{"canonical":"https://abierto.us/opportunities/fa667025b0002","key":"FA667025B0002","url":"https://abierto.us/opportunities/fa667025b0002","title":"Repair Airfield Pavement Spalling","solicitation_number":"FA667025B0002","notice_type":"a","open":false,"response_deadline":"2025-08-26T18:00:00Z","first_posted":"2025-06-05","last_posted":"2025-10-01","department":"DEPT OF DEFENSE","subagency":"DEPT OF THE AIR FORCE","office":"FA6670 914 AW LGC","naics":"237310","psc":"Z1BD","set_aside":"SDVOSBC","place_state":"NY","place_county":"36063","place_county_name":"Niagara County","place_city":"3651055","place_city_name":"Niagara Falls","winner":"INDUSTRY STANDARD USA, LLC","award_amount":"1286200.00","publications":[{"notice_id":"234ef16439054bd1b185bbee27459bb7","title":"Repair Airfield Pavement Spalling","solicitation_number":"FA6670-25-B-0002","notice_type":"p","base_type":"p","posted":"2025-06-05","posted_at":null,"due_at":null,"due_date":null,"cancelled":null,"archived":null,"archive_date":"2025-07-08","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/234ef16439054bd1b185bbee27459bb7/view","enriched":false,"history":[]},{"notice_id":"2579c65a98714a6f85dc06bf73ab21fa","title":"Repair Airfield Pavement Spalling","solicitation_number":"FA6670-25-B-0002","notice_type":"p","base_type":"p","posted":"2025-06-05","posted_at":null,"due_at":null,"due_date":null,"cancelled":null,"archived":null,"archive_date":"2025-08-15","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/2579c65a98714a6f85dc06bf73ab21fa/view","enriched":false,"history":[]},{"notice_id":"0fa6340294804dc78947d1b686ca8a3b","title":"Repair Airfield Pavement Spalling","solicitation_number":"FA667025B0002","notice_type":"o","base_type":"p","posted":"2025-07-08","posted_at":null,"due_at":"2025-08-08T18:00:00Z","due_date":"2025-08-08","cancelled":null,"archived":null,"archive_date":"2025-09-01","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/0fa6340294804dc78947d1b686ca8a3b/view","enriched":false,"history":[]},{"notice_id":"991ada0845cf401c8be0f848f618b7f1","title":"Repair Airfield Pavement Spalling","solicitation_number":"FA667025B0002","notice_type":"o","base_type":"o","posted":"2025-07-30","posted_at":null,"due_at":"2025-08-12T18:00:00Z","due_date":"2025-08-12","cancelled":null,"archived":null,"archive_date":"2025-09-01","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/991ada0845cf401c8be0f848f618b7f1/view","enriched":false,"history":[]},{"notice_id":"da5aac19bfea4e768ceaf87172cd78d1","title":"Repair Airfield Pavement Spalling","solicitation_number":"FA667025B0002","notice_type":"o","base_type":"o","posted":"2025-08-12","posted_at":null,"due_at":"2025-08-21T18:00:00Z","due_date":"2025-08-21","cancelled":null,"archived":null,"archive_date":"2025-09-15","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/da5aac19bfea4e768ceaf87172cd78d1/view","enriched":false,"history":[]},{"notice_id":"7cf726fb57ab4435803d8ff2e72e7bac","title":"Repair Airfield Pavement Spalling","solicitation_number":"FA667025B0002","notice_type":"o","base_type":"o","posted":"2025-08-20","posted_at":null,"due_at":"2025-08-26T18:00:00Z","due_date":"2025-08-26","cancelled":null,"archived":null,"archive_date":"2025-09-15","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/7cf726fb57ab4435803d8ff2e72e7bac/view","enriched":false,"history":[]},{"notice_id":"8721ce2e66b946f8919482586b89fba9","title":"Repair Airfield Pavement Spalling","solicitation_number":"FA667025B0002","notice_type":"o","base_type":"o","posted":"2025-08-20","posted_at":null,"due_at":"2025-08-26T18:00:00Z","due_date":"2025-08-26","cancelled":null,"archived":null,"archive_date":"2025-09-15","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/8721ce2e66b946f8919482586b89fba9/view","enriched":false,"history":[]},{"notice_id":"9e1fd314babb46cc99e7c9f4338cc52a","title":"Repair Airfield Pavement Spalling","solicitation_number":"FA667025B0002","notice_type":"o","base_type":"o","posted":"2025-09-02","posted_at":null,"due_at":"2025-08-26T18:00:00Z","due_date":"2025-08-26","cancelled":null,"archived":null,"archive_date":"2025-09-15","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/9e1fd314babb46cc99e7c9f4338cc52a/view","enriched":false,"history":[]},{"notice_id":"164ef97193134a458aa25141e4f3a4a2","title":"Repair Airfield Pavement Spalling","solicitation_number":"FA667025B0002","notice_type":"o","base_type":"o","posted":"2025-10-01","posted_at":null,"due_at":"2025-08-26T18:00:00Z","due_date":"2025-08-26","cancelled":null,"archived":null,"archive_date":"2025-10-01","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/164ef97193134a458aa25141e4f3a4a2/view","enriched":false,"history":[]},{"notice_id":"3cd11767a83548a282668d07494f733b","title":"Repair Airfield Pavement Spalling","solicitation_number":"FA667025B0002","notice_type":"o","base_type":"o","posted":"2025-10-01","posted_at":null,"due_at":"2025-08-26T18:00:00Z","due_date":"2025-08-26","cancelled":null,"archived":null,"archive_date":"2025-10-15","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/3cd11767a83548a282668d07494f733b/view","enriched":false,"history":[]},{"notice_id":"72f8b84bf43b4193b8d18f9d869b2810","title":"Repair Airfield Pavement Spalling","solicitation_number":"FA667025B0002","notice_type":"a","base_type":"o","posted":"2025-10-01","posted_at":null,"due_at":null,"due_date":null,"cancelled":null,"archived":null,"archive_date":"2025-10-15","award_number":"FA667025C0002","awardee_name":"INDUSTRY STANDARD USA, LLC Liverpool","amount":"1286200.00","link_sam":"https://sam.gov/workspace/contract/opp/72f8b84bf43b4193b8d18f9d869b2810/view","enriched":false,"history":[]}],"latest_notice_id":"72f8b84bf43b4193b8d18f9d869b2810","first_type":"p","notices":[{"dates":{"posted":"2025-06-05"},"links":{"sam":"https://sam.gov/workspace/contract/opp/234ef16439054bd1b185bbee27459bb7/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Repair Airfield Pavement Spalling","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-07-08","archive_type":"manual"},"contacts":[{"name":"Senthan Mahendrarasa","role":"primary","email":"senthan.mahendrarasa@us.af.mil"},{"name":"Mary Elizabeth Pyle Platts","role":"secondary","email":"mary.pyleplatts@us.af.mil"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"234ef16439054bd1b185bbee27459bb7","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"244cd8021729151d0ac73df98e2ac872646f112891b62e670b49bc16cabd4301","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"This is a Pre-Solicitation Notice. This notice does NOT constitute a request for proposal, request for quote or invitation for bid. Estimated issue date for the solicitation is on or after 20 June 2025, with the solicitation closing approximately 30 days thereafter. It will be issued electronically at the Beta Sam website https://beta.sam.gov under the reference number FA6670-25-B-0002. Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair Airfield Pavement Spalling. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 20-0770 Repair Airfield Pavement Spalling, to include the following: Repair airfield PCC pavement spalling in areas of the Aircraft Main Apron and Taxiway Alpha. Repair work includes Patching Full Depth and Partial Depth, Joint Seal, Crack Seal, and Slab/Panel Replacement at PCC pavement. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 360 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.14. The estimated magnitude of construction is between $1,000,000 and $5,000,000. The NAICS code is 237310 and the Small Business Size Standard is $45,000,000. Electronic bid submissions will not be accepted or returned. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://beta.sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.","origin":"extract"},"notice_type":{"code":"p","label":"Presolicitation"},"schema_version":1,"solicitation_number":"FA6670-25-B-0002","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"},{"dates":{"posted":"2025-06-05"},"links":{"sam":"https://sam.gov/workspace/contract/opp/2579c65a98714a6f85dc06bf73ab21fa/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Repair Airfield Pavement Spalling","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-08-15","archive_type":"auto_custom"},"contacts":[{"name":"Senthan Mahendrarasa","role":"primary","email":"senthan.mahendrarasa@us.af.mil"},{"name":"Mary Elizabeth Pyle Platts","role":"secondary","email":"mary.pyleplatts@us.af.mil"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"2579c65a98714a6f85dc06bf73ab21fa","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"6929309cf7805ce1197fdc123c7d8f43d3772886ff013ba384c814e9012e16ea","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"This is a Pre-Solicitation Notice. This notice does NOT constitute a request for proposal, request for quote or invitation for bid. Estimated issue date for the solicitation is on or after 20 June 2025, with the solicitation closing approximately 30 days thereafter. It will be issued electronically at the Beta Sam website https://beta.sam.gov under the reference number FA6670-25-B-0002. Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair Airfield Pavement Spalling. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 20-0770 Repair Airfield Pavement Spalling, to include the following: Repair airfield PCC pavement spalling in areas of the Aircraft Main Apron and Taxiway Alpha. Repair work includes Patching Full Depth and Partial Depth, Joint Seal, Crack Seal, and Slab/Panel Replacement at PCC pavement. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 360 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.14. The estimated magnitude of construction is between $1,000,000 and $5,000,000. The NAICS code is 237310 and the Small Business Size Standard is $45,000,000. Electronic bid submissions will not be accepted or returned. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://beta.sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.","origin":"extract"},"notice_type":{"code":"p","label":"Presolicitation"},"schema_version":1,"solicitation_number":"FA6670-25-B-0002","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"},{"dates":{"posted":"2025-07-08","response_deadline":{"raw":"2025-08-08T14:00:00-04:00","utc":"2025-08-08T18:00:00Z","date":"2025-08-08","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/0fa6340294804dc78947d1b686ca8a3b/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Repair Airfield Pavement Spalling","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-09-01","archive_type":"auto_custom"},"contacts":[{"name":"Senthan Mahendrarasa","role":"primary","email":"senthan.mahendrarasa@us.af.mil"},{"name":"Mary Elizabeth Pyle Platts","role":"secondary","email":"mary.pyleplatts@us.af.mil"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"0fa6340294804dc78947d1b686ca8a3b","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"d7be2a378ebeb7e84c0cb6f2d84f4d4aff1ece9470c3c4c04b14b95444701684","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair Airfield Pavement Spalling. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 20-0770 Repair Airfield Pavement Spalling, to include the following: Repair airfield PCC pavement spalling in areas of the Aircraft Main Apron and Taxiway Alpha. Repair work includes Patching Full Depth and Partial Depth, Joint Seal, Crack Seal, and Slab/Panel Replacement at PCC pavement. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 360 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.14. The estimated magnitude of construction is between $1,000,000 and $5,000,000. The NAICS code is 237310 and the Small Business Size Standard is $45,000,000. Electronic bid submissions will not be accepted or returned. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://beta.sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"FA667025B0002","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"},{"dates":{"posted":"2025-07-30","response_deadline":{"raw":"2025-08-12T14:00:00-04:00","utc":"2025-08-12T18:00:00Z","date":"2025-08-12","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/991ada0845cf401c8be0f848f618b7f1/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Repair Airfield Pavement Spalling","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-09-01","archive_type":"auto_custom"},"contacts":[{"name":"Senthan Mahendrarasa","role":"primary","email":"senthan.mahendrarasa@us.af.mil"},{"name":"Mary Elizabeth Pyle Platts","role":"secondary","email":"mary.pyleplatts@us.af.mil"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"991ada0845cf401c8be0f848f618b7f1","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"dd9e60510d530be446627d8af96621671287292f7de360ba51975b903863662c","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"30 July 2025 Uploaded to Attachments section - - Amendment 1, dtd 30 July 2025 - Addendum 1, dtd 24 July 2025 - Revised Davis Bacon H&H, 25 July 2025 - Site Visit Sign In Sheet - Question and Answers - AF IMT 3000 - Material Approval Submittal Bid Closing date has been extended. ___________________________________________________________________ Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair Airfield Pavement Spalling. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 20-0770 Repair Airfield Pavement Spalling, to include the following: Repair airfield PCC pavement spalling in areas of the Aircraft Main Apron and Taxiway Alpha. Repair work includes Patching Full Depth and Partial Depth, Joint Seal, Crack Seal, and Slab/Panel Replacement at PCC pavement. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 360 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.14. The estimated magnitude of construction is between $1,000,000 and $5,000,000. The NAICS code is 237310 and the Small Business Size Standard is $45,000,000. Electronic bid submissions will not be accepted or returned. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://beta.sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"FA667025B0002","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"},{"dates":{"posted":"2025-08-12","response_deadline":{"raw":"2025-08-21T14:00:00-04:00","utc":"2025-08-21T18:00:00Z","date":"2025-08-21","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/da5aac19bfea4e768ceaf87172cd78d1/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Repair Airfield Pavement Spalling","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-09-15","archive_type":"auto_custom"},"contacts":[{"name":"Senthan Mahendrarasa","role":"primary","email":"senthan.mahendrarasa@us.af.mil"},{"name":"Mary Elizabeth Pyle Platts","role":"secondary","email":"mary.pyleplatts@us.af.mil"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"da5aac19bfea4e768ceaf87172cd78d1","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"2cb24b5a0bb0753d7f7d7a79f63f0f5e95e935907673e9008b7a6ec1addbc7f4","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"12 August 2025 Uploaded to Attachments section - - Amendment 2, dtd 12 August 2025 Bid Closing date has been extended - bid closing is now on Thursday 21 August 2025 at 2 pm EDT. _______________________________________________________________________ 30 July 2025 Uploaded to Attachments section - - Amendment 1, dtd 30 July 2025 - Addendum 1, dtd 24 July 2025 - Revised Davis Bacon H&H, 25 July 2025 - Site Visit Sign In Sheet - Question and Answers - AF IMT 3000 - Material Approval Submittal Bid Closing date has been extended. ___________________________________________________________________ Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair Airfield Pavement Spalling. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 20-0770 Repair Airfield Pavement Spalling, to include the following: Repair airfield PCC pavement spalling in areas of the Aircraft Main Apron and Taxiway Alpha. Repair work includes Patching Full Depth and Partial Depth, Joint Seal, Crack Seal, and Slab/Panel Replacement at PCC pavement. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 360 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.14. The estimated magnitude of construction is between $1,000,000 and $5,000,000. The NAICS code is 237310 and the Small Business Size Standard is $45,000,000. Electronic bid submissions will not be accepted or returned. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://beta.sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"FA667025B0002","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"},{"dates":{"posted":"2025-08-20","response_deadline":{"raw":"2025-08-26T14:00:00-04:00","utc":"2025-08-26T18:00:00Z","date":"2025-08-26","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/7cf726fb57ab4435803d8ff2e72e7bac/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Repair Airfield Pavement Spalling","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-09-15","archive_type":"auto_custom"},"contacts":[{"name":"Senthan Mahendrarasa","role":"primary","email":"senthan.mahendrarasa@us.af.mil"},{"name":"Mary Elizabeth Pyle Platts","role":"secondary","email":"mary.pyleplatts@us.af.mil"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"7cf726fb57ab4435803d8ff2e72e7bac","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"c5cc1b950d43ef825e840797982ae3c1d58e83996619044f0a15efd4a609edcf","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"20 August 2025 Uploaded to Attachments section - - Q and A Set 2 dtd 19 Aug 2025 Bid Closing date has been extended - bid closing is now on Tuesday 26 August 2025 at 2 pm EDT. _______________________________________________________________________ 12 August 2025 Uploaded to Attachments section - - Amendment 2, dtd 12 August 2025 Bid Closing date has been extended - bid closing is now on Thursday 21 August 2025 at 2 pm EDT. _______________________________________________________________________ 30 July 2025 Uploaded to Attachments section - - Amendment 1, dtd 30 July 2025 - Addendum 1, dtd 24 July 2025 - Revised Davis Bacon H&H, 25 July 2025 - Site Visit Sign In Sheet - Question and Answers - AF IMT 3000 - Material Approval Submittal Bid Closing date has been extended. ___________________________________________________________________ Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair Airfield Pavement Spalling. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 20-0770 Repair Airfield Pavement Spalling, to include the following: Repair airfield PCC pavement spalling in areas of the Aircraft Main Apron and Taxiway Alpha. Repair work includes Patching Full Depth and Partial Depth, Joint Seal, Crack Seal, and Slab/Panel Replacement at PCC pavement. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 360 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.14. The estimated magnitude of construction is between $1,000,000 and $5,000,000. The NAICS code is 237310 and the Small Business Size Standard is $45,000,000. Electronic bid submissions will not be accepted or returned. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://beta.sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"FA667025B0002","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"},{"dates":{"posted":"2025-08-20","response_deadline":{"raw":"2025-08-26T14:00:00-04:00","utc":"2025-08-26T18:00:00Z","date":"2025-08-26","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/8721ce2e66b946f8919482586b89fba9/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Repair Airfield Pavement Spalling","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-09-15","archive_type":"auto_custom"},"contacts":[{"name":"Senthan Mahendrarasa","role":"primary","email":"senthan.mahendrarasa@us.af.mil"},{"name":"Mary Elizabeth Pyle Platts","role":"secondary","email":"mary.pyleplatts@us.af.mil"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"8721ce2e66b946f8919482586b89fba9","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"cd0d6859a06a06144d5c6e2d14080b15a20bcaf617ec347def117f1c25f50feb","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"20 August 2025 Uploaded to Attachments section - - Q and A Set 2 dtd 19 Aug 2025 - Amendment 3 - Repair Airfield Pavement Spalling RVKQ 20-0770 19 Aug 2025 - Attach 1 - NFARS_Repair Airfield Pavement_Specs rev 19 August 2025 - Attach 2 - NFARS_Repair Airfield Pavement_Plans_rev19Aug2025 - Attach 3 - DBA NY20250011 H and H 8 Aug 2025 - Attach 7 - Addendum 2 - Repair Airfield Pavement Spalling RVKQ 20-0770 dtd 14 Aug 2025 Bid Closing date has been extended - bid closing is now on Tuesday 26 August 2025 at 2 pm EDT. _______________________________________________________________________ 12 August 2025 Uploaded to Attachments section - - Amendment 2, dtd 12 August 2025 Bid Closing date has been extended - bid closing is now on Thursday 21 August 2025 at 2 pm EDT. _______________________________________________________________________ 30 July 2025 Uploaded to Attachments section - - Amendment 1, dtd 30 July 2025 - Addendum 1, dtd 24 July 2025 - Revised Davis Bacon H&H, 25 July 2025 - Site Visit Sign In Sheet - Question and Answers - AF IMT 3000 - Material Approval Submittal Bid Closing date has been extended. ___________________________________________________________________ Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair Airfield Pavement Spalling. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 20-0770 Repair Airfield Pavement Spalling, to include the following: Repair airfield PCC pavement spalling in areas of the Aircraft Main Apron and Taxiway Alpha. Repair work includes Patching Full Depth and Partial Depth, Joint Seal, Crack Seal, and Slab/Panel Replacement at PCC pavement. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 360 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.14. The estimated magnitude of construction is between $1,000,000 and $5,000,000. The NAICS code is 237310 and the Small Business Size Standard is $45,000,000. Electronic bid submissions will not be accepted or returned. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://beta.sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"FA667025B0002","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"},{"dates":{"posted":"2025-09-02","response_deadline":{"raw":"2025-08-26T14:00:00-04:00","utc":"2025-08-26T18:00:00Z","date":"2025-08-26","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/9e1fd314babb46cc99e7c9f4338cc52a/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Repair Airfield Pavement Spalling","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-09-15","archive_type":"auto_custom"},"contacts":[{"name":"Senthan Mahendrarasa","role":"primary","email":"senthan.mahendrarasa@us.af.mil"},{"name":"Mary Elizabeth Pyle Platts","role":"secondary","email":"mary.pyleplatts@us.af.mil"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"9e1fd314babb46cc99e7c9f4338cc52a","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"f6cd84a0ef3a6809a047ac3b4e58653e1f02a11ebc2b29cedcf1caea3fecaec9","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"2 September 2025 Uploaded to Attachments section - - Spalling - ABSTRACT OF OFFERS - 26 Aug 2025 - Spalling - Bid Opening Sign In Sheet 26 Aug 2025 _______________________________________________________________________ 20 August 2025 Uploaded to Attachments section - - Q and A Set 2 dtd 19 Aug 2025 - Amendment 3 - Repair Airfield Pavement Spalling RVKQ 20-0770 19 Aug 2025 - Attach 1 - NFARS_Repair Airfield Pavement_Specs rev 19 August 2025 - Attach 2 - NFARS_Repair Airfield Pavement_Plans_rev19Aug2025 - Attach 3 - DBA NY20250011 H and H 8 Aug 2025 - Attach 7 - Addendum 2 - Repair Airfield Pavement Spalling RVKQ 20-0770 dtd 14 Aug 2025 Bid Closing date has been extended - bid closing is now on Tuesday 26 August 2025 at 2 pm EDT. _______________________________________________________________________ 12 August 2025 Uploaded to Attachments section - - Amendment 2, dtd 12 August 2025 Bid Closing date has been extended - bid closing is now on Thursday 21 August 2025 at 2 pm EDT. _______________________________________________________________________ 30 July 2025 Uploaded to Attachments section - - Amendment 1, dtd 30 July 2025 - Addendum 1, dtd 24 July 2025 - Revised Davis Bacon H&H, 25 July 2025 - Site Visit Sign In Sheet - Question and Answers - AF IMT 3000 - Material Approval Submittal Bid Closing date has been extended. ___________________________________________________________________ Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair Airfield Pavement Spalling. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 20-0770 Repair Airfield Pavement Spalling, to include the following: Repair airfield PCC pavement spalling in areas of the Aircraft Main Apron and Taxiway Alpha. Repair work includes Patching Full Depth and Partial Depth, Joint Seal, Crack Seal, and Slab/Panel Replacement at PCC pavement. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 360 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.14. The estimated magnitude of construction is between $1,000,000 and $5,000,000. The NAICS code is 237310 and the Small Business Size Standard is $45,000,000. Electronic bid submissions will not be accepted or returned. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://beta.sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"FA667025B0002","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"},{"dates":{"posted":"2025-10-01","response_deadline":{"raw":"2025-08-26T14:00:00-04:00","utc":"2025-08-26T18:00:00Z","date":"2025-08-26","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/164ef97193134a458aa25141e4f3a4a2/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Repair Airfield Pavement Spalling","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-10-01","archive_type":"manual"},"contacts":[{"name":"Senthan Mahendrarasa","role":"primary","email":"senthan.mahendrarasa@us.af.mil"},{"name":"Mary Elizabeth Pyle Platts","role":"secondary","email":"mary.pyleplatts@us.af.mil"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"164ef97193134a458aa25141e4f3a4a2","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T17:48:36.003679Z","row_sha256":"585b678280badbc20564f0faeebf84596b828e4024c99b9481c27c1ebd05fd3a","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T17:48:36.003679Z","first_seen_at":"2026-09-16T17:48:36.003679Z"},"description":{"text":"2 September 2025 Uploaded to Attachments section - - Spalling - ABSTRACT OF OFFERS - 26 Aug 2025 - Spalling - Bid Opening Sign In Sheet 26 Aug 2025 _______________________________________________________________________ 20 August 2025 Uploaded to Attachments section - - Q and A Set 2 dtd 19 Aug 2025 - Amendment 3 - Repair Airfield Pavement Spalling RVKQ 20-0770 19 Aug 2025 - Attach 1 - NFARS_Repair Airfield Pavement_Specs rev 19 August 2025 - Attach 2 - NFARS_Repair Airfield Pavement_Plans_rev19Aug2025 - Attach 3 - DBA NY20250011 H and H 8 Aug 2025 - Attach 7 - Addendum 2 - Repair Airfield Pavement Spalling RVKQ 20-0770 dtd 14 Aug 2025 Bid Closing date has been extended - bid closing is now on Tuesday 26 August 2025 at 2 pm EDT. _______________________________________________________________________ 12 August 2025 Uploaded to Attachments section - - Amendment 2, dtd 12 August 2025 Bid Closing date has been extended - bid closing is now on Thursday 21 August 2025 at 2 pm EDT. _______________________________________________________________________ 30 July 2025 Uploaded to Attachments section - - Amendment 1, dtd 30 July 2025 - Addendum 1, dtd 24 July 2025 - Revised Davis Bacon H&H, 25 July 2025 - Site Visit Sign In Sheet - Question and Answers - AF IMT 3000 - Material Approval Submittal Bid Closing date has been extended. ___________________________________________________________________ Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair Airfield Pavement Spalling. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 20-0770 Repair Airfield Pavement Spalling, to include the following: Repair airfield PCC pavement spalling in areas of the Aircraft Main Apron and Taxiway Alpha. Repair work includes Patching Full Depth and Partial Depth, Joint Seal, Crack Seal, and Slab/Panel Replacement at PCC pavement. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 360 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.14. The estimated magnitude of construction is between $1,000,000 and $5,000,000. The NAICS code is 237310 and the Small Business Size Standard is $45,000,000. Electronic bid submissions will not be accepted or returned. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://beta.sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"FA667025B0002","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"},{"dates":{"posted":"2025-10-01","response_deadline":{"raw":"2025-08-26T14:00:00-04:00","utc":"2025-08-26T18:00:00Z","date":"2025-08-26","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/3cd11767a83548a282668d07494f733b/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Repair Airfield Pavement Spalling","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-10-15","archive_type":"auto_custom"},"contacts":[{"name":"Senthan Mahendrarasa","role":"primary","email":"senthan.mahendrarasa@us.af.mil"},{"name":"Mary Elizabeth Pyle Platts","role":"secondary","email":"mary.pyleplatts@us.af.mil"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"3cd11767a83548a282668d07494f733b","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T17:48:36.003679Z","row_sha256":"1a8b235139ef31970f22722c474ae4f2f25d03ad59a43fa7b604dd58ffb933d9","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T17:48:36.003679Z","first_seen_at":"2026-09-16T17:48:36.003679Z"},"description":{"text":"2 September 2025 Uploaded to Attachments section - - Spalling - ABSTRACT OF OFFERS - 26 Aug 2025 - Spalling - Bid Opening Sign In Sheet 26 Aug 2025 _______________________________________________________________________ 20 August 2025 Uploaded to Attachments section - - Q and A Set 2 dtd 19 Aug 2025 - Amendment 3 - Repair Airfield Pavement Spalling RVKQ 20-0770 19 Aug 2025 - Attach 1 - NFARS_Repair Airfield Pavement_Specs rev 19 August 2025 - Attach 2 - NFARS_Repair Airfield Pavement_Plans_rev19Aug2025 - Attach 3 - DBA NY20250011 H and H 8 Aug 2025 - Attach 7 - Addendum 2 - Repair Airfield Pavement Spalling RVKQ 20-0770 dtd 14 Aug 2025 Bid Closing date has been extended - bid closing is now on Tuesday 26 August 2025 at 2 pm EDT. _______________________________________________________________________ 12 August 2025 Uploaded to Attachments section - - Amendment 2, dtd 12 August 2025 Bid Closing date has been extended - bid closing is now on Thursday 21 August 2025 at 2 pm EDT. _______________________________________________________________________ 30 July 2025 Uploaded to Attachments section - - Amendment 1, dtd 30 July 2025 - Addendum 1, dtd 24 July 2025 - Revised Davis Bacon H&H, 25 July 2025 - Site Visit Sign In Sheet - Question and Answers - AF IMT 3000 - Material Approval Submittal Bid Closing date has been extended. ___________________________________________________________________ Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair Airfield Pavement Spalling. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 20-0770 Repair Airfield Pavement Spalling, to include the following: Repair airfield PCC pavement spalling in areas of the Aircraft Main Apron and Taxiway Alpha. Repair work includes Patching Full Depth and Partial Depth, Joint Seal, Crack Seal, and Slab/Panel Replacement at PCC pavement. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 360 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.14. The estimated magnitude of construction is between $1,000,000 and $5,000,000. The NAICS code is 237310 and the Small Business Size Standard is $45,000,000. Electronic bid submissions will not be accepted or returned. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://beta.sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"FA667025B0002","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"},{"award":{"date":"2025-09-30","amount":"1286200.00","number":"FA667025C0002","awardee":{"raw":"INDUSTRY STANDARD USA, LLC Liverpool NY 13090 USA","name":"INDUSTRY STANDARD USA, LLC Liverpool","location":{"zip":"13090","state":{"code":"NY"},"country":{"code":"USA"}}}},"dates":{"posted":"2025-10-01","award_date":"2025-09-30"},"links":{"sam":"https://sam.gov/workspace/contract/opp/72f8b84bf43b4193b8d18f9d869b2810/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Repair Airfield Pavement Spalling","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-10-15","archive_type":"auto15"},"contacts":[{"name":"Senthan Mahendrarasa","role":"primary","email":"senthan.mahendrarasa@us.af.mil"},{"name":"Mary Elizabeth Pyle Platts","role":"secondary","email":"mary.pyleplatts@us.af.mil"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"72f8b84bf43b4193b8d18f9d869b2810","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T17:48:36.003679Z","row_sha256":"f7594fd0cc2cc8d52a5fa55e462629296351b6c5f20dfb97936e96a16b4d2c98","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T17:48:36.003679Z","first_seen_at":"2026-09-16T17:48:36.003679Z"},"notice_type":{"code":"a","label":"Award Notice"},"schema_version":1,"solicitation_number":"FA667025B0002","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"}],"due_at":"2025-08-26T18:00:00Z","due_date":"2025-08-26","closes_at":"2025-08-26T18:00:00Z","awardable":false,"dept_key":"d-057","dept_name":"DEPT OF DEFENSE","sub_key":"s-5700","sub_name":"DEPT OF THE AIR FORCE","office_key":"o-FA6670","office_name":"FA6670 914 AW LGC","state":"NY","county":"36063","county_name":"Niagara County","city":"3651055","city_name":"Niagara Falls","country":"USA","winner_key":"UB1AD28JBZJ4","amount":"1286200.00","linked_awards":11,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z","principal_notice_id":"3cd11767a83548a282668d07494f733b","description":{"text":"2 September 2025 Uploaded to Attachments section - - Spalling - ABSTRACT OF OFFERS - 26 Aug 2025 - Spalling - Bid Opening Sign In Sheet 26 Aug 2025 _______________________________________________________________________ 20 August 2025 Uploaded to Attachments section - - Q and A Set 2 dtd 19 Aug 2025 - Amendment 3 - Repair Airfield Pavement Spalling RVKQ 20-0770 19 Aug 2025 - Attach 1 - NFARS_Repair Airfield Pavement_Specs rev 19 August 2025 - Attach 2 - NFARS_Repair Airfield Pavement_Plans_rev19Aug2025 - Attach 3 - DBA NY20250011 H and H 8 Aug 2025 - Attach 7 - Addendum 2 - Repair Airfield Pavement Spalling RVKQ 20-0770 dtd 14 Aug 2025 Bid Closing date has been extended - bid closing is now on Tuesday 26 August 2025 at 2 pm EDT. _______________________________________________________________________ 12 August 2025 Uploaded to Attachments section - - Amendment 2, dtd 12 August 2025 Bid Closing date has been extended - bid closing is now on Thursday 21 August 2025 at 2 pm EDT. _______________________________________________________________________ 30 July 2025 Uploaded to Attachments section - - Amendment 1, dtd 30 July 2025 - Addendum 1, dtd 24 July 2025 - Revised Davis Bacon H&H, 25 July 2025 - Site Visit Sign In Sheet - Question and Answers - AF IMT 3000 - Material Approval Submittal Bid Closing date has been extended. ___________________________________________________________________ Niagara Falls Air Reserve Station has a requirement for a Construction project, Repair Airfield Pavement Spalling. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, RVKQ 20-0770 Repair Airfield Pavement Spalling, to include the following: Repair airfield PCC pavement spalling in areas of the Aircraft Main Apron and Taxiway Alpha. Repair work includes Patching Full Depth and Partial Depth, Joint Seal, Crack Seal, and Slab/Panel Replacement at PCC pavement. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 360 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service-Disabled Veteran-Owned Small Business, concerns IAW FAR Subpart 19.14. The estimated magnitude of construction is between $1,000,000 and $5,000,000. The NAICS code is 237310 and the Small Business Size Standard is $45,000,000. Electronic bid submissions will not be accepted or returned. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://beta.sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the Federal Business Opportunities website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.","html":null,"origin":"extract"},"contacts":[{"name":"Senthan Mahendrarasa","role":"primary","email":"senthan.mahendrarasa@us.af.mil"},{"name":"Mary Elizabeth Pyle Platts","role":"secondary","email":"mary.pyleplatts@us.af.mil"}],"place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"naics_codes":["237310"],"award":null,"attachments":[],"awards":[{"award_key":"CONT_AWD_FA667025C0002_9700_-NONE-_-NONE-","permalink":"https://www.usaspending.gov/award/CONT_AWD_FA667025C0002_9700_-NONE-_-NONE-/","piid":"FA667025C0002","parent_piid":null,"award_type":"DEFINITIVE CONTRACT","vendor_key":"UB1AD28JBZJ4","recipient_name":"INDUSTRY STANDARD USA, LLC","recipient_uei":"UB1AD28JBZJ4","recipient_cage":"5ZK97","recipient_city":"LIVERPOOL","recipient_state":"NY","sub_name":"Department of the Air Force","office_name":"FA6670 914 AW LGC","office_key":"o-FA6670","first_action_date":"2025-09-30","last_action_date":"2025-09-30","actions":1,"obligated":"1286200.00","current_total_value":"1286200.00","potential_total_value":"1286200.00","naics":"237310","psc":"Z1BD","extent_competed":"FULL AND OPEN COMPETITION AFTER EXCLUSION OF SOURCES","set_aside":"SERVICE DISABLED VETERAN OWNED SMALL BUSINESS SET-ASIDE","offers_received":7,"description":"RVKQ 20-0770 REPAIR AIRFIELD PAVEMENT SPALLING; THE CONTRACTOR SHALL FURNISH ALL LABOR, MATERIALS, EQUIPMENT AND MISCELLANEOUS SERVICES TO ACCOMPLISH THIS WORK IN STRICT ACCORDANCE WITH THE SPECIFICATIONS, DRAWINGS AND ALL ASSOCIATED DOCUMENTS.","method":"solicitation","confidence":"high","evidence":["solicitation number FA667025B0002 equals the FPDS solicitation identifier","same awarding office FA6670"],"opportunity_key":null,"opportunity_title":null}],"related":[{"key":"FA667026Q0015","latest_notice_id":"4871181e002742f6b12fda70c8892518","title":"2026 SABER IDIQ - (Simplified Acquisition of Base Engineering Requirements)","solicitation_number":"FA667026Q0015","notice_type":"k","first_type":"k","first_posted":"2026-08-13","last_posted":"2026-09-14","notices":3,"due_at":"2026-09-17T17:00:00Z","due_date":"2026-09-17","closes_at":"2026-09-17T17:00:00Z","awardable":true,"open":true,"dept_key":"d-057","dept_name":"DEPT OF DEFENSE","sub_key":"s-5700","sub_name":"DEPT OF THE AIR FORCE","office_key":"o-FA6670","office_name":"FA6670 914 AW LGC","naics":"236220","psc":"Z2BZ","set_aside":"SDVOSBC","state":"NY","county":"36063","county_name":"Niagara County","city":"3651055","city_name":"Niagara Falls","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z"},{"key":"FA667026Q0017","latest_notice_id":"9421151f62ad4247babc3e881660398a","title":"Mass Notification System Kenwood Radio - Niagara Falls ARS Solicitation","solicitation_number":"FA667026Q0017","notice_type":"k","first_type":"k","first_posted":"2026-09-02","last_posted":"2026-09-11","notices":2,"due_at":"2026-09-23T17:00:00Z","due_date":"2026-09-23","closes_at":"2026-09-23T17:00:00Z","awardable":true,"open":true,"dept_key":"d-057","dept_name":"DEPT OF DEFENSE","sub_key":"s-5700","sub_name":"DEPT OF THE AIR FORCE","office_key":"o-FA6670","office_name":"FA6670 914 AW LGC","naics":"238210","psc":"5895","set_aside":null,"state":"NY","county":"36063","county_name":"Niagara County","city":null,"city_name":null,"country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z"}]}