{"canonical":"https://abierto.us/opportunities/dospassportofficeslcut","key":"DOSPASSPORTOFFICESLCUT","url":"https://abierto.us/opportunities/dospassportofficeslcut","title":"U.S. Department of State Passport Office Construction Services – Salt Lake City, Utah - Presolicitation Notice","solicitation_number":"DOS_PassportOffice_SLC_UT","notice_type":"p","open":true,"response_deadline":"2026-09-18T20:00:00Z","first_posted":"2026-05-13","last_posted":"2026-09-03","department":"GENERAL SERVICES ADMINISTRATION","subagency":"PUBLIC BUILDINGS SERVICE","office":"PBS PROJECT DELIVERY CAPITAL CONSTRUCTION - BRANCH WEST","naics":"236220","psc":"Z2AA","set_aside":null,"place_state":"UT","winner":null,"award_amount":null,"publications":[{"notice_id":"5113fa4645e54107a5bba9d97c4bacb0","title":"U.S. Department of State Passport Office Construction Services – Salt Lake City, Utah","solicitation_number":"DOS_PassportOffice_SLC_UT","notice_type":"r","base_type":"r","posted":"2026-05-13","posted_at":null,"due_at":"2026-05-27T20:00:00Z","due_date":"2026-05-27","cancelled":null,"archived":null,"archive_date":"2026-06-11","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/5113fa4645e54107a5bba9d97c4bacb0/view","enriched":false,"history":[]},{"notice_id":"4fc541944ff6496ab7f190d09773110b","title":"Industry Day, U.S. Department of State Passport Office Construction Services – Salt Lake City, Utah","solicitation_number":"DOS_PassportOffice_SLC_UT","notice_type":"s","base_type":"r","posted":"2026-08-10","posted_at":null,"due_at":"2026-08-21T20:00:00Z","due_date":"2026-08-21","cancelled":null,"archived":null,"archive_date":"2026-09-05","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/4fc541944ff6496ab7f190d09773110b/view","enriched":false,"history":[]},{"notice_id":"5961f8bd8dba40ddafbc495080ea1eac","title":"Industry Day, U.S. Department of State Passport Office Construction Services – Salt Lake City, Utah","solicitation_number":"DOS_PassportOffice_SLC_UT","notice_type":"s","base_type":"s","posted":"2026-08-28","posted_at":null,"due_at":"2026-08-21T20:00:00Z","due_date":"2026-08-21","cancelled":null,"archived":null,"archive_date":"2026-09-05","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/5961f8bd8dba40ddafbc495080ea1eac/view","enriched":false,"history":[]},{"notice_id":"d092af31a8914b91bf5c317fbe034e36","title":"U.S. Department of State Passport Office Construction Services – Salt Lake City, Utah - Presolicitation Notice","solicitation_number":"DOS_PassportOffice_SLC_UT","notice_type":"p","base_type":"s","posted":"2026-09-03","posted_at":null,"due_at":"2026-09-18T20:00:00Z","due_date":"2026-09-18","cancelled":null,"archived":null,"archive_date":"2026-10-03","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/d092af31a8914b91bf5c317fbe034e36/view","enriched":false,"history":[]}],"latest_notice_id":"d092af31a8914b91bf5c317fbe034e36","first_type":"r","notices":[{"dates":{"posted":"2026-05-13","response_deadline":{"raw":"2026-05-27T14:00:00-06:00","utc":"2026-05-27T20:00:00Z","date":"2026-05-27","time":"14:00:00","utc_offset_seconds":-21600}},"links":{"sam":"https://sam.gov/workspace/contract/opp/5113fa4645e54107a5bba9d97c4bacb0/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"U.S. Department of State Passport Office Construction Services – Salt Lake City, Utah","agency":{"office":{"code":"47PB54","name":"PBS PROJECT DELIVERY CAPITAL CONSTRUCTION - BRANCH WEST"},"subtier":{"code":"4740","name":"PUBLIC BUILDINGS SERVICE"},"department":{"code":"047","name":"GENERAL SERVICES ADMINISTRATION"},"office_address":{"zip":"20405","city":"Washington","state":"DC","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-06-11","archive_type":"auto15"},"contacts":[{"name":"Jamie (James) Potter","role":"primary","email":"jamie.potter@gsa.gov","phone":"(303) 588-9153"}],"base_type":{"code":"r","label":"Sources Sought"},"notice_id":"5113fa4645e54107a5bba9d97c4bacb0","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T16:22:53.920682Z","row_sha256":"8302c02e380a5b0847129582b6581654bf7f152b0616314a45b50621451e1da8","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T16:22:53.920682Z","first_seen_at":"2026-09-16T16:22:53.920682Z"},"description":{"text":"THIS IS A REQUEST FOR INFORMATION (RFI) AND SOURCES SOUGHT NOTICE (SSN) for Construction Services to deliver a turnkey U.S. Passport Office for the U.S. Department of State at the Wallace F. Bennett Federal Building and the tenant improvement construction for six agencies’ offices in the Wallace F. Bennett Federal Building and the Orrin G. Hatch United States Courthouse in Salt Lake City, Utah. THIS IS NOT A REQUEST FOR PROPOSAL (RFP) AND NO CONTRACT WILL BE AWARDED FROM THIS NOTICE. The U.S. General Services Administration (GSA), Public Buildings Service (PBS), Acquisition Project Delivery – Capital Construction Division (PQA), is conducting market research: (1) To determine if there are adequate Small Business, HUBZone small business, Women-Owned small business, or Service-Disabled Veteran-Owned small business contractors capable of performing the construction services for the requirement described herein. If it is determined that adequate competition exists, the GSA may set the requirement aside for competition among the selected group. GSA PBS PQA is seeking all qualified and interested sources (both Large and Small Businesses) to respond to this RFI to provide Construction Services for the turnkey U.S. Passport Office construction project for the U.S. Department of State at the Wallace F. Bennett Federal Building and the tenant improvement construction for six agencies’ offices in the Wallace F. Bennett Federal Building and the Orrin G. Hatch United States Courthouse in Salt Lake City, Utah. The scope for the new U.S. Passport Office project includes hazardous materials abatement, selective interior office space demolition, and new construction of waiting areas, application windows, office space, training rooms, conference rooms, hoteling cubicles, break rooms, server rooms, locker rooms, restrooms, printing rooms, storage, security desks, security screening, Security Operations Center (SOC), and finish upgrades. The contract type is anticipated to be a firm-fixed-price utilizing a design-bid-build delivery approach. Construction activities in the Wallace F. Bennett Federal Building are expected to occur primarily during normal working hours, with certain utility outage needs to be performed after hours to not affect the active building tenants. Construction activities in the Orrin G. Hatch United States Courthouse are expected to occur primarily outside of normal working hours. The project will consist of three consecutive phases; build-out of the six agencies’ offices, demolition and hazardous materials abatement, and then the U.S. Passport Office and Lobby build-out. The tenant build-outs are in existing occupied facilities with surrounding active tenants requiring coordination with the move and surrounding tenants. Work includes, demolition, hazardous materials abatement, architectural, mechanical, electrical, plumbing, fire protection, telecommunications, audio visual systems, security, equipment, tenant moves, and furniture installation, in full compliance with applicable GSA standards. The project consists of approximately 48,000 square feet of finished office workspace and lobby space. The majority of the project, approximately 30,000 square feet, will be U.S. Passport Office space, with the remaining space for six relocating agencies’ offices and the Bennett Lobby remodel. The U.S. Passport Office’s finished space includes a waiting area, application windows, office space, training rooms, conference rooms, hoteling cubicles, break rooms, server rooms, locker rooms, restrooms, printing rooms, security monitoring, and storage. The lobby renovation consists of security desks, security screening, and finish upgrades. The six relocating agencies’ offices consist of reception areas, office space, training rooms, conference rooms, break rooms, server rooms, and storage. Locations of Performance are: Wallace F. Bennett Federal Building 125 South State Street Salt Lake City, UT 84138 Orrin G. Hatch United States Courthouse 351 South West Temple Street Salt Lake City, UT 84101 Any resultant contract shall adhere to the GSA PBS Core Buildings Standards and Building Information Modeling (BIM). This office anticipates award of a contract for these services in Q1 of 2027. Contract duration is estimated to be twenty two (22) months. Estimated magnitude of construction: $20,000,000 TO $30,000,000. The applicable NAICS code for this requirement is 236220, Commercial and Institutional Building Construction. The Small Business Size Standard is $45M. All interested parties may submit to the Contracting Officer a written Letter of Interest including a Capability Statement addressing the following information (five (5) single-sided page limit in PDF Format). Additional pages will not be considered. All information submitted is subject to verification. Additional information may be requested to substantiate responses. The Government will use this information to assess your firm’s capability to perform this project. QUESTIONS: (Please fill-out on the Google Form: https://forms.gle/ufBr5wnk3wGs4p5cA, except where noted below) Respondents shall complete the Google Form for items (1)-(3) and (5)-(19). Item (4) shall be provided as part of the separate Capability Statement attachment and will not be collected via the Google Form. For Item (5) Bonding Capacity, respondents shall complete the Google Form and also provide supporting documentation as part of the Capability Statement (e.g., a letter from a surety) demonstrating the firm’s ability to obtain bonding for a single project of at least $30 million. Name of your company, Unique Entity ID (SAM), address, point of contact with phone number and email address. Does your company have an active registration at www.sam.gov? Business size for the assigned NAICS code, which can be located at the U.S. Small Business Administration website: www.sba.gov. In addition to the size of business, indicate any other socioeconomic designations such as 8(a), Small Disadvantaged Business, HUBZone Small Business, Service-Disabled Veteran-Owned Small Business, and/or Women-Owned Small Business. Company's capability to perform a contract of this magnitude and complexity. Provide a brief narrative description of three (3) projects performed as a prime contractor that demonstrate experience relevant to this requirement. Projects shall be completed within the past seven (7) years. Work performed as a subcontractor is not considered as evidence of capability to succeed as a prime contractor. Relevant projects are those that demonstrate experience in projects of similar size, scope, and complexity. The Government will consider the following characteristics in determining relevance: Size: Construction cost at time of award was at least $20,000,000 Size: Projects with a comparable construction footprint of at least 25,000 square feet. Scope: Interior renovation or tenant build-out within an occupied facility requiring complex coordination of multiple trades (e.g. mechanical, electrical, plumbing, fire protection, security, and low voltage systems), sequencing constraints, and stakeholder coordination. For each project submitted, provide a concise summary of the work that includes the following details: your specific role (e.g.,prime contractor), the customer's name and point of contact, the contract value at time of award, the period of performance, and a summary of the scope executed. 5. Provide evidence of your company's bonding capability verifying the ability to bond a single project of a magnitude up to $30,000,000. In addition, provide evidence of your company’s aggregate bonding capacity. 6. If your company is/will be part of a joint venture, state the name(s) of the joint venture members and the business size(s) of each. 7. Is your firm local to the Salt Lake City Metropolitan Area? If not, will you self-perform or establish a local presence? 8. If you recently completed a project in the area, what were some of the challenges with the labor market and supply chain? 9. Identify any critical risk or constraints the Government should consider in developing this solicitation? 10. What strategies do you use to mitigate risks related to long-lead items and supply chain delays? 11. Would you be interested in attending an industry day or site walkthrough? 12. What information would be most beneficial for the Government to provide at an industry day to improve proposal quality? 13. Do you foresee any challenges with a 22-month period of performance? 14. Describe your firm’s approach to managing construction activities in occupied federal facilities, including phasing, demolition, hazardous material abatement, tenant coordination, tenant move management, and minimizing disruption. 15. Describe your approach to integrating Government-furnished or Government-installed security systems into the construction schedule (e.g., IDS, ACS, CCTV)? 16. Describe your experience ensuring compliance with Security Operations Center (SOC) requirements during construction? 17. Describe your firm’s relationships with key subcontractors necessary to successfully complete a Security Operations Center (SOC)? 18. Please provide any other information that you feel is pertinent to the requirement. RESPONSES TO THIS RFI ARE DUE NO LATER THAN (NLT) May 27, 2026, AT 2:00 PM Mountain Time (MT). Electronic submission (no more than 25MB) of the statement of capabilities package may be submitted to Jamie (James) Potter at jamie.potter@gsa.gov. Please include the subject line: “DOS Passport Office SLC, Utah Sources Sought Response”. Responses to this RFI shall be used for planning purposes only and shall not commit GSA to issue a solicitation(s) for this requirement. The Government is not obligated to and will not pay for any information received from the respondents as a result of this market research. It is, however, anticipated that a solicitation or solicitations based on the outcome of this market survey will be published and that a subsequent contract or contracts from the solicitation(s) will be awarded.","origin":"extract"},"notice_type":{"code":"r","label":"Sources Sought"},"schema_version":1,"solicitation_number":"DOS_PassportOffice_SLC_UT","place_of_performance":{"zip":"84138","city":{"name":"Salt Lake City"},"state":{"code":"UT"},"country":{"code":"USA"}},"product_service_code":"Z2AA"},{"dates":{"posted":"2026-08-10","response_deadline":{"raw":"2026-08-21T14:00:00-06:00","utc":"2026-08-21T20:00:00Z","date":"2026-08-21","time":"14:00:00","utc_offset_seconds":-21600}},"links":{"sam":"https://sam.gov/workspace/contract/opp/4fc541944ff6496ab7f190d09773110b/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Industry Day, U.S. Department of State Passport Office Construction Services – Salt Lake City, Utah","agency":{"office":{"code":"47PB54","name":"PBS PROJECT DELIVERY CAPITAL CONSTRUCTION - BRANCH WEST"},"subtier":{"code":"4740","name":"PUBLIC BUILDINGS SERVICE"},"department":{"code":"047","name":"GENERAL SERVICES ADMINISTRATION"},"office_address":{"zip":"20405","city":"Washington","state":"DC","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-09-05","archive_type":"auto15"},"contacts":[{"name":"Jamie (James) Potter","role":"primary","email":"jamie.potter@gsa.gov","phone":"(303) 588-9153"}],"base_type":{"code":"r","label":"Sources Sought"},"notice_id":"4fc541944ff6496ab7f190d09773110b","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T00:55:27.040971Z","row_sha256":"cc82cbe5f251bf7a0fd31ffd2611ef543070961bb5951cf5fbdcf6ef57ec03ae","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T00:55:27.040971Z","first_seen_at":"2026-09-16T00:55:27.040971Z"},"description":{"text":"The U.S. General Services Administration (GSA), Public Buildings Service, is hosting an Industry Day on Wednesday, August 26, 2026, from 10:00 AM - noon Mountain Time for firms interested in the upcoming U.S. Passport Office design-bid-build construction procurement. This event will be conducted virtually via Google Meet. RSVP Link: https://forms.gle/c9VHg8anyCicqzxq6 Project Description: GSA intends to procure a firm-fixed-price, design-bid-build construction project to establish a turnkey U.S. Passport Office for the U.S. Department of State at the Wallace F. Bennett Federal Building in Salt Lake City, Utah. The project includes approximately 48,000 square feet of construction consisting of: A new 30,000-square-foot U.S. Passport Office; Tenant improvements to relocate five existing tenant agencies; Modifications to space occupied by a sixth tenant agency (U.S. Department of Health and Human Services) to accommodate a new ABAAS-compliant restroom; and Renovation of the building lobby, including security screening enhancements. A seventh tenant agency will relocate under a separate construction contract. While outside the scope of this procurement, coordination with that effort will be required due to project sequencing. Because the Bennett Federal Building will remain fully occupied throughout construction, the contractor will be required to execute the work in coordinated phases to maintain public access, continuous security screening operations, building functionality, and ongoing tenant operations while minimizing disruptions. Acquisition Overview: This procurement is being delivered using the design-bid-build methodology. The Government will competitively procure and award a construction contract to a general contractor responsible for the overall project execution and management. Contract award is anticipated in March 2027. The Government will issue the solicitation as an unrestricted procurement. The anticipated period of performance for the construction services is approximately twenty-two (22) months. The estimated dollar value of the construction services is between $20,000,000 and $30,000,000. The purpose of the Industry Day is to provide interested firms with an overview of the project, including the Government’s vision, program objectives, functional and operational requirements, and desired project outcomes. The event will provide attendees with an understanding of the project’s scope, key design and construction considerations, and the priorities that will guide the successful delivery of the project. The Industry Day will include an overview of the anticipated acquisition strategy, procurement schedule, and planned evaluation approach, followed by an opportunity for attendees to ask questions regarding the project. The anticipated agenda includes: Welcome and introductions Project overview and objectives Scope of work and key project requirements, and desired project outcomes Acquisition strategy and anticipated procurement schedule Evaluation approach Question and Answer session Registration: This event will be open to American citizens and to foreign nationals employed by American-based contractors. To register, please complete the Industry Day Registration RSVP Google Form (provided above) no later than August 21, 2026, 2:00 PM Mountain Time. Registration is required. RSVP submissions received after 2:00 PM Mountain Time on August 21, 2026, will not be accepted. After the RSVP registration period closes, registered attendees will receive a Google Calendar invitation sent to the email address(es) provided during registration. The invitation will include the Google Meet link for the event. Disclaimer: The information presented during the Industry Day is for planning and informational purposes only and does not amend or supersede any future solicitation or contract requirements. Any official changes or clarifications will be issued through the solicitation process.","origin":"extract"},"notice_type":{"code":"s","label":"Special Notice"},"schema_version":1,"solicitation_number":"DOS_PassportOffice_SLC_UT","place_of_performance":{"zip":"84138","city":{"name":"Salt Lake City"},"state":{"code":"UT"},"country":{"code":"USA"}},"product_service_code":"Z2AA"},{"dates":{"posted":"2026-08-28","response_deadline":{"raw":"2026-08-21T14:00:00-06:00","utc":"2026-08-21T20:00:00Z","date":"2026-08-21","time":"14:00:00","utc_offset_seconds":-21600}},"links":{"sam":"https://sam.gov/workspace/contract/opp/5961f8bd8dba40ddafbc495080ea1eac/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Industry Day, U.S. Department of State Passport Office Construction Services – Salt Lake City, Utah","agency":{"office":{"code":"47PB54","name":"PBS PROJECT DELIVERY CAPITAL CONSTRUCTION - BRANCH WEST"},"subtier":{"code":"4740","name":"PUBLIC BUILDINGS SERVICE"},"department":{"code":"047","name":"GENERAL SERVICES ADMINISTRATION"},"office_address":{"zip":"20405","city":"Washington","state":"DC","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-09-05","archive_type":"auto15"},"contacts":[{"name":"Jamie (James) Potter","role":"primary","email":"jamie.potter@gsa.gov","phone":"(303) 588-9153"}],"base_type":{"code":"s","label":"Special Notice"},"notice_id":"5961f8bd8dba40ddafbc495080ea1eac","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T00:55:27.040971Z","row_sha256":"6a92ba32852e271bf2ae4b32d67f5d21f0ad33f6286cb3ba9035edee4342f792","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T00:55:27.040971Z","first_seen_at":"2026-09-16T00:55:27.040971Z"},"description":{"text":"This posting is being updated on August 28, 2026, to include the attached slide deck presentation delivered during the Industry Day and relevant questions and answers. ---------------------------------------------------------------------------------------------------------------- The U.S. General Services Administration (GSA), Public Buildings Service, is hosting an Industry Day on Wednesday, August 26, 2026, from 10:00 AM - noon Mountain Time for firms interested in the upcoming U.S. Passport Office design-bid-build construction procurement. This event will be conducted virtually via Google Meet. RSVP Link: https://forms.gle/c9VHg8anyCicqzxq6 Project Description: GSA intends to procure a firm-fixed-price, design-bid-build construction project to establish a turnkey U.S. Passport Office for the U.S. Department of State at the Wallace F. Bennett Federal Building in Salt Lake City, Utah. The project includes approximately 48,000 square feet of construction consisting of: A new 30,000-square-foot U.S. Passport Office; Tenant improvements to relocate five existing tenant agencies; Modifications to space occupied by a sixth tenant agency (U.S. Department of Health and Human Services) to accommodate a new ABAAS-compliant restroom; and Renovation of the building lobby, including security screening enhancements. A seventh tenant agency will relocate under a separate construction contract. While outside the scope of this procurement, coordination with that effort will be required due to project sequencing. Because the Bennett Federal Building will remain fully occupied throughout construction, the contractor will be required to execute the work in coordinated phases to maintain public access, continuous security screening operations, building functionality, and ongoing tenant operations while minimizing disruptions. Acquisition Overview: This procurement is being delivered using the design-bid-build methodology. The Government will competitively procure and award a construction contract to a general contractor responsible for the overall project execution and management. Contract award is anticipated in March 2027. The Government will issue the solicitation as an unrestricted procurement. The anticipated period of performance for the construction services is approximately twenty-two (22) months. The estimated dollar value of the construction services is between $20,000,000 and $30,000,000. The purpose of the Industry Day is to provide interested firms with an overview of the project, including the Government’s vision, program objectives, functional and operational requirements, and desired project outcomes. The event will provide attendees with an understanding of the project’s scope, key design and construction considerations, and the priorities that will guide the successful delivery of the project. The Industry Day will include an overview of the anticipated acquisition strategy, procurement schedule, and planned evaluation approach, followed by an opportunity for attendees to ask questions regarding the project. The anticipated agenda includes: Welcome and introductions Project overview and objectives Scope of work and key project requirements, and desired project outcomes Acquisition strategy and anticipated procurement schedule Evaluation approach Question and Answer session Registration: This event will be open to American citizens and to foreign nationals employed by American-based contractors. To register, please complete the Industry Day Registration RSVP Google Form (provided above) no later than August 21, 2026, 2:00 PM Mountain Time. Registration is required. RSVP submissions received after 2:00 PM Mountain Time on August 21, 2026, will not be accepted. After the RSVP registration period closes, registered attendees will receive a Google Calendar invitation sent to the email address(es) provided during registration. The invitation will include the Google Meet link for the event. Disclaimer: The information presented during the Industry Day is for planning and informational purposes only and does not amend or supersede any future solicitation or contract requirements. Any official changes or clarifications will be issued through the solicitation process.","origin":"extract"},"notice_type":{"code":"s","label":"Special Notice"},"schema_version":1,"solicitation_number":"DOS_PassportOffice_SLC_UT","place_of_performance":{"zip":"84138","city":{"name":"Salt Lake City"},"state":{"code":"UT"},"country":{"code":"USA"}},"product_service_code":"Z2AA"},{"dates":{"posted":"2026-09-03","response_deadline":{"raw":"2026-09-18T14:00:00-06:00","utc":"2026-09-18T20:00:00Z","date":"2026-09-18","time":"14:00:00","utc_offset_seconds":-21600}},"links":{"sam":"https://sam.gov/workspace/contract/opp/d092af31a8914b91bf5c317fbe034e36/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"U.S. Department of State Passport Office Construction Services – Salt Lake City, Utah - Presolicitation Notice","agency":{"office":{"code":"47PB54","name":"PBS PROJECT DELIVERY CAPITAL CONSTRUCTION - BRANCH WEST"},"subtier":{"code":"4740","name":"PUBLIC BUILDINGS SERVICE"},"department":{"code":"047","name":"GENERAL SERVICES ADMINISTRATION"},"office_address":{"zip":"20405","city":"Washington","state":"DC","country":"USA"},"organization_type":"OFFICE"},"status":{"active":true,"archive_date":"2026-10-03","archive_type":"auto15"},"contacts":[{"name":"Jamie (James) Potter","role":"primary","email":"jamie.potter@gsa.gov","phone":"(303) 588-9153"}],"base_type":{"code":"s","label":"Special Notice"},"notice_id":"d092af31a8914b91bf5c317fbe034e36","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/datagov/ContractOpportunitiesFullCSV.csv","etag":"\"3f59209463433eba6899e195a597c64d-29\"","fetched_at":"2026-09-16T07:50:12.777658Z","row_sha256":"11a32703708132301f5e7bd4e8a321ec9cf84dfb4b11b0b4db55f8c4b3559ee3","last_modified":"2026-09-16T03:30:52Z"},"updated_at":"2026-09-16T07:50:12.777658Z","first_seen_at":"2026-09-15T22:52:52.472456Z"},"description":{"text":"The U.S. General Services Administration (GSA) intends to issue a Request for Proposals for the award of a single firm-fixed-price construction contract for a design-bid-build project to establish a turnkey U.S. Passport Office for the U.S. Department of State at thevWallace F. Bennett Federal Building in Salt Lake City, Utah. This notice is issued for planning purposes only and is not a solicitation. Project Description The project includes approximately 48,000 square feet of construction consisting of: A new 30,000-square-foot U.S. Passport Office; Tenant improvements to relocate five existing tenant agencies; Modifications to space occupied by a sixth tenant agency (U.S. Department of Health and Human Services) to accommodate new ABAAS-compliant restrooms; and Renovation of the building lobby, including security screening enhancements. A seventh tenant agency will relocate under a separate construction contract. While outside the scope of this procurement, coordination with that effort will be required due to project sequencing. Because the Bennett Federal Building will remain fully occupied throughout construction, the contractor will be required to execute the work in coordinated phases to maintain public access, continuous security screening operations, building functionality, and ongoing tenant operations while minimizing disruptions. Procurement Information GSA intends to conduct a competitive negotiated procurement under FAR Part 15 and award a single firm-fixed-price construction contract using a best value tradeoff selection approach. This procurement will be solicited as full and open competition under NAICS 236220 - Commercial and Institutional Building Construction. GSA anticipates an estimated construction value of approximately $20 to $30 million. Evaluation Factors Past Experience of the General Contractor (30%) Past Performance of the General Contractor (25%) Technical and Management Approach (20%) Key Personnel Qualifications (15%) Small Business Participation Plan (10%) Firm-Fixed-Price Solicitation Information GSA anticipates issuing the Request for Proposals by September 30, 2026. All provided timelines are projections and remain subject to change. The solicitation, all amendments, notices and related procurement information will be available through SAM.gov. Interested parties are responsible for monitoring SAM.gov for updates, amendments and additional information related to this procurement. Offerors must be actively registered in the System for Award Management (SAM.gov) at the time of proposal submission and contract award. Points of Contact Contracting Officer: Jamie (James) Potter Email: jamie.potter@gsa.gov Project Manager: Clay Weiland Email: clay.weiland@gsa.gov","origin":"extract"},"notice_type":{"code":"p","label":"Presolicitation"},"schema_version":1,"solicitation_number":"DOS_PassportOffice_SLC_UT","place_of_performance":{"zip":"84138","city":{"name":"Salt Lake City"},"state":{"code":"UT"},"country":{"code":"USA"}},"product_service_code":"Z2AA"}],"due_at":"2026-09-18T20:00:00Z","due_date":"2026-09-18","closes_at":"2026-09-18T20:00:00Z","awardable":true,"dept_key":"d-047","dept_name":"GENERAL SERVICES ADMINISTRATION","sub_key":"s-4740","sub_name":"PUBLIC BUILDINGS SERVICE","office_key":"o-47PB54","office_name":"PBS PROJECT DELIVERY CAPITAL CONSTRUCTION - BRANCH WEST","state":"UT","country":"USA","winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T17:40:17.704408Z","principal_notice_id":"d092af31a8914b91bf5c317fbe034e36","description":{"text":"The U.S. General Services Administration (GSA) intends to issue a Request for Proposals for the award of a single firm-fixed-price construction contract for a design-bid-build project to establish a turnkey U.S. Passport Office for the U.S. Department of State at thevWallace F. Bennett Federal Building in Salt Lake City, Utah. This notice is issued for planning purposes only and is not a solicitation. Project Description The project includes approximately 48,000 square feet of construction consisting of: A new 30,000-square-foot U.S. Passport Office; Tenant improvements to relocate five existing tenant agencies; Modifications to space occupied by a sixth tenant agency (U.S. Department of Health and Human Services) to accommodate new ABAAS-compliant restrooms; and Renovation of the building lobby, including security screening enhancements. A seventh tenant agency will relocate under a separate construction contract. While outside the scope of this procurement, coordination with that effort will be required due to project sequencing. Because the Bennett Federal Building will remain fully occupied throughout construction, the contractor will be required to execute the work in coordinated phases to maintain public access, continuous security screening operations, building functionality, and ongoing tenant operations while minimizing disruptions. Procurement Information GSA intends to conduct a competitive negotiated procurement under FAR Part 15 and award a single firm-fixed-price construction contract using a best value tradeoff selection approach. This procurement will be solicited as full and open competition under NAICS 236220 - Commercial and Institutional Building Construction. GSA anticipates an estimated construction value of approximately $20 to $30 million. Evaluation Factors Past Experience of the General Contractor (30%) Past Performance of the General Contractor (25%) Technical and Management Approach (20%) Key Personnel Qualifications (15%) Small Business Participation Plan (10%) Firm-Fixed-Price Solicitation Information GSA anticipates issuing the Request for Proposals by September 30, 2026. All provided timelines are projections and remain subject to change. The solicitation, all amendments, notices and related procurement information will be available through SAM.gov. Interested parties are responsible for monitoring SAM.gov for updates, amendments and additional information related to this procurement. Offerors must be actively registered in the System for Award Management (SAM.gov) at the time of proposal submission and contract award. Points of Contact Contracting Officer: Jamie (James) Potter Email: jamie.potter@gsa.gov Project Manager: Clay Weiland Email: clay.weiland@gsa.gov","html":null,"origin":"extract"},"contacts":[{"name":"Jamie (James) Potter","role":"primary","email":"jamie.potter@gsa.gov","phone":"(303) 588-9153"}],"place_of_performance":{"zip":"84138","city":{"name":"Salt Lake City"},"state":{"code":"UT"},"country":{"code":"USA"}},"office_address":{"zip":"20405","city":"Washington","state":"DC","country":"USA"},"naics_codes":["236220"],"award":null,"attachments":[],"awards":[],"related":[{"key":"47PB5426R0014","latest_notice_id":"74da76ea613347a396c9c65a9a7dc201","title":"NASA Ames Engineering and Mission Operations Facility Design-Build Services Solicitation","solicitation_number":"47PB5426R0014","notice_type":"o","first_type":"o","first_posted":"2026-08-28","last_posted":"2026-09-14","notices":2,"due_at":"2026-10-07T18:00:00Z","due_date":"2026-10-07","closes_at":"2026-10-07T18:00:00Z","awardable":true,"open":true,"dept_key":"d-047","dept_name":"GENERAL SERVICES ADMINISTRATION","sub_key":"s-4740","sub_name":"PUBLIC BUILDINGS SERVICE","office_key":"o-47PB54","office_name":"PBS PROJECT DELIVERY CAPITAL CONSTRUCTION - BRANCH WEST","naics":"236220","psc":"Y1AA","set_aside":null,"state":"CA","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T07:31:38.954589Z"}]}