a proposal through the Solicitation Module in PIEE, Offerors must have an active Proposal Manager role in PIEE at https://piee.eb.mil . Interested Offerors are encouraged to register for the required role as soon as possible.Information and training on PIEE Solicitation Module is available at:https://dodprocurementtoolbox.com/site-pages/solicitation-moduleAdditional Web Based Training is available at:https://pieetraining.eb.mil/wbt/xhtml/wbt/sol/index.xhtmlhttps://pieetraining.eb.mil/wbt/sol/Posting_Offer.pdf","origin":"extract"},"notice_type":{"code":"p","label":"Presolicitation"},"schema_version":1,"solicitation_number":"N4008425R0066","product_service_code":"Z2JZ"},{"dates":{"posted":"2025-02-07","response_deadline":{"raw":"2025-02-21T14:30:00-09:00","utc":"2025-02-21T23:30:00Z","date":"2025-02-21","time":"14:30:00","utc_offset_seconds":-32400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/5a3eeabc3fce4fb0ab8796242150df55/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","agency":{"office":{"code":"N40084","name":"NAVFACSYSCOM FAR EAST"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"96349-0013","city":"FPO","state":"AP","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-02-07","archive_type":"auto_custom"},"contacts":[{"name":"Emiko Uyama","role":"primary","email":"emiko.uyama2.ln@us.navy.mil","phone":"046-816-2874"},{"name":"Teresa Aguon","role":"secondary","email":"teresa.f.aguon.civ@us.navy.mil"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"5a3eeabc3fce4fb0ab8796242150df55","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"63f19fd32f0da571c8327ad07c8833c787300a2fb66ff7e4254355a335e17ed1","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"Pre-Solicitation Notice for Solicitation No. N4008425R0066 The Naval Facilities Engineering Systems Command, Far East (NAVFAC FE) is issuing this pre-solicitation notice in accordance with FAR 36.213-2. This pre-solicitation notice does NOT constitute a request for proposal, request for quote, or invitation for bid. This notice shall NOT be construed as a commitment by the Government for any purpose. Interested Offerors can view and/or download the solicitation from the Government-wide point of entry (GPE), currently the Solicitation Module in the Procurement Integrated Enterprise Environment (PIEE) website (https://piee.eb.mil/sol/xhtml/unauth/index.xhtml) and/or Contract Opportunities in the System for Award Management (SAM) website (https://sam.gov) when it becomes available on or about 25 Feb 2025. DESCRIPTION OF PROPOSED WORK This acquisition is for an Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan; U.S. Marine Corps Combined Arms Training Center (CATC), Camp Fuji, Japan; and various locations in the Atsugi Area of Responsibility (AOR), Japan. The Contractor must furnish all labor, management, supervision, tools, materials, equipment, incidental engineering, and transportation, except otherwise specified in each task order necessary to perform the various projects. The proposed scope of work will be specified in each task order and may include, but is not limited to, facility repair/ renovation, demolition, built-in equipment repair/replacement, piping repair/replacement, pipe insulation, electrical work, mechanical work, road pavement, fencing roofing, painting, site work, utilities, removal and disposal of material containing lead paint with lead, cadmium, chromium (VI) and asbestos containing material, welding, and masonry. This requirement is anticipated to result in approximately five (5) Firm-Fixed-Price (FFP) IDIQ contract awards where the maximum aggregate value of all contracts will not exceed $99,000,000 or Japanese yen equivalent over an eight-year period, consisting of one four (4) year base period and one four (4) year option period, for a maximum duration of 96 months. The anticipated task orders will be FFP ranging from 300,000 JPY to 75,000,000 JPY. However, task orders under or over these amounts may be considered if it is determined to be in the Government’s best interest and approved by the Contracting Officer. Task orders for the minimum guarantee of 400,000 JPY / $2,744.76 (FY25 Budget Exchange Rate at 145.7323 JPY) each will be issued concurrently with the award of the basic contract for the Offerors awarded a MACC, but not awarded the seed project. Only the base period of the contract will offer a minimum guarantee. There will be one (1) Design-Bid-Build seed project included in this solicitation. Title: B84 Replace Metal Roof Naval Air Facility (NAF) Atsugi The project was selected as the seed project from existing requirements to best represent the nature of potential work under this contract. Per FAR 36.204, the magnitude of the seed project is between $250,000 and $500,000, or Japanese Yen equivalent using the Fiscal Year 2025 Budget Exchange Rate of ¥145.7323 / $1.00. Award will be made to the responsible Offerors whose proposals, conforming to the solicitation, are the most advantageous and offers the best value to the Government considering price and non-price evaluation factors. PLANS AND SPECIFICATIONS The RFP including the plans and specifications will be posted on the Government-wide point of entry (GPE), currently DoD Solicitation Module in the PIEE website and/or ContractOpportunities in the SAM website. When posted, all RFP documents may be downloaded from the website free of charge. CONTRACTOR LICENSING REQUIREMENTS Any contract resulting from this solicitation will be awarded and performed in its entirety in the country of Japan. Contractors must be duly authorized to operate and conduct business in Japan and must fully comply with all laws, decrees, labor standards, and regulations of Japan during the performance of the contract. Prior to award of any contract, Offerors must be registered to do business and possess a construction license (Kensetsu Gyo Kyoka) issued by the Ministry of Land, Infrastructure and Transport, or prefectural government. Offerors will be required to provide verification on such construction license prior to award of any contract to the contracting officer if such information is not already on file with or available to the contracting officer. STATUS OF FORCES AGREEMENT The U.S. Government will not offer “United States Official Contractor” status under Article XIV of the U.S.-Japan Status of Forces Agreement (SOFA) to any Offeror awarded a contract under this solicitation; however, the U.S. Government may consider designating eligible employee(s) as “Members of the Civilian Component” under Article I(b) of the SOFA. SYSTEM FOR AWARD MANAGEMENT (SAM) REGISTRATION All Offerors (i.e., whether individually or as a joint venture, et.) responding to this solicitation must be registered in the SAM database at https://sam.gov prior to the closing date for receipt of proposals to be eligible for award and must have active Representation and Certifications in SAM. Interested Offerors are encouraged to register as soon as possible. An Offeror is required to be registered in SAM when submitting its proposal, and shall continue to be registered at all relevant times, i.e., time of award, during contract performance, and through final payment of the contract resulting from the solicitation. Offerors with no active registration in SAM or an Offeror whose SAM online Representations and Certifications are not current will not be eligible for award. PROCUREMENT INTEGRATED ENTERPRISE ENVIRONMENT (PIEE) REGISTRATION This solicitation will require electronic submittal of proposals through the DoD Solicitation Module in PIEE or via other methods, if specified by the Government. In order to submit a proposal through the Solicitation Module in PIEE, Offerors must have an active Proposal Manager role in PIEE at https://piee.eb.mil . Interested Offerors are encouraged to register for the required role as soon as possible. Information and training on PIEE Solicitation Module is available at: https://dodprocurementtoolbox.com/site-pages/solicitation-module Additional Web Based Training is available at: https://pieetraining.eb.mil/wbt/xhtml/wbt/sol/index.xhtml https://pieetraining.eb.mil/wbt/sol/Posting_Offer.pdf","origin":"extract"},"notice_type":{"code":"p","label":"Presolicitation"},"schema_version":1,"solicitation_number":"N4008425R0066","product_service_code":"Z2JZ"},{"dates":{"posted":"2025-02-09","response_deadline":{"raw":"2025-02-21T14:30:00-09:00","utc":"2025-02-21T23:30:00Z","date":"2025-02-21","time":"14:30:00","utc_offset_seconds":-32400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/282290bb11e7452fa2fbc00dea9c5dfd/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","agency":{"office":{"code":"N40084","name":"NAVFACSYSCOM FAR EAST"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"96349-0013","city":"FPO","state":"AP","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-02-07","archive_type":"auto_custom"},"contacts":[{"name":"Emiko Uyama","role":"primary","email":"emiko.uyama2.ln@us.navy.mil","phone":"046-816-2874"},{"name":"Teresa Aguon","role":"secondary","email":"teresa.f.aguon.civ@us.navy.mil"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"282290bb11e7452fa2fbc00dea9c5dfd","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"322d9dc8c95b1b4df87fd2ba3292984d1963dbecfab49498f1851611f06e4fed","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"Pre-Solicitation Notice for Solicitation No. N4008425R0066 The Naval Facilities Engineering Systems Command, Far East (NAVFAC FE) is issuing this pre-solicitation notice in accordance with FAR 36.213-2. This pre-solicitation notice does NOT constitute a request for proposal, request for quote, or invitation for bid. This notice shall NOT be construed as a commitment by the Government for any purpose. Interested Offerors can view and/or download the solicitation from the Government-wide point of entry (GPE), currently the Solicitation Module in the Procurement Integrated Enterprise Environment (PIEE) website (https://piee.eb.mil/sol/xhtml/unauth/index.xhtml) and/or Contract Opportunities in the System for Award Management (SAM) website (https://sam.gov) when it becomes available on or about 25 Feb 2025. DESCRIPTION OF PROPOSED WORK This acquisition is for an Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan; U.S. Marine Corps Combined Arms Training Center (CATC), Camp Fuji, Japan; and various locations in the Atsugi Area of Responsibility (AOR), Japan. The Contractor must furnish all labor, management, supervision, tools, materials, equipment, incidental engineering, and transportation, except otherwise specified in each task order necessary to perform the various projects. The proposed scope of work will be specified in each task order and may include, but is not limited to, facility repair/ renovation, demolition, built-in equipment repair/replacement, piping repair/replacement, pipe insulation, electrical work, mechanical work, road pavement, fencing roofing, painting, site work, utilities, removal and disposal of material containing lead paint with lead, cadmium, chromium (VI) and asbestos containing material, welding, and masonry. This requirement is anticipated to result in approximately five (5) Firm-Fixed-Price (FFP) IDIQ contract awards where the maximum aggregate value of all contracts will not exceed $99,000,000 or Japanese yen equivalent over an eight-year period, consisting of one four (4) year base period and one four (4) year option period, for a maximum duration of 96 months. The anticipated task orders will be FFP ranging from 300,000 JPY to 75,000,000 JPY. However, task orders under or over these amounts may be considered if it is determined to be in the Government’s best interest and approved by the Contracting Officer. Task orders for the minimum guarantee of 400,000 JPY / $2,744.76 (FY25 Budget Exchange Rate at 145.7323 JPY) each will be issued concurrently with the award of the basic contract for the Offerors awarded a MACC, but not awarded the seed project. Only the base period of the contract will offer a minimum guarantee. There will be one (1) Design-Bid-Build seed project included in this solicitation. Title: B84 Replace Metal Roof Naval Air Facility (NAF) Atsugi The project was selected as the seed project from existing requirements to best represent the nature of potential work under this contract. Per FAR 36.204, the magnitude of the seed project is between $250,000 and $500,000, or Japanese Yen equivalent using the Fiscal Year 2025 Budget Exchange Rate of ¥145.7323 / $1.00. Award will be made to the responsible Offerors whose proposals, conforming to the solicitation, are the most advantageous and offers the best value to the Government considering price and non-price evaluation factors. PLANS AND SPECIFICATIONS The RFP including the plans and specifications will be posted on the Government-wide point of entry (GPE), currently DoD Solicitation Module in the PIEE website and/or ContractOpportunities in the SAM website. When posted, all RFP documents may be downloaded from the website free of charge. CONTRACTOR LICENSING REQUIREMENTS Any contract resulting from this solicitation will be awarded and performed in its entirety in the country of Japan. Contractors must be duly authorized to operate and conduct business in Japan and must fully comply with all laws, decrees, labor standards, and regulations of Japan during the performance of the contract. Prior to award of any contract, Offerors must be registered to do business and possess a construction license (Kensetsu Gyo Kyoka) issued by the Ministry of Land, Infrastructure and Transport, or prefectural government. Offerors will be required to provide verification on such construction license prior to award of any contract to the contracting officer if such information is not already on file with or available to the contracting officer. STATUS OF FORCES AGREEMENT The U.S. Government will not offer “United States Official Contractor” status under Article XIV of the U.S.-Japan Status of Forces Agreement (SOFA) to any Offeror awarded a contract under this solicitation; however, the U.S. Government may consider designating eligible employee(s) as “Members of the Civilian Component” under Article I(b) of the SOFA. SYSTEM FOR AWARD MANAGEMENT (SAM) REGISTRATION All Offerors (i.e., whether individually or as a joint venture, et.) responding to this solicitation must be registered in the SAM database at https://sam.gov prior to the closing date for receipt of proposals to be eligible for award and must have active Representation and Certifications in SAM. Interested Offerors are encouraged to register as soon as possible. An Offeror is required to be registered in SAM when submitting its proposal, and shall continue to be registered at all relevant times, i.e., time of award, during contract performance, and through final payment of the contract resulting from the solicitation. Offerors with no active registration in SAM or an Offeror whose SAM online Representations and Certifications are not current will not be eligible for award. PROCUREMENT INTEGRATED ENTERPRISE ENVIRONMENT (PIEE) REGISTRATION This solicitation will require electronic submittal of proposals through the DoD Solicitation Module in PIEE or via other methods, if specified by the Government. In order to submit a proposal through the Solicitation Module in PIEE, Offerors must have an active Proposal Manager role in PIEE at https://piee.eb.mil . Interested Offerors are encouraged to register for the required role as soon as possible. Information and training on PIEE Solicitation Module is available at: https://dodprocurementtoolbox.com/site-pages/solicitation-module Additional Web Based Training is available at: https://pieetraining.eb.mil/wbt/xhtml/wbt/sol/index.xhtml https://pieetraining.eb.mil/wbt/sol/Posting_Offer.pdf","origin":"extract"},"notice_type":{"code":"p","label":"Presolicitation"},"schema_version":1,"solicitation_number":"N4008425R0066","product_service_code":"Z2JZ"},{"dates":{"posted":"2025-02-28","response_deadline":{"raw":"2025-04-18T14:30:00+09:00","utc":"2025-04-18T05:30:00Z","date":"2025-04-18","time":"14:30:00","utc_offset_seconds":32400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/46f81c7e0ef44c5eb02167fc8052d6d1/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","agency":{"office":{"code":"N40084","name":"NAVFACSYSCOM FAR EAST"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"96349-0013","city":"FPO","state":"AP","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-02-28","archive_type":"auto_custom"},"contacts":[{"name":"Emiko Uyama","role":"primary","email":"emiko.uyama2.ln@us.navy.mil","phone":"046-816-2874"},{"name":"Teresa Aguon","role":"secondary","email":"teresa.f.aguon.civ@us.navy.mil","phone":"3152432875"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"46f81c7e0ef44c5eb02167fc8052d6d1","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"9241d4683a3cccf27e5c6c9add098053255aa7106e7faeb9e099386869eef35b","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"A pre-proposal conference will be held in English on Tuesday, 25 March 2025 at 1000 Japan Standard Time (JST) at NAVFAC Far East, Building 89, U.S. Naval Facility (NAF) Atsugi, Japan. Site visit of the seed project location will commence immediately after the pre-proposal conference. Participants without base access will require Government escort to attend the site visit and shall submit a request for base access using RFP Attachment 4, Site Visit Request List, no later than 18 March 2025 at 1430 (JST) via email to Ms. Emiko Uyama, Contract Specialist, at emiko.uyama2.ln@us.navy.mil and Ms Teresa Aguon, Contracting Officer, at teresa.f.aguon.civ@us.navy.mil. Failure to request for base access will result in delays or disapproval to access the site location.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"N4008425R0066","place_of_performance":{"city":{"name":"Atsugi"},"country":{"code":"JPN"}},"product_service_code":"Z2JZ"},{"dates":{"posted":"2025-02-28","response_deadline":{"raw":"2025-04-18T14:30:00+09:00","utc":"2025-04-18T05:30:00Z","date":"2025-04-18","time":"14:30:00","utc_offset_seconds":32400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/87bb17a6c9c14fa1bfee761b87c6a806/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","agency":{"office":{"code":"N40084","name":"NAVFACSYSCOM FAR EAST"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"96349-0013","city":"FPO","state":"AP","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-02-28","archive_type":"auto_custom"},"contacts":[{"name":"Emiko Uyama","role":"primary","email":"emiko.uyama2.ln@us.navy.mil","phone":"046-816-2874"},{"name":"Teresa Aguon","role":"secondary","email":"teresa.f.aguon.civ@us.navy.mil","phone":"3152432875"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"87bb17a6c9c14fa1bfee761b87c6a806","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"0c752d9547cb7b6d61753f39fd6b0648ca50b62db3798bf72acb8967bba17eaa","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"A pre-proposal conference will be held in English on Tuesday, 25 March 2025 at 1000 Japan Standard Time (JST) at NAVFAC Far East, Building 89, U.S. Naval Facility (NAF) Atsugi, Japan. Site visit of the seed project location will commence immediately after the pre-proposal conference. Participants without base access will require Government escort to attend the site visit and shall submit a request for base access using RFP Attachment 4, Site Visit Request List, no later than 18 March 2025 at 1430 (JST) via email to Ms. Emiko Uyama, Contract Specialist, at emiko.uyama2.ln@us.navy.mil and Ms Teresa Aguon, Contracting Officer, at teresa.f.aguon.civ@us.navy.mil. Failure to request for base access will result in delays or disapproval to access the site location.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"N4008425R0066","product_service_code":"Z2JZ"},{"dates":{"posted":"2025-03-04","response_deadline":{"raw":"2025-04-18T14:30:00+09:00","utc":"2025-04-18T05:30:00Z","date":"2025-04-18","time":"14:30:00","utc_offset_seconds":32400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/70ff9237bf41471bba5e52c4448ba6a6/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","agency":{"office":{"code":"N40084","name":"NAVFACSYSCOM FAR EAST"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"96349-0013","city":"FPO","state":"AP","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-03-05","archive_type":"auto_custom"},"contacts":[{"name":"Emiko Uyama","role":"primary","email":"emiko.uyama2.ln@us.navy.mil","phone":"046-816-2874"},{"name":"Teresa Aguon","role":"secondary","email":"teresa.f.aguon.civ@us.navy.mil","phone":"3152432875"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"70ff9237bf41471bba5e52c4448ba6a6","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"297f7ab6a2a4c292fe3d748c3b3f9d3543da242633b10f639cda82645f7788b5","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"Amend 0001 was issued with attachment of Enclosure (1) Government response to Pre-proposal inquiries (PPI); Attachment 5 Atsugi DBB MACC Seed Project Drawing - Enclosure 1; Attachment 5 Atsugi DBB MACC Seed Project Drawing - Enclosure 2. **A pre-proposal conference will be held in English on Tuesday, 25 March 2025 at 1000 Japan Standard Time (JST) at NAVFAC Far East, Building 89, U.S. Naval Facility (NAF) Atsugi, Japan. Site visit of the seed project location will commence immediately after the pre-proposal conference. Participants without base access will require Government escort to attend the site visit and shall submit a request for base access using RFP Attachment 4, Site Visit Request List, no later than 18 March 2025 at 1430 (JST) via email to Ms. Emiko Uyama, Contract Specialist, at emiko.uyama2.ln@us.navy.mil and Ms Teresa Aguon, Contracting Officer, at teresa.f.aguon.civ@us.navy.mil. Failure to request for base access will result in delays or disapproval to access the site location.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"N4008425R0066","place_of_performance":{"city":{"name":"Atsugi"},"country":{"code":"JPN"}},"product_service_code":"Z2JZ"},{"dates":{"posted":"2025-03-04","response_deadline":{"raw":"2025-04-18T14:30:00+09:00","utc":"2025-04-18T05:30:00Z","date":"2025-04-18","time":"14:30:00","utc_offset_seconds":32400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/7ed99ab94b5c4b09ac1e032ddccef542/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","agency":{"office":{"code":"N40084","name":"NAVFACSYSCOM FAR EAST"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"96349-0013","city":"FPO","state":"AP","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-03-05","archive_type":"auto_custom"},"contacts":[{"name":"Emiko Uyama","role":"primary","email":"emiko.uyama2.ln@us.navy.mil","phone":"046-816-2874"},{"name":"Teresa Aguon","role":"secondary","email":"teresa.f.aguon.civ@us.navy.mil","phone":"3152432875"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"7ed99ab94b5c4b09ac1e032ddccef542","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"dab9b4cf583d1e60eedd3eb2da7b4e816de625159cb146dc935800206a785217","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"Amend 0001 was issued with attachment of Enclosure (1) Government response to Pre-proposal inquiries (PPI); Attachment 5 Atsugi DBB MACC Seed Project Drawing - Enclosure 1; Attachment 5 Atsugi DBB MACC Seed Project Drawing - Enclosure 2. **A pre-proposal conference will be held in English on Tuesday, 25 March 2025 at 1000 Japan Standard Time (JST) at NAVFAC Far East, Building 89, U.S. Naval Facility (NAF) Atsugi, Japan. Site visit of the seed project location will commence immediately after the pre-proposal conference. Participants without base access will require Government escort to attend the site visit and shall submit a request for base access using RFP Attachment 4, Site Visit Request List, no later than 18 March 2025 at 1430 (JST) via email to Ms. Emiko Uyama, Contract Specialist, at emiko.uyama2.ln@us.navy.mil and Ms Teresa Aguon, Contracting Officer, at teresa.f.aguon.civ@us.navy.mil. Failure to request for base access will result in delays or disapproval to access the site location.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"N4008425R0066","place_of_performance":{"city":{"name":"Atsugi"},"country":{"code":"JPN"}},"product_service_code":"Z2JZ"},{"dates":{"posted":"2025-03-21","response_deadline":{"raw":"2025-04-18T14:30:00+09:00","utc":"2025-04-18T05:30:00Z","date":"2025-04-18","time":"14:30:00","utc_offset_seconds":32400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/7a4f8a20498e4595b0f3f8b03ae22c7d/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","agency":{"office":{"code":"N40084","name":"NAVFACSYSCOM FAR EAST"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"96349-0013","city":"FPO","state":"AP","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-03-21","archive_type":"auto_custom"},"contacts":[{"name":"Emiko Uyama","role":"primary","email":"emiko.uyama2.ln@us.navy.mil","phone":"046-816-2874"},{"name":"Teresa Aguon","role":"secondary","email":"teresa.f.aguon.civ@us.navy.mil","phone":"3152432875"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"7a4f8a20498e4595b0f3f8b03ae22c7d","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"adbaa591d71362a0bd5eadb790c0cdab538a26c845191b96e2114d55ab8772b2","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"**Amd 0002 was issued with attachment of Enclosure (1) Government response to Pre-proposal inquiries (PPI); PPI Attachment 1 - EXHIBIT A and EXHIBIT C. * Amend 0001 was issued with attachment of Enclosure (1) Government response to Pre-proposal inquiries (PPI); Attachment 5 Atsugi DBB MACC Seed Project Drawing - Enclosure 1; Attachment 5 Atsugi DBB MACC Seed Project Drawing - Enclosure 2. **A pre-proposal conference will be held in English on Tuesday, 25 March 2025 at 1000 Japan Standard Time (JST) at NAVFAC Far East, Building 89, U.S. Naval Facility (NAF) Atsugi, Japan. Site visit of the seed project location will commence immediately after the pre-proposal conference. Participants without base access will require Government escort to attend the site visit and shall submit a request for base access using RFP Attachment 4, Site Visit Request List, no later than 18 March 2025 at 1430 (JST) via email to Ms. Emiko Uyama, Contract Specialist, at emiko.uyama2.ln@us.navy.mil and Ms Teresa Aguon, Contracting Officer, at teresa.f.aguon.civ@us.navy.mil. Failure to request for base access will result in delays or disapproval to access the site location.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"N4008425R0066","place_of_performance":{"city":{"name":"Atsugi"},"country":{"code":"JPN"}},"product_service_code":"Z2JZ"},{"dates":{"posted":"2025-03-21","response_deadline":{"raw":"2025-04-18T14:30:00+09:00","utc":"2025-04-18T05:30:00Z","date":"2025-04-18","time":"14:30:00","utc_offset_seconds":32400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/8d4630317f6f4cc6b36fef218ef98056/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","agency":{"office":{"code":"N40084","name":"NAVFACSYSCOM FAR EAST"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"96349-0013","city":"FPO","state":"AP","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-03-21","archive_type":"auto_custom"},"contacts":[{"name":"Emiko Uyama","role":"primary","email":"emiko.uyama2.ln@us.navy.mil","phone":"046-816-2874"},{"name":"Teresa Aguon","role":"secondary","email":"teresa.f.aguon.civ@us.navy.mil","phone":"3152432875"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"8d4630317f6f4cc6b36fef218ef98056","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"30cfe3aa32baa343b3882c1c95f048bb8daa16334b3c6175621dc66d833de823","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"Amd 0002 was issued with attachment of Enclosure (1) Government response to Pre-proposal inquiries (PPI); PPI Attachment 1 - EXHIBIT A and EXHIBIT C. Amend 0001 was issued with attachment of Enclosure (1) Government response to Pre-proposal inquiries (PPI); Attachment 5 Atsugi DBB MACC Seed Project Drawing - Enclosure 1; Attachment 5 Atsugi DBB MACC Seed Project Drawing - Enclosure 2. **A pre-proposal conference will be held in English on Tuesday, 25 March 2025 at 1000 Japan Standard Time (JST) at NAVFAC Far East, Building 89, U.S. Naval Facility (NAF) Atsugi, Japan. Site visit of the seed project location will commence immediately after the pre-proposal conference. Participants without base access will require Government escort to attend the site visit and shall submit a request for base access using RFP Attachment 4, Site Visit Request List, no later than 18 March 2025 at 1430 (JST) via email to Ms. Emiko Uyama, Contract Specialist, at emiko.uyama2.ln@us.navy.mil and Ms Teresa Aguon, Contracting Officer, at teresa.f.aguon.civ@us.navy.mil. Failure to request for base access will result in delays or disapproval to access the site location.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"N4008425R0066","place_of_performance":{"city":{"name":"Atsugi"},"country":{"code":"JPN"}},"product_service_code":"Z2JZ"},{"dates":{"posted":"2025-03-25","response_deadline":{"raw":"2025-04-18T14:30:00+09:00","utc":"2025-04-18T05:30:00Z","date":"2025-04-18","time":"14:30:00","utc_offset_seconds":32400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/690c657c67dd4afebf6d952fb22b5249/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","agency":{"office":{"code":"N40084","name":"NAVFACSYSCOM FAR EAST"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"96349-0013","city":"FPO","state":"AP","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-03-21","archive_type":"auto_custom"},"contacts":[{"name":"Emiko Uyama","role":"primary","email":"emiko.uyama2.ln@us.navy.mil","phone":"046-816-2874"},{"name":"Teresa Aguon","role":"secondary","email":"teresa.f.aguon.civ@us.navy.mil","phone":"3152432875"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"690c657c67dd4afebf6d952fb22b5249","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"fccec8090e12ecdb2a0db49b13a3b7474c8904e73d31cd3a1cf013023aa9ad99","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"-The slides used for Pre-proposal conference (held on 25 March 2025 is now attached. -Amd 0002 was issued with attachment of Enclosure (1) Government response to Pre-proposal inquiries (PPI); PPI Attachment 1 - EXHIBIT A and EXHIBIT C. -Amend 0001 was issued with attachment of Enclosure (1) Government response to Pre-proposal inquiries (PPI); Attachment 5 Atsugi DBB MACC Seed Project Drawing - Enclosure 1; Attachment 5 Atsugi DBB MACC Seed Project Drawing - Enclosure 2. **A pre-proposal conference will be held in English on Tuesday, 25 March 2025 at 1000 Japan Standard Time (JST) at NAVFAC Far East, Building 89, U.S. Naval Facility (NAF) Atsugi, Japan. Site visit of the seed project location will commence immediately after the pre-proposal conference. Participants without base access will require Government escort to attend the site visit and shall submit a request for base access using RFP Attachment 4, Site Visit Request List, no later than 18 March 2025 at 1430 (JST) via email to Ms. Emiko Uyama, Contract Specialist, at emiko.uyama2.ln@us.navy.mil and Ms Teresa Aguon, Contracting Officer, at teresa.f.aguon.civ@us.navy.mil. Failure to request for base access will result in delays or disapproval to access the site location.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"N4008425R0066","place_of_performance":{"city":{"name":"Atsugi"},"country":{"code":"JPN"}},"product_service_code":"Z2JZ"},{"dates":{"posted":"2025-04-10","response_deadline":{"raw":"2025-04-18T14:30:00+09:00","utc":"2025-04-18T05:30:00Z","date":"2025-04-18","time":"14:30:00","utc_offset_seconds":32400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/2daaa2a4381947be968d0b67eeb06c21/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","agency":{"office":{"code":"N40084","name":"NAVFACSYSCOM FAR EAST"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"96349-0013","city":"FPO","state":"AP","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-04-10","archive_type":"auto_custom"},"contacts":[{"name":"Emiko Uyama","role":"primary","email":"emiko.uyama2.ln@us.navy.mil","phone":"046-816-2874"},{"name":"Teresa Aguon","role":"secondary","email":"teresa.f.aguon.civ@us.navy.mil","phone":"3152432875"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"2daaa2a4381947be968d0b67eeb06c21","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"4c431d73dbbeb094878edd54a1b04d851c197484da63865089895b896fb8ebf9","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"***Amd 0003 was issued with attachmet of Enclosure (1) Government response to Pre-proposal inquiries (PPI); PPI Attachment - Asbestos Fiber Identification Report and EM 385-1-1 **Amd 0002 was issued with attachment of Enclosure (1) Government response to Pre-proposal inquiries (PPI); PPI Attachment 1 - EXHIBIT A and EXHIBIT C. * Amend 0001 was issued with attachment of Enclosure (1) Government response to Pre-proposal inquiries (PPI); Attachment 5 Atsugi DBB MACC Seed Project Drawing - Enclosure 1; Attachment 5 Atsugi DBB MACC Seed Project Drawing - Enclosure 2. **A pre-proposal conference will be held in English on Tuesday, 25 March 2025 at 1000 Japan Standard Time (JST) at NAVFAC Far East, Building 89, U.S. Naval Facility (NAF) Atsugi, Japan. Site visit of the seed project location will commence immediately after the pre-proposal conference. Participants without base access will require Government escort to attend the site visit and shall submit a request for base access using RFP Attachment 4, Site Visit Request List, no later than 18 March 2025 at 1430 (JST) via email to Ms. Emiko Uyama, Contract Specialist, at emiko.uyama2.ln@us.navy.mil and Ms Teresa Aguon, Contracting Officer, at teresa.f.aguon.civ@us.navy.mil. Failure to request for base access will result in delays or disapproval to access the site location.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"N4008425R0066","place_of_performance":{"city":{"name":"Atsugi"},"country":{"code":"JPN"}},"product_service_code":"Z2JZ"},{"dates":{"posted":"2025-04-10","response_deadline":{"raw":"2025-04-18T14:30:00+09:00","utc":"2025-04-18T05:30:00Z","date":"2025-04-18","time":"14:30:00","utc_offset_seconds":32400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/bf5655b2ed954fd5b10f2d5e9841aa16/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","agency":{"office":{"code":"N40084","name":"NAVFACSYSCOM FAR EAST"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"96349-0013","city":"FPO","state":"AP","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-04-10","archive_type":"auto_custom"},"contacts":[{"name":"Emiko Uyama","role":"primary","email":"emiko.uyama2.ln@us.navy.mil","phone":"046-816-2874"},{"name":"Teresa Aguon","role":"secondary","email":"teresa.f.aguon.civ@us.navy.mil","phone":"3152432875"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"bf5655b2ed954fd5b10f2d5e9841aa16","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"87e4d1231a1cbe2385f6996e75da39de04214bdc62db426e9fd1efac42796be3","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"***Amd 0003 was issued with attachmet of Enclosure (1) Government response to Pre-proposal inquiries (PPI); PPI Attachment - Asbestos Fiber Identification Report and EM 385-1-1 **Amd 0002 was issued with attachment of Enclosure (1) Government response to Pre-proposal inquiries (PPI); PPI Attachment 1 - EXHIBIT A and EXHIBIT C. * Amend 0001 was issued with attachment of Enclosure (1) Government response to Pre-proposal inquiries (PPI); Attachment 5 Atsugi DBB MACC Seed Project Drawing - Enclosure 1; Attachment 5 Atsugi DBB MACC Seed Project Drawing - Enclosure 2. **A pre-proposal conference will be held in English on Tuesday, 25 March 2025 at 1000 Japan Standard Time (JST) at NAVFAC Far East, Building 89, U.S. Naval Facility (NAF) Atsugi, Japan. Site visit of the seed project location will commence immediately after the pre-proposal conference. Participants without base access will require Government escort to attend the site visit and shall submit a request for base access using RFP Attachment 4, Site Visit Request List, no later than 18 March 2025 at 1430 (JST) via email to Ms. Emiko Uyama, Contract Specialist, at emiko.uyama2.ln@us.navy.mil and Ms Teresa Aguon, Contracting Officer, at teresa.f.aguon.civ@us.navy.mil. Failure to request for base access will result in delays or disapproval to access the site location.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"N4008425R0066","place_of_performance":{"city":{"name":"Atsugi"},"country":{"code":"JPN"}},"product_service_code":"Z2JZ"},{"dates":{"posted":"2025-04-14","response_deadline":{"raw":"2025-04-18T14:30:00+09:00","utc":"2025-04-18T05:30:00Z","date":"2025-04-18","time":"14:30:00","utc_offset_seconds":32400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/0ee6436392c24d968c738e027eee7fcd/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","agency":{"office":{"code":"N40084","name":"NAVFACSYSCOM FAR EAST"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"96349-0013","city":"FPO","state":"AP","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-04-15","archive_type":"auto_custom"},"contacts":[{"name":"Emiko Uyama","role":"primary","email":"emiko.uyama2.ln@us.navy.mil","phone":"046-816-2874"},{"name":"Teresa Aguon","role":"secondary","email":"teresa.f.aguon.civ@us.navy.mil","phone":"3152432875"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"0ee6436392c24d968c738e027eee7fcd","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"247e8a6ea382511ba416d6116a31b6b06ef8f4d0b82b1c96dac86392df55fff8","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"****Amd 0004 was issued with attachment of Enclosure (1) Government response to Pre-proposal inquiries (PPI). ***Amd 0003 was issued with attachmet of Enclosure (1) Government response to Pre-proposal inquiries (PPI); PPI Attachment - Asbestos Fiber Identification Report and EM 385-1-1 **Amd 0002 was issued with attachment of Enclosure (1) Government response to Pre-proposal inquiries (PPI); PPI Attachment 1 - EXHIBIT A and EXHIBIT C. * Amend 0001 was issued with attachment of Enclosure (1) Government response to Pre-proposal inquiries (PPI); Attachment 5 Atsugi DBB MACC Seed Project Drawing - Enclosure 1; Attachment 5 Atsugi DBB MACC Seed Project Drawing - Enclosure 2. **A pre-proposal conference will be held in English on Tuesday, 25 March 2025 at 1000 Japan Standard Time (JST) at NAVFAC Far East, Building 89, U.S. Naval Facility (NAF) Atsugi, Japan. Site visit of the seed project location will commence immediately after the pre-proposal conference. Participants without base access will require Government escort to attend the site visit and shall submit a request for base access using RFP Attachment 4, Site Visit Request List, no later than 18 March 2025 at 1430 (JST) via email to Ms. Emiko Uyama, Contract Specialist, at emiko.uyama2.ln@us.navy.mil and Ms Teresa Aguon, Contracting Officer, at teresa.f.aguon.civ@us.navy.mil. Failure to request for base access will result in delays or disapproval to access the site location.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"N4008425R0066","place_of_performance":{"city":{"name":"Atsugi"},"country":{"code":"JPN"}},"product_service_code":"Z2JZ"},{"dates":{"posted":"2025-04-15","response_deadline":{"raw":"2025-04-18T14:30:00+09:00","utc":"2025-04-18T05:30:00Z","date":"2025-04-18","time":"14:30:00","utc_offset_seconds":32400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/840c7dc2309049b8bb17248cfc42ea21/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","agency":{"office":{"code":"N40084","name":"NAVFACSYSCOM FAR EAST"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"96349-0013","city":"FPO","state":"AP","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-04-15","archive_type":"auto_custom"},"contacts":[{"name":"Emiko Uyama","role":"primary","email":"emiko.uyama2.ln@us.navy.mil","phone":"046-816-2874"},{"name":"Teresa Aguon","role":"secondary","email":"teresa.f.aguon.civ@us.navy.mil","phone":"3152432875"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"840c7dc2309049b8bb17248cfc42ea21","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"066a357d3bb18d1a21d565365b8836909ee280a6d60462e52be778bc45b47bbb","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"****Amd 0004 was issued with attachment of Enclosure (1) Government response to Pre-proposal inquiries (PPI). ***Amd 0003 was issued with attachmet of Enclosure (1) Government response to Pre-proposal inquiries (PPI); PPI Attachment - Asbestos Fiber Identification Report and EM 385-1-1 **Amd 0002 was issued with attachment of Enclosure (1) Government response to Pre-proposal inquiries (PPI); PPI Attachment 1 - EXHIBIT A and EXHIBIT C. * Amend 0001 was issued with attachment of Enclosure (1) Government response to Pre-proposal inquiries (PPI); Attachment 5 Atsugi DBB MACC Seed Project Drawing - Enclosure 1; Attachment 5 Atsugi DBB MACC Seed Project Drawing - Enclosure 2. **A pre-proposal conference will be held in English on Tuesday, 25 March 2025 at 1000 Japan Standard Time (JST) at NAVFAC Far East, Building 89, U.S. Naval Facility (NAF) Atsugi, Japan. Site visit of the seed project location will commence immediately after the pre-proposal conference. Participants without base access will require Government escort to attend the site visit and shall submit a request for base access using RFP Attachment 4, Site Visit Request List, no later than 18 March 2025 at 1430 (JST) via email to Ms. Emiko Uyama, Contract Specialist, at emiko.uyama2.ln@us.navy.mil and Ms Teresa Aguon, Contracting Officer, at teresa.f.aguon.civ@us.navy.mil. Failure to request for base access will result in delays or disapproval to access the site location.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"N4008425R0066","place_of_performance":{"city":{"name":"Atsugi"},"country":{"code":"JPN"}},"product_service_code":"Z2JZ"},{"award":{"date":"2025-09-19","amount":"99000000.00","number":"N4008425D0066-N4008425D0069","awardee":{"raw":"KANAGAWA NABCO PTY. LTD. Yokohama-shi JPN","name":"KANAGAWA NABCO PTY. LTD. Yokohama-shi JPN"}},"dates":{"posted":"2025-09-23","award_date":"2025-09-19"},"links":{"sam":"https://sam.gov/workspace/contract/opp/6ff43590ab724b8e9829d957c92bdf54/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Indefinite Delivery/Indefinite Quantity (IDIQ), Design-Bid-Build (DBB), Multiple Award Construction Contract (MACC) for the U.S. Naval Air Facility (NAF), Atsugi, Japan","agency":{"office":{"code":"N40084","name":"NAVFACSYSCOM FAR EAST"},"subtier":{"code":"1700","name":"DEPT OF THE NAVY"},"department":{"code":"017","name":"DEPT OF DEFENSE"},"office_address":{"zip":"96349-0013","city":"FPO","state":"AP","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-10-04","archive_type":"auto15"},"contacts":[{"name":"Emiko Uyama","role":"primary","email":"emiko.uyama2.ln@us.navy.mil","phone":"046-816-2874"},{"name":"Teresa Aguon","role":"secondary","email":"teresa.f.aguon.civ@us.navy.mil","phone":"3152432875"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"6ff43590ab724b8e9829d957c92bdf54","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"83024be5c4c8bea585f3d074945522fff86679f16fe82132aa0195c653e56647","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"In addition to the above contract, subject requirement was awarded to the following contractors as listed below, in the total aggregate Not-To-Exceed (NTE) amount of $99,000,000. This represents the NTE amount for the life of all the contract awrads combined. N40084-25-D-0066, Kanagawa Nabco Pty. Ltd. N40084-25-D-0067, Mitomo Co., LTd. N40084-25-D-0068, Nihon MECCS Co., Ltd. N40084-25-D-0069, Acty Co., Ltd.","origin":"extract"},"notice_type":{"code":"a","label":"Award Notice"},"schema_version":1,"solicitation_number":"N4008425R0066","place_of_performance":{"city":{"name":"Atsugi"},"country":{"code":"JPN"}},"product_service_code":"Z2JZ"}],"due_at":"2025-04-18T05:30:00Z","due_date":"2025-04-18","closes_at":"2025-04-18T05:30:00Z","awardable":false,"dept_key":"d-017","dept_name":"DEPT OF DEFENSE","sub_key":"s-1700","sub_name":"DEPT OF THE NAVY","office_key":"o-N40084","office_name":"NAVFACSYSCOM FAR EAST","state":null,"county":null,"county_name":null,"city":null,"city_name":null,"country":"JPN","winner_key":"HD9KRGNMN5A3","amount":"99000000.00","linked_awards":60,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z","principal_notice_id":"6ff43590ab724b8e9829d957c92bdf54","description":{"text":"In addition to the above contract, subject requirement was awarded to the following contractors as listed below, in the total aggregate Not-To-Exceed (NTE) amount of $99,000,000. This represents the NTE amount for the life of all the contract awrads combined. N40084-25-D-0066, Kanagawa Nabco Pty. Ltd. N40084-25-D-0067, Mitomo Co., LTd. N40084-25-D-0068, Nihon MECCS Co., Ltd. N40084-25-D-0069, Acty Co., Ltd.","html":null,"origin":"extract"},"contacts":[{"name":"Emiko Uyama","role":"primary","email":"emiko.uyama2.ln@us.navy.mil","phone":"046-816-2874"},{"name":"Teresa Aguon","role":"secondary","email":"teresa.f.aguon.civ@us.navy.mil","phone":"3152432875"}],"place_of_performance":{"city":{"name":"Atsugi"},"country":{"code":"JPN"}},"office_address":{"zip":"96349-0013","city":"FPO","state":"AP","country":"USA"},"naics_codes":["236220"],"award":{"date":"2025-09-19","amount":"99000000.00","number":"N4008425D0066-N4008425D0069","awardee":{"raw":"KANAGAWA NABCO PTY. LTD. Yokohama-shi JPN","name":"KANAGAWA NABCO PTY. LTD. Yokohama-shi JPN"}},"attachments":[],"awards":[{"award_key":"CONT_AWD_N4008425F0315_9700_N4008425D0066_9700","permalink":"https://www.usaspending.gov/award/CONT_AWD_N4008425F0315_9700_N4008425D0066_9700/","piid":"N4008425F0315","parent_piid":"N4008425D0066","award_type":"DELIVERY ORDER","vendor_key":"HD9KRGNMN5A3","recipient_name":"KANAGAWA NABCO PTY. LTD.","recipient_uei":"HD9KRGNMN5A3","recipient_cage":"JSS96","recipient_city":"YOKOHAMA-SHI","recipient_state":null,"sub_name":"Department of the Navy","office_name":"NAVFACSYSCOM FAR EAST","office_key":"o-N40084","first_action_date":"2025-09-19","last_action_date":"2026-01-16","actions":2,"obligated":"205856.90","current_total_value":"205856.90","potential_total_value":"205856.90","naics":"236220","psc":"Z2JZ","extent_competed":"FULL AND OPEN COMPETITION","set_aside":null,"offers_received":4,"description":"ATSUGI MINI MACC SEED PROJECT - ATS-84 REPLACE METAL ROOF","method":"solicitation","confidence":"high","evidence":["solicitation number N4008425R0066 equals the FPDS solicitation identifier","same awarding office N40084"],"opportunity_key":null,"opportunity_title":null},{"award_key":"CONT_AWD_N4008425F0372_9700_N4008425D0067_9700","permalink":"https://www.usaspending.gov/award/CONT_AWD_N4008425F0372_9700_N4008425D0067_9700/","piid":"N4008425F0372","parent_piid":"N4008425D0067","award_type":"DELIVERY ORDER","vendor_key":"LGJUANQ5LG56","recipient_name":"MITOMO CO., LTD.","recipient_uei":"LGJUANQ5LG56","recipient_cage":"JSD30","recipient_city":"YOKOHAMA-SHI","recipient_state":null,"sub_name":"Department of the Navy","office_name":"NAVFACSYSCOM FAR EAST","office_key":"o-N40084","first_action_date":"2025-09-19","last_action_date":"2025-09-19","actions":1,"obligated":"2744.76","current_total_value":"2744.76","potential_total_value":"2744.76","naics":"236220","psc":"Z2JZ","extent_competed":"FULL AND OPEN COMPETITION","set_aside":null,"offers_received":4,"description":"ATSUGI MINI MACC - MINIMUM GUARANTEE","method":"solicitation","confidence":"high","evidence":["solicitation number N4008425R0066 equals the FPDS solicitation identifier","same awarding office N40084"],"opportunity_key":null,"opportunity_title":null},{"award_key":"CONT_IDV_N4008425D0067_9700","permalink":"https://www.usaspending.gov/award/CONT_IDV_N4008425D0067_9700/","piid":"N4008425D0067","parent_piid":null,"award_type":null,"vendor_key":"LGJUANQ5LG56","recipient_name":"MITOMO CO., LTD.","recipient_uei":"LGJUANQ5LG56","recipient_cage":"JSD30","recipient_city":"YOKOHAMA-SHI","recipient_state":null,"sub_name":"Department of the Navy","office_name":"NAVFACSYSCOM FAR EAST","office_key":"o-N40084","first_action_date":"2025-09-19","last_action_date":"2025-09-19","actions":1,"obligated":"0","current_total_value":null,"potential_total_value":"99000000.00","naics":"236220","psc":"Z2JZ","extent_competed":"FULL AND OPEN COMPETITION","set_aside":"NO SET ASIDE USED.","offers_received":4,"description":"INDEFINITE DELIVERY/INDEFINITE QUANTITY (IDIQ), DESIGN-BID-BUILD MULTIPLE AWARD CONSTRUCTION CONTRACT (MACC) FOR ATSUGI, JAPAN","method":"solicitation","confidence":"high","evidence":["solicitation number N4008425R0066 equals the FPDS solicitation identifier","same awarding office N40084"],"opportunity_key":null,"opportunity_title":null},{"award_key":"CONT_IDV_N4008425D0068_9700","permalink":"https://www.usaspending.gov/award/CONT_IDV_N4008425D0068_9700/","piid":"N4008425D0068","parent_piid":null,"award_type":null,"vendor_key":"W25NAMCHCS56","recipient_name":"NIHON MECCS CO.,LTD.","recipient_uei":"W25NAMCHCS56","recipient_cage":"JS5K1","recipient_city":"CHUO-KU","recipient_state":null,"sub_name":"Department of the Navy","office_name":"NAVFACSYSCOM FAR EAST","office_key":"o-N40084","first_action_date":"2025-09-19","last_action_date":"2025-09-19","actions":1,"obligated":"0","current_total_value":null,"potential_total_value":"99000000.00","naics":"236220","psc":"Z2JZ","extent_competed":"FULL AND OPEN COMPETITION","set_aside":"NO SET ASIDE USED.","offers_received":4,"description":"INDEFINITE DELIVERY/INDEFINITE QUANTITY (IDIQ), DESIGN-BID-BUILD MULTIPLE AWARD CONSTRUCTION CONTRACT (MACC) FOR ATSUGI, JAPAN","method":"solicitation","confidence":"high","evidence":["solicitation number N4008425R0066 equals the FPDS solicitation identifier","same awarding office N40084"],"opportunity_key":null,"opportunity_title":null}],"related":[{"key":"N4008426Q1017","latest_notice_id":"3bff0cfd501347c691dc80fb7d8feb08","title":"REQUEST FOR QUOTATION NO. N4008426Q1017 PROCUREMENT OF AERIAL PLATFORM FOR NAVAL FACILITIES ENGINEERING SYSTEMS COMMAND FAR EAST","solicitation_number":"N4008426Q1017","notice_type":"k","first_type":"k","first_posted":"2026-08-11","last_posted":"2026-09-16","notices":5,"due_at":"2026-09-25T02:00:00Z","due_date":"2026-09-25","closes_at":"2026-09-25T02:00:00Z","awardable":true,"open":true,"dept_key":"d-017","dept_name":"DEPT OF DEFENSE","sub_key":"s-1700","sub_name":"DEPT OF THE NAVY","office_key":"o-N40084","office_name":"NAVFACSYSCOM FAR EAST","naics":"333924","psc":"2320","set_aside":null,"state":null,"county":null,"county_name":null,"city":null,"city_name":null,"country":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-17T06:28:38.602097Z"},{"key":"N4008426Q1024","latest_notice_id":"96218b0f5a3847c1b1d9b49f2d2344d7","title":"REQUEST FOR QUOTATION NO. N4008426Q1024 PROCUREMENT OF MEDIUM RESCUE VEHICLE FOR CNRJ FIRE DEPARTMENT, COMMANDER FLEET ACTIVITIES SASEBO, JAPAN","solicitation_number":"N4008426Q1024","notice_type":"k","first_type":"k","first_posted":"2026-08-14","last_posted":"2026-09-16","notices":4,"due_at":"2026-10-05T02:00:00Z","due_date":"2026-10-05","closes_at":"2026-10-05T02:00:00Z","awardable":true,"open":true,"dept_key":"d-017","dept_name":"DEPT OF DEFENSE","sub_key":"s-1700","sub_name":"DEPT OF THE NAVY","office_key":"o-N40084","office_name":"NAVFACSYSCOM FAR EAST","naics":"336120","psc":"4210","set_aside":null,"state":null,"county":null,"county_name":null,"city":null,"city_name":null,"country":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-17T06:28:38.602097Z"},{"key":"N4008426Q1023","latest_notice_id":"f4a4b07530bd48fe85c509ca1f3d2db2","title":"REQUEST FOR QUOTATION NO. N4008426Q1023 STRAIGHT VEHICLE LEASE FOR NAVAL CRIMINAL INVESTIGATIVE SERVICE, NAVAL FACILITIES ENGINEERING SYSTEMS COMMAND FAR EAST AREA OF RESPONSIBILITY","solicitation_number":"N4008426Q1023","notice_type":"k","first_type":"k","first_posted":"2026-07-29","last_posted":"2026-09-16","notices":7,"due_at":"2026-10-07T02:00:00Z","due_date":"2026-10-07","closes_at":"2026-10-07T02:00:00Z","awardable":true,"open":true,"dept_key":"d-017","dept_name":"DEPT OF DEFENSE","sub_key":"s-1700","sub_name":"DEPT OF THE NAVY","office_key":"o-N40084","office_name":"NAVFACSYSCOM FAR EAST","naics":"532112","psc":"W023","set_aside":null,"state":null,"county":null,"county_name":null,"city":null,"city_name":null,"country":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-17T06:28:38.602097Z"},{"key":"N4008426R7500","latest_notice_id":"500e7efc8cd040b18ea19a2338b7fc43","title":"N4008426R7500 DB RMAC FACILITY IMPROVEMENT AT NETDC, SAN ANTONIO, ZAMBALES, PHILIPPINES","solicitation_number":"N4008426R7500","notice_type":"o","first_type":"p","first_posted":"2026-06-08","last_posted":"2026-09-15","notices":7,"due_at":"2026-10-09T04:00:00Z","due_date":"2026-10-09","closes_at":"2026-10-09T04:00:00Z","awardable":true,"open":true,"dept_key":"d-017","dept_name":"DEPT OF DEFENSE","sub_key":"s-1700","sub_name":"DEPT OF THE NAVY","office_key":"o-N40084","office_name":"NAVFACSYSCOM FAR EAST","naics":"236220","psc":"Y1JZ","set_aside":null,"state":null,"county":null,"county_name":null,"city":null,"city_name":null,"country":"PHL","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-17T06:28:38.602097Z"},{"key":"N4008426Q1022","latest_notice_id":"2e97044a96a54c15800c2367db69ef76","title":"REQUEST FOR QUOTATION NO. N4008426Q1022 PROCUREMENT OF CRANES FOR NAVFAC FAR EAST","solicitation_number":"N4008426Q1022","notice_type":"k","first_type":"k","first_posted":"2026-09-16","last_posted":"2026-09-16","notices":1,"due_at":"2026-10-16T02:00:00Z","due_date":"2026-10-16","closes_at":"2026-10-16T02:00:00Z","awardable":true,"open":true,"dept_key":"d-017","dept_name":"DEPT OF DEFENSE","sub_key":"s-1700","sub_name":"DEPT OF THE NAVY","office_key":"o-N40084","office_name":"NAVFACSYSCOM FAR EAST","naics":"333120","psc":"3810","set_aside":null,"state":null,"county":null,"county_name":null,"city":null,"city_name":null,"country":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-17T06:28:38.602097Z"}]}