{"canonical":"https://abierto.us/opportunities/fa667024b0001","key":"FA667024B0001","url":"https://abierto.us/opportunities/fa667024b0001","title":"Airfield Striping and Marking for Taxiways and Aprons","solicitation_number":"FA6670-24-B-0001","notice_type":"a","open":false,"response_deadline":"2024-09-06T18:00:00Z","first_posted":"2024-08-02","last_posted":"2024-10-02","department":"DEPT OF DEFENSE","subagency":"DEPT OF THE AIR FORCE","office":"FA6670 914 AW LGC","naics":"237310","psc":"Z1BD","set_aside":"SDVOSBC","place_state":"NY","place_county":"36063","place_county_name":"Niagara County","place_city":"3651055","place_city_name":"Niagara Falls","winner":"GLOBAL URBAN ENTERPRISES, L.L.C.","award_amount":"742256.00","publications":[{"notice_id":"69739019ff2a4c8fa2e3f7813fc4f86c","title":"Airfield Striping and Marking for Taxiways and Aprons","solicitation_number":"FA6670-24-B-0001","notice_type":"o","base_type":"p","posted":"2024-08-02","posted_at":null,"due_at":"2024-09-04T17:00:00Z","due_date":"2024-09-04","cancelled":null,"archived":null,"archive_date":"2024-10-15","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/69739019ff2a4c8fa2e3f7813fc4f86c/view","enriched":false,"history":[]},{"notice_id":"01412bce43a24ac0b0cee9bd6f169aa5","title":"Airfield Striping and Marking for Taxiways and Aprons","solicitation_number":"FA6670-24-B-0001","notice_type":"o","base_type":"o","posted":"2024-08-13","posted_at":null,"due_at":"2024-09-04T17:00:00Z","due_date":"2024-09-04","cancelled":null,"archived":null,"archive_date":"2024-10-15","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/01412bce43a24ac0b0cee9bd6f169aa5/view","enriched":false,"history":[]},{"notice_id":"c3204f7edc734671aa316a5ff82b2d39","title":"Airfield Striping and Marking for Taxiways and Aprons","solicitation_number":"FA6670-24-B-0001","notice_type":"o","base_type":"o","posted":"2024-08-21","posted_at":null,"due_at":"2024-09-06T18:00:00Z","due_date":"2024-09-06","cancelled":null,"archived":null,"archive_date":"2024-10-15","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/c3204f7edc734671aa316a5ff82b2d39/view","enriched":false,"history":[]},{"notice_id":"21f7c112a6364e3b971509d94cf64705","title":"Airfield Striping and Marking for Taxiways and Aprons","solicitation_number":"FA6670-24-B-0001","notice_type":"o","base_type":"o","posted":"2024-08-22","posted_at":null,"due_at":"2024-09-06T18:00:00Z","due_date":"2024-09-06","cancelled":null,"archived":null,"archive_date":"2024-10-15","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/21f7c112a6364e3b971509d94cf64705/view","enriched":false,"history":[]},{"notice_id":"1d3bdc9f36794df3bf46d6ba22a3c6b5","title":"Airfield Striping and Marking for Taxiways and Aprons","solicitation_number":"FA6670-24-B-0001","notice_type":"o","base_type":"o","posted":"2024-09-06","posted_at":null,"due_at":"2024-09-06T18:00:00Z","due_date":"2024-09-06","cancelled":null,"archived":null,"archive_date":"2024-10-15","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/1d3bdc9f36794df3bf46d6ba22a3c6b5/view","enriched":false,"history":[]},{"notice_id":"dbb6424d5e8d414caa2966210d006a42","title":"Airfield Striping and Marking for Taxiways and Aprons","solicitation_number":"FA6670-24-B-0001","notice_type":"o","base_type":"o","posted":"2024-09-06","posted_at":null,"due_at":"2024-09-06T18:00:00Z","due_date":"2024-09-06","cancelled":null,"archived":null,"archive_date":"2024-10-02","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/dbb6424d5e8d414caa2966210d006a42/view","enriched":false,"history":[]},{"notice_id":"0b45736cff35450da31c7af71ca166d5","title":"AWARD Notice - Airfield Striping and Marking for Taxiways and Aprons","solicitation_number":"FA6670-24-B-0001","notice_type":"a","base_type":"a","posted":"2024-10-02","posted_at":null,"due_at":null,"due_date":null,"cancelled":null,"archived":null,"archive_date":"2024-10-10","award_number":"FA6670-24-C-0003","awardee_name":"GLOBAL URBAN ENTERPRISES, L.L.C. Victor","amount":"742256.00","link_sam":"https://sam.gov/workspace/contract/opp/0b45736cff35450da31c7af71ca166d5/view","enriched":false,"history":[]},{"notice_id":"995b05642bcf476a89d475e7e34eaecf","title":"Airfield Striping and Marking for Taxiways and Aprons","solicitation_number":"FA6670-24-B-0001","notice_type":"a","base_type":"o","posted":"2024-10-02","posted_at":null,"due_at":null,"due_date":null,"cancelled":null,"archived":null,"archive_date":"2024-10-10","award_number":"FA6670-24-C-0003","awardee_name":"GLOBAL URBAN ENTERPRISES, L.L.C. Victor","amount":"742256.00","link_sam":"https://sam.gov/workspace/contract/opp/995b05642bcf476a89d475e7e34eaecf/view","enriched":false,"history":[]}],"latest_notice_id":"995b05642bcf476a89d475e7e34eaecf","first_type":"o","notices":[{"dates":{"posted":"2024-08-02","response_deadline":{"raw":"2024-09-04T13:00:00-04:00","utc":"2024-09-04T17:00:00Z","date":"2024-09-04","time":"13:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/69739019ff2a4c8fa2e3f7813fc4f86c/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Airfield Striping and Marking for Taxiways and Aprons","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-10-15","archive_type":"auto_custom"},"contacts":[{"name":"Mary Elizabeth Pyle Platts","role":"primary","email":"mary.pyleplatts@us.af.mil"},{"name":"Senthan Mahendrarasa","role":"secondary","email":"senthan.mahendrarasa@us.af.mil"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"69739019ff2a4c8fa2e3f7813fc4f86c","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"567c6c87c8c7eeb52f0ca0ebf7d701ce2f406af99ab089862e695bf6e1752e47","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"Niagara Falls Air Reserve Station has a requirement for a Construction project, Airfield Striping and Marking for Taxiways and Aprons. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, Airfield Striping and Marking for Taxiways and Aprons, to include the following: 1)Removal and reapplication of all taxiway markings on taxiways A, A1, A2, A3, and A4 up to and including the runway hold lines; 2) Removal and reapplication of all markings on the Operational Apron; 3) Cleaning and restriping/remarking all Main Apron markings; and 4) Removal and reapplication of all hangar entrance markings.. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 75 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service Disabled Veteran Owned Small Business, (SDVOSB). The estimated magnitude of construction is between $500,000 and $1,000,000. The NAICS code is 237310 and the Small Business Size Standard is $45,000,000.00. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the SAM website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"FA6670-24-B-0001","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"},{"dates":{"posted":"2024-08-13","response_deadline":{"raw":"2024-09-04T13:00:00-04:00","utc":"2024-09-04T17:00:00Z","date":"2024-09-04","time":"13:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/01412bce43a24ac0b0cee9bd6f169aa5/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Airfield Striping and Marking for Taxiways and Aprons","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-10-15","archive_type":"auto_custom"},"contacts":[{"name":"Mary Elizabeth Pyle Platts","role":"primary","email":"mary.pyleplatts@us.af.mil"},{"name":"Senthan Mahendrarasa","role":"secondary","email":"senthan.mahendrarasa@us.af.mil"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"01412bce43a24ac0b0cee9bd6f169aa5","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"1efd9246f9ad38fb70b9f953182c32e3fadd118365415c65cc0050d2a79a4ee6","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"13 August 2024 Site Visit Signing Sheet posted _________________________________________________________________________ Niagara Falls Air Reserve Station has a requirement for a Construction project, Airfield Striping and Marking for Taxiways and Aprons. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, Airfield Striping and Marking for Taxiways and Aprons, to include the following: 1)Removal and reapplication of all taxiway markings on taxiways A, A1, A2, A3, and A4 up to and including the runway hold lines; 2) Removal and reapplication of all markings on the Operational Apron; 3) Cleaning and restriping/remarking all Main Apron markings; and 4) Removal and reapplication of all hangar entrance markings.. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 75 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service Disabled Veteran Owned Small Business, (SDVOSB). The estimated magnitude of construction is between $500,000 and $1,000,000. The NAICS code is 237310 and the Small Business Size Standard is $45,000,000.00. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the SAM website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"FA6670-24-B-0001","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"},{"dates":{"posted":"2024-08-21","response_deadline":{"raw":"2024-09-06T14:00:00-04:00","utc":"2024-09-06T18:00:00Z","date":"2024-09-06","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/c3204f7edc734671aa316a5ff82b2d39/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Airfield Striping and Marking for Taxiways and Aprons","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-10-15","archive_type":"auto_custom"},"contacts":[{"name":"Mary Elizabeth Pyle Platts","role":"primary","email":"mary.pyleplatts@us.af.mil"},{"name":"Senthan Mahendrarasa","role":"secondary","email":"senthan.mahendrarasa@us.af.mil"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"c3204f7edc734671aa316a5ff82b2d39","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"448e69d01b53c6fc529816417fe5eef16588cc228618106398ddaab3c857d8a7","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"21 Aug 2024 Amendment 1 posted which incorporated Addendum 1, adds clause 52.288-1, adds Section L Instructions to Offerors and extends the proposal due date. ________________________________________________________________________ 13 August 2024 Site Visit Signing Sheet posted _________________________________________________________________________ Niagara Falls Air Reserve Station has a requirement for a Construction project, Airfield Striping and Marking for Taxiways and Aprons. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, Airfield Striping and Marking for Taxiways and Aprons, to include the following: 1)Removal and reapplication of all taxiway markings on taxiways A, A1, A2, A3, and A4 up to and including the runway hold lines; 2) Removal and reapplication of all markings on the Operational Apron; 3) Cleaning and restriping/remarking all Main Apron markings; and 4) Removal and reapplication of all hangar entrance markings.. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 75 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service Disabled Veteran Owned Small Business, (SDVOSB). The estimated magnitude of construction is between $500,000 and $1,000,000. The NAICS code is 237310 and the Small Business Size Standard is $45,000,000.00. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the SAM website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"FA6670-24-B-0001","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"},{"dates":{"posted":"2024-08-22","response_deadline":{"raw":"2024-09-06T14:00:00-04:00","utc":"2024-09-06T18:00:00Z","date":"2024-09-06","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/21f7c112a6364e3b971509d94cf64705/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Airfield Striping and Marking for Taxiways and Aprons","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-10-15","archive_type":"auto_custom"},"contacts":[{"name":"Mary Elizabeth Pyle Platts","role":"primary","email":"mary.pyleplatts@us.af.mil"},{"name":"Senthan Mahendrarasa","role":"secondary","email":"senthan.mahendrarasa@us.af.mil"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"21f7c112a6364e3b971509d94cf64705","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"d9ab62892815a7ca891ba02a5c170f4f1e604a6352fb8c3347101bfb75a7db2b","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"22 Aug 2024 Site Visit Questions and Answers posted. ________________________________________________________________________ 21 Aug 2024 Amendment 1 posted which incorporated Addendum 1, adds clause 52.288-1, adds Section L Instructions to Offerors and extends the proposal due date. ________________________________________________________________________ 13 August 2024 Site Visit Signing Sheet posted _________________________________________________________________________ Niagara Falls Air Reserve Station has a requirement for a Construction project, Airfield Striping and Marking for Taxiways and Aprons. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, Airfield Striping and Marking for Taxiways and Aprons, to include the following: 1)Removal and reapplication of all taxiway markings on taxiways A, A1, A2, A3, and A4 up to and including the runway hold lines; 2) Removal and reapplication of all markings on the Operational Apron; 3) Cleaning and restriping/remarking all Main Apron markings; and 4) Removal and reapplication of all hangar entrance markings.. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 75 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service Disabled Veteran Owned Small Business, (SDVOSB). The estimated magnitude of construction is between $500,000 and $1,000,000. The NAICS code is 237310 and the Small Business Size Standard is $45,000,000.00. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the SAM website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"FA6670-24-B-0001","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"},{"dates":{"posted":"2024-09-06","response_deadline":{"raw":"2024-09-06T14:00:00-04:00","utc":"2024-09-06T18:00:00Z","date":"2024-09-06","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/1d3bdc9f36794df3bf46d6ba22a3c6b5/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Airfield Striping and Marking for Taxiways and Aprons","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-10-15","archive_type":"auto_custom"},"contacts":[{"name":"Mary Elizabeth Pyle Platts","role":"primary","email":"mary.pyleplatts@us.af.mil"},{"name":"Senthan Mahendrarasa","role":"secondary","email":"senthan.mahendrarasa@us.af.mil"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"1d3bdc9f36794df3bf46d6ba22a3c6b5","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"3149d77f1f8779b4a9614acf055a4cbc7f0a1deb7415bfeba2f88483753481e4","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"6 Sept 2024 Bid Abstract and Bid Sign in sheet posted. ________________________________________________________________________ 22 Aug 2024 Site Visit Questions and Answers posted. ________________________________________________________________________ 21 Aug 2024 Amendment 1 posted which incorporated Addendum 1, adds clause 52.288-1, adds Section L Instructions to Offerors and extends the proposal due date. ________________________________________________________________________ 13 August 2024 Site Visit Signing Sheet posted _________________________________________________________________________ Niagara Falls Air Reserve Station has a requirement for a Construction project, Airfield Striping and Marking for Taxiways and Aprons. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, Airfield Striping and Marking for Taxiways and Aprons, to include the following: 1)Removal and reapplication of all taxiway markings on taxiways A, A1, A2, A3, and A4 up to and including the runway hold lines; 2) Removal and reapplication of all markings on the Operational Apron; 3) Cleaning and restriping/remarking all Main Apron markings; and 4) Removal and reapplication of all hangar entrance markings.. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 75 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service Disabled Veteran Owned Small Business, (SDVOSB). The estimated magnitude of construction is between $500,000 and $1,000,000. The NAICS code is 237310 and the Small Business Size Standard is $45,000,000.00. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the SAM website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"FA6670-24-B-0001","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"},{"dates":{"posted":"2024-09-06","response_deadline":{"raw":"2024-09-06T14:00:00-04:00","utc":"2024-09-06T18:00:00Z","date":"2024-09-06","time":"14:00:00","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/dbb6424d5e8d414caa2966210d006a42/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Airfield Striping and Marking for Taxiways and Aprons","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-10-02","archive_type":"manual"},"contacts":[{"name":"Mary Elizabeth Pyle Platts","role":"primary","email":"mary.pyleplatts@us.af.mil"},{"name":"Senthan Mahendrarasa","role":"secondary","email":"senthan.mahendrarasa@us.af.mil"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"dbb6424d5e8d414caa2966210d006a42","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"43af3eddeb4169c850d0234cb0e51a5425e21985c022f7f330933725d8cedc6e","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"6 Sept 2024 Bid Abstract and Bid Sign in sheet posted. ________________________________________________________________________ 22 Aug 2024 Site Visit Questions and Answers posted. ________________________________________________________________________ 21 Aug 2024 Amendment 1 posted which incorporated Addendum 1, adds clause 52.288-1, adds Section L Instructions to Offerors and extends the proposal due date. ________________________________________________________________________ 13 August 2024 Site Visit Signing Sheet posted _________________________________________________________________________ Niagara Falls Air Reserve Station has a requirement for a Construction project, Airfield Striping and Marking for Taxiways and Aprons. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, Airfield Striping and Marking for Taxiways and Aprons, to include the following: 1)Removal and reapplication of all taxiway markings on taxiways A, A1, A2, A3, and A4 up to and including the runway hold lines; 2) Removal and reapplication of all markings on the Operational Apron; 3) Cleaning and restriping/remarking all Main Apron markings; and 4) Removal and reapplication of all hangar entrance markings.. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 75 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service Disabled Veteran Owned Small Business, (SDVOSB). The estimated magnitude of construction is between $500,000 and $1,000,000. The NAICS code is 237310 and the Small Business Size Standard is $45,000,000.00. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the SAM website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"FA6670-24-B-0001","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"},{"award":{"date":"2024-09-25","amount":"742256.00","number":"FA6670-24-C-0003","awardee":{"raw":"GLOBAL URBAN ENTERPRISES, L.L.C. Victor NY 14564 USA","name":"GLOBAL URBAN ENTERPRISES, L.L.C. Victor","location":{"zip":"14564","state":{"code":"NY"},"country":{"code":"USA"}}}},"dates":{"posted":"2024-10-02","award_date":"2024-09-25"},"links":{"sam":"https://sam.gov/workspace/contract/opp/0b45736cff35450da31c7af71ca166d5/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"AWARD Notice - Airfield Striping and Marking for Taxiways and Aprons","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-10-10","archive_type":"auto15"},"contacts":[{"name":"Mary Elizabeth Pyle Platts","role":"primary","email":"mary.pyleplatts@us.af.mil"},{"name":"Senthan Mahendrarasa","role":"secondary","email":"senthan.mahendrarasa@us.af.mil"}],"base_type":{"code":"a","label":"Award Notice"},"notice_id":"0b45736cff35450da31c7af71ca166d5","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T19:12:38.374141Z","row_sha256":"0944495a551bc52531c455e2b0485d80eaa800622ed5d92dc0a95170217c1b6f","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T19:12:38.374141Z","first_seen_at":"2026-09-16T19:12:38.374141Z"},"notice_type":{"code":"a","label":"Award Notice"},"schema_version":1,"solicitation_number":"FA6670-24-B-0001","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"},{"award":{"date":"2024-09-25","amount":"742256.00","number":"FA6670-24-C-0003","awardee":{"raw":"GLOBAL URBAN ENTERPRISES, L.L.C. Victor NY 14564 USA","name":"GLOBAL URBAN ENTERPRISES, L.L.C. Victor","location":{"zip":"14564","state":{"code":"NY"},"country":{"code":"USA"}}}},"dates":{"posted":"2024-10-02","award_date":"2024-09-25"},"links":{"sam":"https://sam.gov/workspace/contract/opp/995b05642bcf476a89d475e7e34eaecf/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Airfield Striping and Marking for Taxiways and Aprons","agency":{"office":{"code":"FA6670","name":"FA6670 914 AW LGC"},"subtier":{"code":"5700","name":"DEPT OF THE AIR FORCE"},"department":{"code":"057","name":"DEPT OF DEFENSE"},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-10-10","archive_type":"auto15"},"contacts":[{"name":"Mary Elizabeth Pyle Platts","role":"primary","email":"mary.pyleplatts@us.af.mil"},{"name":"Senthan Mahendrarasa","role":"secondary","email":"senthan.mahendrarasa@us.af.mil"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"995b05642bcf476a89d475e7e34eaecf","set_aside":{"code":"SDVOSBC","label":"Service-Disabled Veteran-Owned Small Business Set-Aside (FAR 19.14)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T19:12:38.374141Z","row_sha256":"781d058d31d289aa3dd6462941c2caf527931af8e6929c17bd50c56f55aa6ff0","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T19:12:38.374141Z","first_seen_at":"2026-09-16T19:12:38.374141Z"},"notice_type":{"code":"a","label":"Award Notice"},"schema_version":1,"solicitation_number":"FA6670-24-B-0001","place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"product_service_code":"Z1BD"}],"due_at":"2024-09-06T18:00:00Z","due_date":"2024-09-06","closes_at":"2024-09-06T18:00:00Z","awardable":false,"dept_key":"d-057","dept_name":"DEPT OF DEFENSE","sub_key":"s-5700","sub_name":"DEPT OF THE AIR FORCE","office_key":"o-FA6670","office_name":"FA6670 914 AW LGC","state":"NY","county":"36063","county_name":"Niagara County","city":"3651055","city_name":"Niagara Falls","country":"USA","winner_key":"XTXHYTLBGTK8","amount":"742256.00","linked_awards":2,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z","principal_notice_id":"dbb6424d5e8d414caa2966210d006a42","description":{"text":"6 Sept 2024 Bid Abstract and Bid Sign in sheet posted. ________________________________________________________________________ 22 Aug 2024 Site Visit Questions and Answers posted. ________________________________________________________________________ 21 Aug 2024 Amendment 1 posted which incorporated Addendum 1, adds clause 52.288-1, adds Section L Instructions to Offerors and extends the proposal due date. ________________________________________________________________________ 13 August 2024 Site Visit Signing Sheet posted _________________________________________________________________________ Niagara Falls Air Reserve Station has a requirement for a Construction project, Airfield Striping and Marking for Taxiways and Aprons. Contractor to furnish all plant, labor, parts, materials, equipment, transportation and supervision required to complete the following construction project, Airfield Striping and Marking for Taxiways and Aprons, to include the following: 1)Removal and reapplication of all taxiway markings on taxiways A, A1, A2, A3, and A4 up to and including the runway hold lines; 2) Removal and reapplication of all markings on the Operational Apron; 3) Cleaning and restriping/remarking all Main Apron markings; and 4) Removal and reapplication of all hangar entrance markings.. Work will be performed at the 914th Air Refueling Wing, Niagara Falls ARS, Niagara County, NY. Performance time is 75 calendar days. A single Firm Fixed-Price construction contract will be awarded. This solicitation is set-aside 100% Service Disabled Veteran Owned Small Business, (SDVOSB). The estimated magnitude of construction is between $500,000 and $1,000,000. The NAICS code is 237310 and the Small Business Size Standard is $45,000,000.00. Bid, Payment and Performance Bonds will be required. Liquidated damages will be identified in the solicitation and placed under the proposed contract. All applicable provisions and clauses will be included in the actual solicitation. Site visit information will be provided in the solicitation; prime contractors, subcontractors and/or suppliers may attend the site visit. The complete solicitation will only be available electronically at https://sam.gov. No paper / hard copies will be provided. It is the contractor's responsibility for downloading the RFP documents and for monitoring the website for possible amendments, any changes or updates. Interested vendors may register their contact information at the SAM website under this notice. The list will be available online and is to facilitate subcontracting opportunities. Contractors must be actively registered in the System for Award Management (SAM) database at https://www.sam.gov and have their Online Representations and Certifications completed. Failure to register in the database will render the contractor ineligible for award. Offerors must also be actively registered in Wide Area Workflow (WAWF) - https://wawf.eb.mil This notice does not obligate the government to award a contract nor does it obligate the government to pay and/or reimburse respondents and/or their associates for any costs incurred to submit the requested information and/or a proposal. Responses to this notice and/or the Request for Proposals will not be returned. Any questions relating to this solicitation must be submitted in writing to the contracting office. No verbal communications are authorized.","html":null,"origin":"extract"},"contacts":[{"name":"Mary Elizabeth Pyle Platts","role":"primary","email":"mary.pyleplatts@us.af.mil"},{"name":"Senthan Mahendrarasa","role":"secondary","email":"senthan.mahendrarasa@us.af.mil"}],"place_of_performance":{"zip":"14304","city":{"name":"Niagara Falls"},"state":{"code":"NY"},"country":{"code":"USA"}},"office_address":{"zip":"14304-5000","city":"NIAGARA FALLS","state":"NY","country":"USA"},"naics_codes":["237310"],"award":null,"attachments":[],"awards":[{"award_key":"CONT_AWD_FA667024C0003_9700_-NONE-_-NONE-","permalink":"https://www.usaspending.gov/award/CONT_AWD_FA667024C0003_9700_-NONE-_-NONE-/","piid":"FA667024C0003","parent_piid":null,"award_type":"DEFINITIVE CONTRACT","vendor_key":"XTXHYTLBGTK8","recipient_name":"GLOBAL URBAN ENTERPRISES, L.L.C.","recipient_uei":"XTXHYTLBGTK8","recipient_cage":"77QB6","recipient_city":"VICTOR","recipient_state":"NY","sub_name":"Department of the Air Force","office_name":"FA6670 914 AW LGC","office_key":"o-FA6670","first_action_date":"2024-09-25","last_action_date":"2024-11-18","actions":2,"obligated":"742256.00","current_total_value":"742256.00","potential_total_value":"742256.00","naics":"237310","psc":"Z1BD","extent_competed":"FULL AND OPEN COMPETITION AFTER EXCLUSION OF SOURCES","set_aside":"SERVICE DISABLED VETERAN OWNED SMALL BUSINESS SET-ASIDE","offers_received":5,"description":"STRIPING AND MARKING FOR AIRFIELD AND TAXIWAYS AND RAMPS","method":"piid","confidence":"high","evidence":["award number FA667024C0003 equals the contract number","same awarding office FA6670"],"opportunity_key":null,"opportunity_title":null}],"related":[{"key":"FA667026Q0015","latest_notice_id":"4871181e002742f6b12fda70c8892518","title":"2026 SABER IDIQ - (Simplified Acquisition of Base Engineering Requirements)","solicitation_number":"FA667026Q0015","notice_type":"k","first_type":"k","first_posted":"2026-08-13","last_posted":"2026-09-14","notices":3,"due_at":"2026-09-17T17:00:00Z","due_date":"2026-09-17","closes_at":"2026-09-17T17:00:00Z","awardable":true,"open":true,"dept_key":"d-057","dept_name":"DEPT OF DEFENSE","sub_key":"s-5700","sub_name":"DEPT OF THE AIR FORCE","office_key":"o-FA6670","office_name":"FA6670 914 AW LGC","naics":"236220","psc":"Z2BZ","set_aside":"SDVOSBC","state":"NY","county":"36063","county_name":"Niagara County","city":"3651055","city_name":"Niagara Falls","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z"},{"key":"FA667026Q0017","latest_notice_id":"9421151f62ad4247babc3e881660398a","title":"Mass Notification System Kenwood Radio - Niagara Falls ARS Solicitation","solicitation_number":"FA667026Q0017","notice_type":"k","first_type":"k","first_posted":"2026-09-02","last_posted":"2026-09-11","notices":2,"due_at":"2026-09-23T17:00:00Z","due_date":"2026-09-23","closes_at":"2026-09-23T17:00:00Z","awardable":true,"open":true,"dept_key":"d-057","dept_name":"DEPT OF DEFENSE","sub_key":"s-5700","sub_name":"DEPT OF THE AIR FORCE","office_key":"o-FA6670","office_name":"FA6670 914 AW LGC","naics":"238210","psc":"5895","set_aside":null,"state":"NY","county":"36063","county_name":"Niagara County","city":null,"city_name":null,"country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z"}]}