{"canonical":"https://abierto.us/opportunities/75h70126r00019","key":"75H70126R00019","url":"https://abierto.us/opportunities/75h70126r00019","title":"Lame Deer Heliport and Concrete Support Structure Remediation","solicitation_number":"75H70126R00008","notice_type":"a","open":false,"response_deadline":"2026-06-03T19:00:00Z","first_posted":"2025-11-05","last_posted":"2026-08-31","department":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF","subagency":"INDIAN HEALTH SERVICE","office":"DIV OF ENGINEERING SVCS - SEATTLE","naics":"237310","psc":"Y1BZ","set_aside":"ISBEE","place_state":"MT","winner":"T. F. POWERS CONSTRUCTION CO","award_amount":"3775028.00","publications":[{"notice_id":"9d6f445b6d744bbdb6eae65f73ee2ed4","title":"Grindstone Water Storage Tank & Treatment Monitoring","solicitation_number":"75H70126R00008","notice_type":"r","base_type":"r","posted":"2025-11-05","posted_at":null,"due_at":"2025-11-21T00:00:00Z","due_date":"2025-11-20","cancelled":null,"archived":null,"archive_date":"2025-12-05","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/9d6f445b6d744bbdb6eae65f73ee2ed4/view","enriched":false,"history":[]},{"notice_id":"51818307cc184f2b9ce5778d7f0a1a84","title":"Lame Deer Heliport and Concrete Support Structure Remediation","solicitation_number":"75H70126R00019","notice_type":"r","base_type":"r","posted":"2025-12-11","posted_at":null,"due_at":"2025-12-22T23:00:00Z","due_date":"2025-12-22","cancelled":null,"archived":null,"archive_date":"2026-01-06","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/51818307cc184f2b9ce5778d7f0a1a84/view","enriched":false,"history":[]},{"notice_id":"e3ae7fd0d1e84e8599b7318e44cb499f","title":"Grindstone Water Storage Tank Replacement","solicitation_number":"75H70126R00008","notice_type":"p","base_type":"p","posted":"2026-01-16","posted_at":null,"due_at":"2026-02-02T22:00:00Z","due_date":"2026-02-02","cancelled":null,"archived":null,"archive_date":"2026-02-17","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/e3ae7fd0d1e84e8599b7318e44cb499f/view","enriched":false,"history":[]},{"notice_id":"9280501a791049ad9aac16b93c7e17ac","title":"Lame Deer Heliport and Concrete Support Structure Remediation","solicitation_number":"75H70126R00019","notice_type":"p","base_type":"r","posted":"2026-02-23","posted_at":null,"due_at":"2026-03-10T23:00:00Z","due_date":"2026-03-10","cancelled":null,"archived":null,"archive_date":"2026-03-25","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/9280501a791049ad9aac16b93c7e17ac/view","enriched":false,"history":[]},{"notice_id":"597b99c7b5914dd081e88324bc5dd37d","title":"Lame Deer Heliport and Concrete Support Structure Remediation","solicitation_number":"75H70126R00019","notice_type":"o","base_type":"p","posted":"2026-04-01","posted_at":null,"due_at":"2026-05-08T21:00:00Z","due_date":"2026-05-08","cancelled":null,"archived":null,"archive_date":"2026-05-23","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/597b99c7b5914dd081e88324bc5dd37d/view","enriched":false,"history":[]},{"notice_id":"159cff8be9e044c48ea5edb28b9aa200","title":"Lame Deer Heliport and Concrete Support Structure Remediation","solicitation_number":"75H70126R00019","notice_type":"o","base_type":"o","posted":"2026-04-15","posted_at":null,"due_at":"2026-05-08T21:00:00Z","due_date":"2026-05-08","cancelled":null,"archived":null,"archive_date":"2026-05-23","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/159cff8be9e044c48ea5edb28b9aa200/view","enriched":false,"history":[]},{"notice_id":"06419caa59294f1cbd5dcd630db0802a","title":"Lame Deer Heliport and Concrete Support Structure Remediation","solicitation_number":"75H70126R00019","notice_type":"o","base_type":"o","posted":"2026-04-17","posted_at":null,"due_at":"2026-05-08T21:00:00Z","due_date":"2026-05-08","cancelled":null,"archived":null,"archive_date":"2026-05-23","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/06419caa59294f1cbd5dcd630db0802a/view","enriched":false,"history":[]},{"notice_id":"fd3cf9cff0cd4b179adab747ffb0cb3b","title":"Grindstone Water Storage Tank Replacement","solicitation_number":"75H70126R00008","notice_type":"o","base_type":"p","posted":"2026-05-04","posted_at":null,"due_at":"2026-06-03T19:00:00Z","due_date":"2026-06-03","cancelled":null,"archived":null,"archive_date":"2026-06-18","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/fd3cf9cff0cd4b179adab747ffb0cb3b/view","enriched":false,"history":[]},{"notice_id":"52d67ba839914a85b80aed3c8086384a","title":"Lame Deer Heliport and Concrete Support Structure Remediation","solicitation_number":"75H70126R00019","notice_type":"o","base_type":"o","posted":"2026-05-05","posted_at":null,"due_at":"2026-05-20T21:00:00Z","due_date":"2026-05-20","cancelled":null,"archived":null,"archive_date":"2026-06-04","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/52d67ba839914a85b80aed3c8086384a/view","enriched":false,"history":[]},{"notice_id":"d5ed531594ee44fc9dd94eb7838c72c0","title":"Lame Deer Heliport and Concrete Support Structure Remediation","solicitation_number":"75H70126R00019","notice_type":"o","base_type":"o","posted":"2026-05-07","posted_at":null,"due_at":"2026-05-20T21:00:00Z","due_date":"2026-05-20","cancelled":null,"archived":null,"archive_date":"2026-06-04","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/d5ed531594ee44fc9dd94eb7838c72c0/view","enriched":false,"history":[]},{"notice_id":"2cd7167fa74b451180ff52e20d71368d","title":"Grindstone Water Storage Tank Replacement","solicitation_number":"75H70126R00008","notice_type":"o","base_type":"o","posted":"2026-05-19","posted_at":null,"due_at":"2026-06-03T19:00:00Z","due_date":"2026-06-03","cancelled":null,"archived":null,"archive_date":"2026-06-18","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/2cd7167fa74b451180ff52e20d71368d/view","enriched":false,"history":[]},{"notice_id":"b32fe6b4b11a4b2a93ea0a31c15b5eca","title":"Grindstone Water Storage Tank Replacement","solicitation_number":"75H70126R00008","notice_type":"o","base_type":"o","posted":"2026-05-26","posted_at":null,"due_at":"2026-06-03T19:00:00Z","due_date":"2026-06-03","cancelled":null,"archived":null,"archive_date":"2026-06-18","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/b32fe6b4b11a4b2a93ea0a31c15b5eca/view","enriched":false,"history":[]},{"notice_id":"53fdf3c0672b4affbac89b047f476a62","title":"Grindstone Water Storage Tank Replacement","solicitation_number":"75H70126R00008","notice_type":"o","base_type":"o","posted":"2026-06-02","posted_at":null,"due_at":"2026-06-03T19:00:00Z","due_date":"2026-06-03","cancelled":null,"archived":null,"archive_date":"2026-06-18","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/53fdf3c0672b4affbac89b047f476a62/view","enriched":false,"history":[]},{"notice_id":"ff561f9766ba4ac09dfcdef2a5ae2784","title":"Grindstone Water Storage Tank Replacement","solicitation_number":"75H70126C","notice_type":"a","base_type":"o","posted":"2026-06-30","posted_at":null,"due_at":null,"due_date":null,"cancelled":null,"archived":null,"archive_date":"2026-07-15","award_number":"75H70126C00022","awardee_name":"S.T.RHOADES CONSTRUCTION INCORPORATED Redding","amount":"1050150.00","link_sam":"https://sam.gov/workspace/contract/opp/ff561f9766ba4ac09dfcdef2a5ae2784/view","enriched":false,"history":[]},{"notice_id":"5538b7f63b284bcea9b95a449b41deca","title":"Lame Deer Heliport and Concrete Support Structure Remediation","solicitation_number":"75H70126C","notice_type":"a","base_type":"o","posted":"2026-08-31","posted_at":null,"due_at":null,"due_date":null,"cancelled":null,"archived":null,"archive_date":"2026-09-15","award_number":"75H70126C00024","awardee_name":"T. F. Powers Construction Co Fargo","amount":"3775028.00","link_sam":"https://sam.gov/workspace/contract/opp/5538b7f63b284bcea9b95a449b41deca/view","enriched":false,"history":[]}],"latest_notice_id":"5538b7f63b284bcea9b95a449b41deca","first_type":"r","notices":[{"dates":{"posted":"2025-11-05","response_deadline":{"raw":"2025-11-20T16:00:00-08:00","utc":"2025-11-21T00:00:00Z","date":"2025-11-20","time":"16:00:00","utc_offset_seconds":-28800}},"links":{"sam":"https://sam.gov/workspace/contract/opp/9d6f445b6d744bbdb6eae65f73ee2ed4/view"},"naics":{"codes":["237110"],"primary":"237110"},"title":"Grindstone Water Storage Tank & Treatment Monitoring","agency":{"office":{"code":"75H701","name":"DIV OF ENGINEERING SVCS - SEATTLE"},"subtier":{"code":"7527","name":"INDIAN HEALTH SERVICE"},"department":{"code":"075","name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF"},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-12-05","archive_type":"auto15"},"contacts":[{"name":"Thupten Tsering","role":"primary","email":"Thupten.Tsering@ihs.gov","phone":"2066152452"}],"base_type":{"code":"r","label":"Sources Sought"},"notice_id":"9d6f445b6d744bbdb6eae65f73ee2ed4","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T17:48:36.003679Z","row_sha256":"1dfc11945820722a58fa43dbf9575bef5304097ebd9889c5c7fb6cc4b5fbed2c","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T17:48:36.003679Z","first_seen_at":"2026-09-16T17:48:36.003679Z"},"description":{"text":"The Indian Health Service (IHS) is conducting a SOURCES SOUGHT/REQUEST FOR INFORMATION as outlined in FAR 15.201(c)(3) to gain knowledge of interest, capabilities, and qualifications of firms especially small businesses including: Native American/Indian-Owned Businesses, 8(a) Certified Small Businesses, Historically Underutilized Business Zones (HUB-Zone) Small Businesses, Women Owned Small Businesses, Service Disabled Veteran-Owned Small Businesses (SDVOSB), Small Disadvantaged Businesses (SDB), and Veteran Owned Small Businesses. This notice is intended strictly for Market Research to determine if a 100% Set Aside for Indian Economic Enterprise (IEE) Firms or if a 100% Set Aside for Small business concerns can fulfill the requirements set forth in this request for information (RFI). Interested firms are requested to reply to this announcement with a submittal as described below. NO PROPOSALS ARE BEING REQUESTED OR ACCEPTED WITH THIS RFI. THIS IS NOT A SOLICITATION FOR PROPOSALS. Respondents will NOT be notified of the results of this notice. No reimbursement will be made for any costs associated with providing information in response to this notice or any follow-up information requested. Market Research is being performed pursuant to Federal Acquisition Regulation (FAR) Part 10 to identify businesses capable of performing the functions described herein. LOCATION OF PROJECT: Elk Creek, CA TERO is not applicable CONSTRUCTION DURATION: Period of Performance is 180 calendar days after issuance of a Notice to Proceed. SET-ASIDE: The appropriate set-aside will be finalized based on the results of this sources sought. It is anticipated that this project will be procured as a 100% Small Business set-aside under North American Industry Classification System (NAICS) code 237110 Water and Sewer Line and Related Structures Construction with a size standard of $45 million. For information concerning NAICS and SBA size standards, go to https://www.sba.gov SUMMARY OF SCOPE The purpose of this contract is to Replace a water storage tank, remove old tanks, and install water quality monitoring equipment at the Grindstone Indian Rancheria. RESPONSES – SUBMITTAL Responses to this notice must be emailed to the Contract Specialist, Thupten Tsering, at thupten.tsering@ihs.gov and must be received no later than the due date and time identified in the SAM.gov posting. In the absence of the Contract Specialist, responses may be submitted to the Contracting Officer, Andrew Hart, at andrew.hart@ihs.gov Interested firms shall utilize the attached \"Sources Sought Submittal Questionnaire\" (attachment 1) to provide the required information on the questionnaire. **For Indian owned business, the contractor shall complete and submit Attachment 2: IHS IEE Representation Form (Jan 2022). Please note that there shall be no personally identifiable information (PII), such as social security numbers, included in the documentation submitted. Any PII shall be redacted prior to submission. **For Indian owned business, the contractor shall complete and submit a narrative addressing the following questions: How is your company structured to handle quality control of the various disciplines of a construction project? (i.e., what position(s) (full-time/part-time) are employed under your company to perform QC?) Does your company primarily handle the construction activities related to construction management by the prime contractor and if so, what are those activities? Does your company self-perform any of the construction disciplines, if so, what are those disciplines? All information received in response to this source sought that is marked proprietary will be handled accordingly. Documents and/or information other than what is requested will not be reviewed. Information submitted beyond what is requested will not be considered. QUESTIONS: Questions regarding this sources sought may be emailed to Thupten Tsering at thupten.tsering@ihs.gov In the absence of the Contract Specialist, questions may be submitted to the Contracting Officer, Andrew Hart, at andrew.hart@ihs.gov NOTE: Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at www.sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the government may not delay award for the purpose of allowing a contractor additional time to register in SAM. This notice is for informational purposes only and is NOT a request for submission of offers. No other information is available until issuance of the solicitation itself. No bidder list is maintained. All potential offerors should register with www.sam.gov if interested in this forthcoming acquisition. Upon issuance of the solicitation, all responsible sources may submit a bid, proposal, or quotation which shall be considered by the agency.","origin":"extract"},"notice_type":{"code":"r","label":"Sources Sought"},"schema_version":1,"solicitation_number":"75H70126R00008","place_of_performance":{"zip":"95939","city":{"name":"Elk Creek"},"state":{"code":"CA"},"country":{"code":"USA"}}},{"dates":{"posted":"2025-12-11","response_deadline":{"raw":"2025-12-22T16:00:00-07:00","utc":"2025-12-22T23:00:00Z","date":"2025-12-22","time":"16:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/51818307cc184f2b9ce5778d7f0a1a84/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Lame Deer Heliport and Concrete Support Structure Remediation","agency":{"office":{"code":"75H701","name":"DIV OF ENGINEERING SVCS - SEATTLE"},"subtier":{"code":"7527","name":"INDIAN HEALTH SERVICE"},"department":{"code":"075","name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF"},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-01-06","archive_type":"auto15"},"contacts":[{"name":"Matt D Sanders","role":"primary","email":"matt.sanders@ihs.gov","phone":"240-472-6176"},{"name":"Andrew E. Hart","role":"secondary","email":"andrew.hart@ihs.gov","phone":"2066152453"}],"base_type":{"code":"r","label":"Sources Sought"},"notice_id":"51818307cc184f2b9ce5778d7f0a1a84","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T17:48:36.003679Z","row_sha256":"d65b7b7807e4b7761a5fd2690ca369d02d4738b2714870f1934ba4615d93743e","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T17:48:36.003679Z","first_seen_at":"2026-09-16T17:48:36.003679Z"},"description":{"text":"The Indian Health Service (IHS) is conducting a second SOURCES SOUGHT/REQUEST FOR INFORMATION as outlined in FAR 15.201(c)(3) to gain knowledge of interest, capabilities, and qualifications of firms especially small businesses including: Native American/Indian-Owned Businesses (Indian Economic Enterprise (IEE)), 8(a) Certified Small Businesses, Historically Underutilized Business Zones (HUB-Zone) Small Businesses, Women Owned Small Businesses, Service Disabled Veteran-Owned Small Businesses (SDVOSB), Small Disadvantaged Businesses (SDB), and Veteran Owned Small Businesses. NO PROPOSALS ARE BEING REQUESTED OR ACCEPTED WITH THIS RFI. THIS IS NOT A SOLICITATION FOR PROPOSALS. Respondents will NOT be notified of the results of this notice. No reimbursement will be made for any costs associated with providing information in response to this notice or any follow-up information requested. Market Research is being performed pursuant to Federal Acquisition Regulation (FAR) Part 10 to identify businesses capable of performing the functions described herein. SUMMARY OF SCOPE The existing heliport at the Northern Cheyenne Health Center in Lame Deer, Montana is failing due to concrete cracking and spalling and requires complete replacement. The facility’s structural support systems for the ambulance bay, emergency entrance, and loading dock have also failed and require remediation to restore full operational capacity. The project includes the full demolition and replacement of the existing heliport along with structural concrete remediation work at the ambulance bay, emergency entrance, and loading dock. Major elements of work include: Demolition, reconstruction, and commissioning of the medical facility’s heliport, including all associated airfield concrete work; Construction of sidewalks and ramps for patient transport between the heliport and the facility; Installation of an electrical lighting system suitable for nighttime and low-visibility helicopter operations; Replacement of the heliport safety fence, access gates, and associated site improvements; Structural concrete remediation including installation of new beams, columns, and concrete flooring for the ambulance bay and drive, emergency entrance, and loading dock; Installation of a crawlspace HVAC system to reduce humidity levels. The Period of Performance will be approximately 120 calendar days from the date of the Notice to Proceed. A winter exclusionary period may be authorized depending on the Notice to Proceed date. The anticipated project magnitude is between $1,000,000 and $5,000,000. The type of work to be performed will be categorized under PSC code Z2BZ, Repair Or Alteration Of Other Airfield Structures and NAICS code 237310 Highway, Street, and Bridge Construction with a size standard of $45 million. RESPONSES - SUBMITTAL Responses to this notice must be emailed to Matt Sanders at matt.sanders@ihs.gov and must be received no later than 4:00 pm MST, Monday, 22 Dec 2025. Responses must include: Company Information: Company name, website, physical address, SAM UEI code Point of Contact: Contact name, phone number, and E-mail address If a solicitation is issued, will your firm/company be submitting a proposal? Indicate Yes or No Type of Business: Native American-owned (IEE/ISBEE), SBA certified 8(a), SBA Certified HUB Zone, Service Disabled Veteran-Owned Small Businesses (SDVOSB), Women Owned Small Business (WOSB), and/or Small Businesses (SB). For more information on the definitions or requirements for these small business programs, refer to http://www.sba.gov. Native American-owned (IEE/ISBEE) firms SHALL submit the following TWO Documents: Completed and signed Attachment 1: IHS IEE Representation Form (Jan 2022) The controlling enterprise’s Department of the Interior, Bureau of Indian Affairs Certificate of Degree of Indian Blood documentation. NOTE: ISBEE firms that submit only one of the above documents WILL NOT be considered an ISBEE firm for the purposes of this sources sought. BOTH Documents must be submitted for ISBEE confirmation. Please note that there shall be no personally identifiable information (PII), such as social security numbers, included in the documentation submitted. Any PII shall be redacted prior to submission. Bond Capacity: Information on the firm's bonding capability - specifically identify single and aggregate bonding capacities. Experience Submission Requirements: IHS is seeking capability information from firms that can perform BOTH (1) heliport demolition and construction AND (2) structural concrete remediation of building support systems. Respondents must demonstrate experience in both areas. A lack of experience in either heliport demolition/construction or structural concrete remediation will result in a determination that the respondent is not capable of performing this requirement. Respondents that only state that they could perform both requirements without submitting real experience indicating as such will also be considered non-capable. Respondents are requested to submit at least two (2) but no more than five (5) projects completed by your firm within the last seven (7) years that are similar to the work that will be required under this project. Firms shall include the following information for each project: Indicate whether Prime Contractor or Subcontractor for each project submitted; Dates of construction for each project submitted; Contract value, location, completion date, and complexity of job for each project submitted; Indicate whether the project is a federal, state, tribal or other for each project submitted; and Project references/Agency point of contact (telephone number and email address) for each project submitted. If the entity responding to this sources sought is submitting experience information from any entity that does not match the name, CAGE code, and/or UEI exactly as stated on the submitting entity’s SAM record (e.g. affiliates, subsidiaries, parent companies, sister companies, etc.) the submission shall clearly demonstrate how that entity will have meaningful involvement in the performance of the contract and specifically address which resources would be committed to the contract. Failure to comply with this requirement or failure to adequately demonstrate meaningful involvement and commitment of resources on behalf of that entity may result in that experience information to be considered not relevant. ADDITIONAL INFORMATION: Pursuant to 48 CFR Part 326, Subpart 326.603-3 and IHM 5.5-6, Indian Health Service must use the negotiation authority of the Buy Indian Act, 25 U.S.C. 47, to give preference to Indian Economic Enterprises (IEE) whenever the use of that authority is authorized and practicable. Any IEE/ISBEE firm responding to this notice should submit their capability statement as well as the Buy Indian Act Indian Economic Enterprise Representation Form (attached). All Small Businesses are highly encouraged to respond to this notice. However, firms should understand that generic capability statements are not sufficient for effective evaluation of their capacity and capability to perform the work required. Please note that a decision not to submit a response to this request for information will not preclude a firm from participating in any future solicitation. All information received in response to this source sought that is marked proprietary will be handled accordingly. Documents and/or information other than what is requested will not be reviewed. Information submitted beyond what is requested will not be considered. QUESTIONS: Questions regarding this sources sought may be emailed to Matt Sanders at matt.sanders@ihs.gov or Andrew Hart at Andrew.hart@ihs.gov.","origin":"extract"},"notice_type":{"code":"r","label":"Sources Sought"},"schema_version":1,"solicitation_number":"75H70126R00019","place_of_performance":{"zip":"59043","city":{"name":"Lame Deer"},"state":{"code":"MT"},"country":{"code":"USA"}},"product_service_code":"Z2BZ"},{"dates":{"posted":"2026-01-16","response_deadline":{"raw":"2026-02-02T14:00:00-08:00","utc":"2026-02-02T22:00:00Z","date":"2026-02-02","time":"14:00:00","utc_offset_seconds":-28800}},"links":{"sam":"https://sam.gov/workspace/contract/opp/e3ae7fd0d1e84e8599b7318e44cb499f/view"},"naics":{"codes":["237110"],"primary":"237110"},"title":"Grindstone Water Storage Tank Replacement","agency":{"office":{"code":"75H701","name":"DIV OF ENGINEERING SVCS - SEATTLE"},"subtier":{"code":"7527","name":"INDIAN HEALTH SERVICE"},"department":{"code":"075","name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF"},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-02-17","archive_type":"auto15"},"contacts":[{"name":"Thupten Tsering","role":"primary","email":"Thupten.Tsering@ihs.gov","phone":"2066152452"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"e3ae7fd0d1e84e8599b7318e44cb499f","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T16:22:53.920682Z","row_sha256":"eb63dd153d46adfd632edca6696cb3923319df38623fc229082f0ff38d702fc4","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T16:22:53.920682Z","first_seen_at":"2026-09-16T16:22:53.920682Z"},"description":{"text":"This is a PRE-SOLICITATION NOTICE for Solicitation 75H70126R00008, a construction project for the Indian Health Service (IHS) Division of Engineering Services (DES). The purpose of this project will be the removal of two water storage tanks (60,000 and 30,000 gallons) and installation of one 135,000-gallon water storage tank for the Grinstone Rancheria located in Elk Creek, CA. Included in this installation will be equipment required for communication and monitoring as well as startup and training for up to four individuals. All work shall be completed in accordance with the SOW, specifications, drawings, and other documents incorporated via amendment. This project will be procured as a Total Small Business Set-Aside solicitation under North American Industry Classification System (NAICS) code 237110 Water and Sewer Line and Related Structures Construction with a size standard of $45 million. The Product Service Code (PSC) for this procurement is Y1ND Construction of Sewage and Waste Facilities. The offeror must possess a current registration in SAM.gov as a small business under this NAICS to be eligible for award. The Government anticipates releasing the solicitation in late January 2026 with proposals due at least 30 calendar days after solicitation issuance. This date is subject to change. A full scope of work, plans and specifications and Davis Bacon Wage Determination will be included in the solicitation documents. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at www.sam.gov for download by interested parties. SCOPE AND LOCATION OF WORK: Elk Creek, CA In accordance with FAR 52.237-1 Offerors are urged and expected to inspect the site where services are to be performed and to satisfy themselves regarding all general and local conditions that may affect the cost of contract performance, to the extent that the information is reasonably obtainable. In no event shall failure to inspect the site constitute grounds for a claim after contract award. SITE VISIT: The date, time, and location of a site visit will be specified in the solicitation. TERO: TERO fees do not apply. CONSTRUCTION DURATION: Period of Performance is 180 calendar days after issuance of a Notice to Proceed. CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be less than $1,200,000.00. CONTRACT TYPE: The IHS intends to award a Firm Fixed Price (FFP) construction contract in support of this requirement. NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES. For the purposes of this procurement, a concern is considered a small business if its average annual revenue for the last three (3) years is less than $45 million. For information concerning NAICS and SBA size standards, go to www.sba.gov. It is the responsibility of the contractor to check www.sam.gov frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties. This solicitation will be procured as a Request for Proposal (RFP) in accordance with FAR Part 15 and 36 procedures with price only evaluation criteria. NOTE: Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at: https://www.sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the government may not delay award for the purpose of allowing a contractor additional time to register in SAM. This notice is for informational purposes only and is NOT a request for submission of offers. No other information is available until issuance of the solicitation itself. No bidder list is maintained. All potential bidders should register with https://www.sam.gov if interested in this forthcoming acquisition.","origin":"extract"},"notice_type":{"code":"p","label":"Presolicitation"},"schema_version":1,"solicitation_number":"75H70126R00008","place_of_performance":{"zip":"95939","city":{"name":"Elk Creek"},"state":{"code":"CA"},"country":{"code":"USA"}},"product_service_code":"Y1NE"},{"dates":{"posted":"2026-02-23","response_deadline":{"raw":"2026-03-10T16:00:00-07:00","utc":"2026-03-10T23:00:00Z","date":"2026-03-10","time":"16:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/9280501a791049ad9aac16b93c7e17ac/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Lame Deer Heliport and Concrete Support Structure Remediation","agency":{"office":{"code":"75H701","name":"DIV OF ENGINEERING SVCS - SEATTLE"},"subtier":{"code":"7527","name":"INDIAN HEALTH SERVICE"},"department":{"code":"075","name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF"},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-03-25","archive_type":"auto15"},"contacts":[{"name":"Matt D Sanders","role":"primary","email":"matt.sanders@ihs.gov","phone":"240-472-6176"},{"name":"Andrew E. Hart","role":"secondary","email":"andrew.hart@ihs.gov","phone":"2066152453"}],"base_type":{"code":"r","label":"Sources Sought"},"notice_id":"9280501a791049ad9aac16b93c7e17ac","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T16:22:53.920682Z","row_sha256":"3a4f2d6377d36d4c7a61f148214fca589a293c82f77323cce1ff9d8dbeac694a","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T16:22:53.920682Z","first_seen_at":"2026-09-16T16:22:53.920682Z"},"description":{"text":"This is a PRESOLICITATION NOTICE for the upcoming Solicitation 75H70126R00019 Lame Deer Heliport and Structure Remediation, located in Lame Deer, MT. These construction services will be in support of the Indian Health Service (IHS) prepared in accordance with FAR Part 36. The Government anticipates releasing the solicitation on or about 10 March 2026 and will remain open for approximately 30 calendar days. The solicitation and all amendments for this Request for Proposals will be posted on https://sam.gov under Contract Opportunities. A full scope of work, plans and specifications and Construction Wage Determination will be included in the solicitation documents. Additional details can be found in the solicitation when it is posted to https://sam.gov. SCOPE OF WORK: The existing heliport at the Northern Cheyenne Health Center in Lame Deer, Montana is failing due to concrete cracking and spalling and requires complete replacement. The facility’s structural support systems for the ambulance bay, emergency entrance, and loading dock have also failed and require remediation to restore full operational capacity. The project includes the full demolition and replacement of the existing heliport along with structural concrete remediation work at the ambulance bay, emergency entrance, and loading dock. Major elements of work include: o Demolition, reconstruction, and commissioning of the medical facility’s heliport, including all associated airfield concrete work; o Construction of sidewalks and ramps for patient transport between the heliport and the facility; o Installation of an electrical lighting system suitable for nighttime and low-visibility helicopter operations; o Replacement of the heliport safety fence, access gates, and associated site improvements; o Structural concrete remediation including installation of new beams, columns, and concrete flooring for the ambulance bay and drive, emergency entrance, and loading dock; o Installation of a crawlspace HVAC system to reduce humidity levels. Firms that respond to the upcoming solicitation must demonstrate recent experience (within the past 6 years) with both (1) heliport or airfield demolition/construction AND (2) structural concrete remediation of building support systems. A lack of experience in either requirement may result in a determination that the respondent is not capable of performing this requirement. LOCATION OF PROJECT: All work shall be performed at the Northern Cheyenne Health Center at 420 Cheyenne Ave, Lame Deer, MT 59043 TERO: TERO fees do apply. (More information will be released in solicitation, but the TERO contact can be reached at 406-477-6287 CONSTRUCTION DURATION: Period of Performance is 120 calendar days from issuance of the Notice to Proceed. CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $1,000,000 and $5,000,000. SITE VISIT: Details regarding the Site Visit will be included in the solicitation. NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES. CONTRACT TYPE: The Indian Health Service intends to award a single Firm Fixed Price (FFP) contract in support of this requirement. This solicitation will be procured as a Request for Proposal (RFP) in accordance with FAR Part 36 procedures with Lowest Price Technically Acceptable (LPTA) evaluation criteria. This project will be solicited as Unrestricted, Full and Open, under North American Industry Classification System (NAICS) code 237310 Highway, Street, and Bridge Construction. The associated size standard for this procurement is $45 million. Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at: https://sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the Government may not delay award for the purpose of allowing a contractor additional time to register in SAM. It is the responsibility of the contractor to check https://sam.gov frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties. This notice is for informational purposes only and is NOT a request for submission of offers. No other information is available until issuance of the solicitation itself. No bidder list is maintained. Interested bidders should follow this solicitation notice on https://sam.gov to receive email notifications of any updates to the initial notice including any subsequent amendments. No additional information is available other than what is noted herein. Firms are instructed not to call requesting more information.","origin":"extract"},"notice_type":{"code":"p","label":"Presolicitation"},"schema_version":1,"solicitation_number":"75H70126R00019","place_of_performance":{"zip":"59043","city":{"name":"Lame Deer"},"state":{"code":"MT"},"country":{"code":"USA"}},"product_service_code":"Z2BZ"},{"dates":{"posted":"2026-04-01","response_deadline":{"raw":"2026-05-08T14:00:00-07:00","utc":"2026-05-08T21:00:00Z","date":"2026-05-08","time":"14:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/597b99c7b5914dd081e88324bc5dd37d/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Lame Deer Heliport and Concrete Support Structure Remediation","agency":{"office":{"code":"75H701","name":"DIV OF ENGINEERING SVCS - SEATTLE"},"subtier":{"code":"7527","name":"INDIAN HEALTH SERVICE"},"department":{"code":"075","name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF"},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-05-23","archive_type":"auto15"},"contacts":[{"name":"Matt D Sanders","role":"primary","email":"matt.sanders@ihs.gov","phone":"240-472-6176"},{"name":"Andrew E. Hart","role":"secondary","email":"andrew.hart@ihs.gov","phone":"2066152453"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"597b99c7b5914dd081e88324bc5dd37d","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T16:22:53.920682Z","row_sha256":"aac92a3b3aa1c6ff76478c888ac36997dc076b332e0f481589999922e6f69c0a","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T16:22:53.920682Z","first_seen_at":"2026-09-16T16:22:53.920682Z"},"description":{"text":"SCOPE OF WORK: The existing heliport at the Northern Cheyenne Health Center in Lame Deer, Montana is failing due to concrete cracking and spalling and requires complete replacement. The facility’s structural support systems for the ambulance bay, emergency entrance, and loading dock have also failed and require remediation to restore full operational capacity. The project includes the full demolition and replacement of the existing heliport along with structural concrete remediation work at the ambulance bay, emergency entrance, and loading dock. Major elements of work include: o Demolition, reconstruction, and commissioning of the medical facility’s heliport, including all associated airfield concrete work; o Construction of sidewalks and ramps for patient transport between the heliport and the facility; o Installation of an electrical lighting system suitable for nighttime and low-visibility helicopter operations; o Replacement of the heliport safety fence, access gates, and associated site improvements; o Structural concrete remediation including installation of new beams, columns, and concrete flooring for the ambulance bay and drive, emergency entrance, and loading dock; o Installation of a crawlspace HVAC system to reduce humidity levels. LOCATION OF PROJECT: All work shall be performed at the Northern Cheyenne Health Center at 420 Cheyenne Ave, Lame Deer, MT 59043 TERO: TERO fees do apply. CONSTRUCTION DURATION: Period of Performance is 120 calendar days from issuance of the Notice to Proceed. CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $1,000,000 and $5,000,000. SITE VISIT: See Section L.5 in the solicitation document. PSC/NAICS: The type of work to be performed will be categorized under PSC code Y1BZ, Construction Of Other Airfield Structures and NAICS code 237310 Highway, Street, and Bridge Construction with a size standard of $45 million. SET ASIDE: This solicitation is being issued as Unrestricted, Full and Open Competition.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"75H70126R00019","place_of_performance":{"zip":"59043","city":{"name":"Lame Deer"},"state":{"code":"MT"},"country":{"code":"USA"}},"product_service_code":"Y1BZ"},{"dates":{"posted":"2026-04-15","response_deadline":{"raw":"2026-05-08T14:00:00-07:00","utc":"2026-05-08T21:00:00Z","date":"2026-05-08","time":"14:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/159cff8be9e044c48ea5edb28b9aa200/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Lame Deer Heliport and Concrete Support Structure Remediation","agency":{"office":{"code":"75H701","name":"DIV OF ENGINEERING SVCS - SEATTLE"},"subtier":{"code":"7527","name":"INDIAN HEALTH SERVICE"},"department":{"code":"075","name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF"},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-05-23","archive_type":"auto15"},"contacts":[{"name":"Matt D Sanders","role":"primary","email":"matt.sanders@ihs.gov","phone":"240-472-6176"},{"name":"Andrew E. Hart","role":"secondary","email":"andrew.hart@ihs.gov","phone":"2066152453"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"159cff8be9e044c48ea5edb28b9aa200","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T16:22:53.920682Z","row_sha256":"1d56bf72dcc6c27350b1126fa333c02d028cc8eff584583ab94f109d63630da0","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T16:22:53.920682Z","first_seen_at":"2026-09-16T16:22:53.920682Z"},"description":{"text":"SCOPE OF WORK: The existing heliport at the Northern Cheyenne Health Center in Lame Deer, Montana is failing due to concrete cracking and spalling and requires complete replacement. The facility’s structural support systems for the ambulance bay, emergency entrance, and loading dock have also failed and require remediation to restore full operational capacity. The project includes the full demolition and replacement of the existing heliport along with structural concrete remediation work at the ambulance bay, emergency entrance, and loading dock. Major elements of work include: o Demolition, reconstruction, and commissioning of the medical facility’s heliport, including all associated airfield concrete work; o Construction of sidewalks and ramps for patient transport between the heliport and the facility; o Installation of an electrical lighting system suitable for nighttime and low-visibility helicopter operations; o Replacement of the heliport safety fence, access gates, and associated site improvements; o Structural concrete remediation including installation of new beams, columns, and concrete flooring for the ambulance bay and drive, emergency entrance, and loading dock; o Installation of a crawlspace HVAC system to reduce humidity levels. LOCATION OF PROJECT: All work shall be performed at the Northern Cheyenne Health Center at 420 Cheyenne Ave, Lame Deer, MT 59043 TERO: TERO fees do apply. CONSTRUCTION DURATION: Period of Performance is 120 calendar days from issuance of the Notice to Proceed. CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $1,000,000 and $5,000,000. SITE VISIT: See Section L.5 in the solicitation document. PSC/NAICS: The type of work to be performed will be categorized under PSC code Y1BZ, Construction Of Other Airfield Structures and NAICS code 237310 Highway, Street, and Bridge Construction with a size standard of $45 million. SET ASIDE: This solicitation is being issued as Unrestricted, Full and Open Competition. ***Amendment 01 issued 15 April 2026***","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"75H70126R00019","place_of_performance":{"zip":"59043","city":{"name":"Lame Deer"},"state":{"code":"MT"},"country":{"code":"USA"}},"product_service_code":"Y1BZ"},{"dates":{"posted":"2026-04-17","response_deadline":{"raw":"2026-05-08T14:00:00-07:00","utc":"2026-05-08T21:00:00Z","date":"2026-05-08","time":"14:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/06419caa59294f1cbd5dcd630db0802a/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Lame Deer Heliport and Concrete Support Structure Remediation","agency":{"office":{"code":"75H701","name":"DIV OF ENGINEERING SVCS - SEATTLE"},"subtier":{"code":"7527","name":"INDIAN HEALTH SERVICE"},"department":{"code":"075","name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF"},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-05-23","archive_type":"auto15"},"contacts":[{"name":"Matt D Sanders","role":"primary","email":"matt.sanders@ihs.gov","phone":"240-472-6176"},{"name":"Andrew E. Hart","role":"secondary","email":"andrew.hart@ihs.gov","phone":"2066152453"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"06419caa59294f1cbd5dcd630db0802a","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T16:22:53.920682Z","row_sha256":"c3718338d6977d53fe3b5840219e03ce63bd6dfe08f964ac8b1b564cec7ec380","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T16:22:53.920682Z","first_seen_at":"2026-09-16T16:22:53.920682Z"},"description":{"text":"SCOPE OF WORK: The existing heliport at the Northern Cheyenne Health Center in Lame Deer, Montana is failing due to concrete cracking and spalling and requires complete replacement. The facility’s structural support systems for the ambulance bay, emergency entrance, and loading dock have also failed and require remediation to restore full operational capacity. The project includes the full demolition and replacement of the existing heliport along with structural concrete remediation work at the ambulance bay, emergency entrance, and loading dock. Major elements of work include: o Demolition, reconstruction, and commissioning of the medical facility’s heliport, including all associated airfield concrete work; o Construction of sidewalks and ramps for patient transport between the heliport and the facility; o Installation of an electrical lighting system suitable for nighttime and low-visibility helicopter operations; o Replacement of the heliport safety fence, access gates, and associated site improvements; o Structural concrete remediation including installation of new beams, columns, and concrete flooring for the ambulance bay and drive, emergency entrance, and loading dock; o Installation of a crawlspace HVAC system to reduce humidity levels. LOCATION OF PROJECT: All work shall be performed at the Northern Cheyenne Health Center at 420 Cheyenne Ave, Lame Deer, MT 59043 TERO: TERO fees do apply. CONSTRUCTION DURATION: Period of Performance is 120 calendar days from issuance of the Notice to Proceed. CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $1,000,000 and $5,000,000. SITE VISIT: See Section L.5 in the solicitation document. PSC/NAICS: The type of work to be performed will be categorized under PSC code Y1BZ, Construction Of Other Airfield Structures and NAICS code 237310 Highway, Street, and Bridge Construction with a size standard of $45 million. SET ASIDE: This solicitation is being issued as Unrestricted, Full and Open Competition. ***Amendment 01 issued 15 April 2026*** ***Amendment 02 issued 17 April 2026***","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"75H70126R00019","place_of_performance":{"zip":"59043","city":{"name":"Lame Deer"},"state":{"code":"MT"},"country":{"code":"USA"}},"product_service_code":"Y1BZ"},{"dates":{"posted":"2026-05-04","response_deadline":{"raw":"2026-06-03T12:00:00-07:00","utc":"2026-06-03T19:00:00Z","date":"2026-06-03","time":"12:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/fd3cf9cff0cd4b179adab747ffb0cb3b/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Grindstone Water Storage Tank Replacement","agency":{"office":{"code":"75H701","name":"DIV OF ENGINEERING SVCS - SEATTLE"},"subtier":{"code":"7527","name":"INDIAN HEALTH SERVICE"},"department":{"code":"075","name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF"},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-06-18","archive_type":"auto15"},"contacts":[{"name":"Thupten Tsering","role":"primary","email":"Thupten.Tsering@ihs.gov","phone":"2066152452"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"fd3cf9cff0cd4b179adab747ffb0cb3b","set_aside":{"code":"ISBEE","label":"Indian Small Business Economic Enterprise (Department of the Interior)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T16:22:53.920682Z","row_sha256":"4e76f924607a217ee5ce51c87fb0006eb2922dc25d3750d21f2a9aa04616d138","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T16:22:53.920682Z","first_seen_at":"2026-09-16T16:22:53.920682Z"},"description":{"text":"See attached SOLICITATION NOTICE for solicitation number 75H70126R00008 for a construction project for the Indian Health Service (IHS). The purpose of this project is to remove (2) existing water storage tanks, install electrical control wire in conduit, and install equipment for water monitoring requirements. Project 17-N18 will replace the existing 60,000-gal tank with a new 135,000-gal bolted steel tank. After the new tank is brought online; the existing 60,000-gal tank will be removed from the site and the new tank will be enclosed by chain-link fence. Project 20-N65 will allow communication between the tank, tribal office building, and water treatment plant. The monitoring equipment will assist the tribe to meet requirements of the EPA -in order to comply with the surface water treatment rule. This project will be procured as a 100% set-aside for Indian Small Business Economic Enterprises (ISBEE) utilizing North American Industry Classification System (NAICS) code 236220 Commercial and Institutional Building Construction. The associated size standard for this procurement is $45 million. Please review all attachments to this notice for details. SCOPE OF WORK: See Section C of the attached solicitation for details. LOCATION OF PROJECT: Elk Creek, CA. See project documents. TERO: TERO fees do apply. CONSTRUCTION DURATION: Period of Performance is 180 calendar days after issuance of a Notice to Proceed. SITE VISIT: See FAR 52.236-27 CONTRACT TYPE: The IHS intends to award a Firm Fixed Price (FFP) construction contract in support of this requirement. This solicitation will be procured as a Request for Proposal (RFP) in accordance with FAR Part 15 and 36 procedures. PROPOSAL REQUIREMENTS: See Sections L&M of the solicitation. PROPOSAL DUE DATE: The offeror’s proposal shall be submitted electronically no later than the due date and time indicated in block 13 of the SF 1442, unless changed by amendment. EVALUATION: In accordance with FAR 15.101-2, the evaluation for this award will be based on the lowest price technically acceptable proposal (LPTA). See Sections L&M of the solicitation for specific requirements. Prices proposed must reflect the offeror’s understanding of the requirement, ability to perform, and be considered fair and reasonable to the Government. Price is the discriminating factor for award among eligible offers. The total firm fixed price listed in block 17 of the SF1442 shall be utilized for the overall price evaluation and to determine the lowest priced offer. QUESTIONS: Offerors shall submit all questions concerning this solicitation in writing to the Contract Specialist, Thupten Tsering, at Thupten.Tsering@ihs.gov NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES. For the purposes of this procurement, a concern is considered a small business if its average annual revenue for the last three (3) years is less than $45 million. For information concerning NAICS and SBA size standards, go to http://www.sba.gov. It is the responsibility of the contractor to check https://sam.gov/ frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties. NOTE: Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at: https://www.sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the government may not delay award for the purpose of allowing a contractor additional time to register in SAM.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"75H70126R00008","place_of_performance":{"zip":"95939","city":{"name":"Elk Creek"},"state":{"code":"CA"},"country":{"code":"USA"}},"product_service_code":"Y1NE"},{"dates":{"posted":"2026-05-05","response_deadline":{"raw":"2026-05-20T14:00:00-07:00","utc":"2026-05-20T21:00:00Z","date":"2026-05-20","time":"14:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/52d67ba839914a85b80aed3c8086384a/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Lame Deer Heliport and Concrete Support Structure Remediation","agency":{"office":{"code":"75H701","name":"DIV OF ENGINEERING SVCS - SEATTLE"},"subtier":{"code":"7527","name":"INDIAN HEALTH SERVICE"},"department":{"code":"075","name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF"},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-06-04","archive_type":"auto15"},"contacts":[{"name":"Matt D Sanders","role":"primary","email":"matt.sanders@ihs.gov","phone":"240-472-6176"},{"name":"Andrew E. Hart","role":"secondary","email":"andrew.hart@ihs.gov","phone":"2066152453"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"52d67ba839914a85b80aed3c8086384a","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T16:22:53.920682Z","row_sha256":"d35d15dd5b7a3c5b28eadd9405a8062651540d21d676887d8f779468646569fe","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T16:22:53.920682Z","first_seen_at":"2026-09-16T16:22:53.920682Z"},"description":{"text":"SCOPE OF WORK: The existing heliport at the Northern Cheyenne Health Center in Lame Deer, Montana is failing due to concrete cracking and spalling and requires complete replacement. The facility’s structural support systems for the ambulance bay, emergency entrance, and loading dock have also failed and require remediation to restore full operational capacity. The project includes the full demolition and replacement of the existing heliport along with structural concrete remediation work at the ambulance bay, emergency entrance, and loading dock. Major elements of work include: o Demolition, reconstruction, and commissioning of the medical facility’s heliport, including all associated airfield concrete work; o Construction of sidewalks and ramps for patient transport between the heliport and the facility; o Installation of an electrical lighting system suitable for nighttime and low-visibility helicopter operations; o Replacement of the heliport safety fence, access gates, and associated site improvements; o Structural concrete remediation including installation of new beams, columns, and concrete flooring for the ambulance bay and drive, emergency entrance, and loading dock; o Installation of a crawlspace HVAC system to reduce humidity levels. LOCATION OF PROJECT: All work shall be performed at the Northern Cheyenne Health Center at 420 Cheyenne Ave, Lame Deer, MT 59043 TERO: TERO fees do apply. CONSTRUCTION DURATION: Period of Performance is 120 calendar days from issuance of the Notice to Proceed. CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $1,000,000 and $5,000,000. SITE VISIT: See Section L.5 in the solicitation document. PSC/NAICS: The type of work to be performed will be categorized under PSC code Y1BZ, Construction Of Other Airfield Structures and NAICS code 237310 Highway, Street, and Bridge Construction with a size standard of $45 million. SET ASIDE: This solicitation is being issued as Unrestricted, Full and Open Competition. ***Amendment 01 issued 15 April 2026*** ***Amendment 02 issued 17 April 2026*** ***Amendment 03 issued 05 May 2026***","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"75H70126R00019","place_of_performance":{"zip":"59043","city":{"name":"Lame Deer"},"state":{"code":"MT"},"country":{"code":"USA"}},"product_service_code":"Y1BZ"},{"dates":{"posted":"2026-05-07","response_deadline":{"raw":"2026-05-20T14:00:00-07:00","utc":"2026-05-20T21:00:00Z","date":"2026-05-20","time":"14:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/d5ed531594ee44fc9dd94eb7838c72c0/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Lame Deer Heliport and Concrete Support Structure Remediation","agency":{"office":{"code":"75H701","name":"DIV OF ENGINEERING SVCS - SEATTLE"},"subtier":{"code":"7527","name":"INDIAN HEALTH SERVICE"},"department":{"code":"075","name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF"},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-06-04","archive_type":"auto15"},"contacts":[{"name":"Matt D Sanders","role":"primary","email":"matt.sanders@ihs.gov","phone":"240-472-6176"},{"name":"Andrew E. Hart","role":"secondary","email":"andrew.hart@ihs.gov","phone":"2066152453"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"d5ed531594ee44fc9dd94eb7838c72c0","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T16:22:53.920682Z","row_sha256":"ad91f555c0f98835b81336d07c325a5964deeb0f48a40650c7b42ab520d1deff","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T16:22:53.920682Z","first_seen_at":"2026-09-16T16:22:53.920682Z"},"description":{"text":"SCOPE OF WORK: The existing heliport at the Northern Cheyenne Health Center in Lame Deer, Montana is failing due to concrete cracking and spalling and requires complete replacement. The facility’s structural support systems for the ambulance bay, emergency entrance, and loading dock have also failed and require remediation to restore full operational capacity. The project includes the full demolition and replacement of the existing heliport along with structural concrete remediation work at the ambulance bay, emergency entrance, and loading dock. Major elements of work include: o Demolition, reconstruction, and commissioning of the medical facility’s heliport, including all associated airfield concrete work; o Construction of sidewalks and ramps for patient transport between the heliport and the facility; o Installation of an electrical lighting system suitable for nighttime and low-visibility helicopter operations; o Replacement of the heliport safety fence, access gates, and associated site improvements; o Structural concrete remediation including installation of new beams, columns, and concrete flooring for the ambulance bay and drive, emergency entrance, and loading dock; o Installation of a crawlspace HVAC system to reduce humidity levels. LOCATION OF PROJECT: All work shall be performed at the Northern Cheyenne Health Center at 420 Cheyenne Ave, Lame Deer, MT 59043 TERO: TERO fees do apply. CONSTRUCTION DURATION: Period of Performance is 120 calendar days from issuance of the Notice to Proceed. CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $1,000,000 and $5,000,000. SITE VISIT: See Section L.5 in the solicitation document. PSC/NAICS: The type of work to be performed will be categorized under PSC code Y1BZ, Construction Of Other Airfield Structures and NAICS code 237310 Highway, Street, and Bridge Construction with a size standard of $45 million. SET ASIDE: This solicitation is being issued as Unrestricted, Full and Open Competition. ***Amendment 01 issued 15 April 2026*** ***Amendment 02 issued 17 April 2026*** ***Amendment 03 issued 05 May 2026*** ***Amendment 04 issued 07 May 2026***","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"75H70126R00019","place_of_performance":{"zip":"59043","city":{"name":"Lame Deer"},"state":{"code":"MT"},"country":{"code":"USA"}},"product_service_code":"Y1BZ"},{"dates":{"posted":"2026-05-19","response_deadline":{"raw":"2026-06-03T12:00:00-07:00","utc":"2026-06-03T19:00:00Z","date":"2026-06-03","time":"12:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/2cd7167fa74b451180ff52e20d71368d/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Grindstone Water Storage Tank Replacement","agency":{"office":{"code":"75H701","name":"DIV OF ENGINEERING SVCS - SEATTLE"},"subtier":{"code":"7527","name":"INDIAN HEALTH SERVICE"},"department":{"code":"075","name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF"},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-06-18","archive_type":"auto15"},"contacts":[{"name":"Thupten Tsering","role":"primary","email":"Thupten.Tsering@ihs.gov","phone":"2066152452"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"2cd7167fa74b451180ff52e20d71368d","set_aside":{"code":"ISBEE","label":"Indian Small Business Economic Enterprise (Department of the Interior)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T16:22:53.920682Z","row_sha256":"e7497aea26e4889988a72d013aef86384bb69ed0c7a51c01270ef68d0560b160","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T16:22:53.920682Z","first_seen_at":"2026-09-16T16:22:53.920682Z"},"description":{"text":"** See amendment 1 dated 5/19/2026 ** See attached SOLICITATION NOTICE for solicitation number 75H70126R00008 for a construction project for the Indian Health Service (IHS). The purpose of this project is to remove (2) existing water storage tanks, install electrical control wire in conduit, and install equipment for water monitoring requirements. Project 17-N18 will replace the existing 60,000-gal tank with a new 135,000-gal bolted steel tank. After the new tank is brought online; the existing 60,000-gal tank will be removed from the site and the new tank will be enclosed by chain-link fence. Project 20-N65 will allow communication between the tank, tribal office building, and water treatment plant. The monitoring equipment will assist the tribe to meet requirements of the EPA -in order to comply with the surface water treatment rule. This project will be procured as a 100% set-aside for Indian Small Business Economic Enterprises (ISBEE) utilizing North American Industry Classification System (NAICS) code 236220 Commercial and Institutional Building Construction. The associated size standard for this procurement is $45 million. Please review all attachments to this notice for details. SCOPE OF WORK: See Section C of the attached solicitation for details. LOCATION OF PROJECT: Elk Creek, CA. See project documents. TERO: TERO fees do apply. CONSTRUCTION DURATION: Period of Performance is 180 calendar days after issuance of a Notice to Proceed. SITE VISIT: See FAR 52.236-27 CONTRACT TYPE: The IHS intends to award a Firm Fixed Price (FFP) construction contract in support of this requirement. This solicitation will be procured as a Request for Proposal (RFP) in accordance with FAR Part 15 and 36 procedures. PROPOSAL REQUIREMENTS: See Sections L&M of the solicitation. PROPOSAL DUE DATE: The offeror’s proposal shall be submitted electronically no later than the due date and time indicated in block 13 of the SF 1442, unless changed by amendment. EVALUATION: In accordance with FAR 15.101-2, the evaluation for this award will be based on the lowest price technically acceptable proposal (LPTA). See Sections L&M of the solicitation for specific requirements. Prices proposed must reflect the offeror’s understanding of the requirement, ability to perform, and be considered fair and reasonable to the Government. Price is the discriminating factor for award among eligible offers. The total firm fixed price listed in block 17 of the SF1442 shall be utilized for the overall price evaluation and to determine the lowest priced offer. QUESTIONS: Offerors shall submit all questions concerning this solicitation in writing to the Contract Specialist, Thupten Tsering, at Thupten.Tsering@ihs.gov NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES. For the purposes of this procurement, a concern is considered a small business if its average annual revenue for the last three (3) years is less than $45 million. For information concerning NAICS and SBA size standards, go to http://www.sba.gov. It is the responsibility of the contractor to check https://sam.gov/ frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties. NOTE: Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at: https://www.sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the government may not delay award for the purpose of allowing a contractor additional time to register in SAM.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"75H70126R00008","place_of_performance":{"zip":"95939","city":{"name":"Elk Creek"},"state":{"code":"CA"},"country":{"code":"USA"}},"product_service_code":"Y1NE"},{"dates":{"posted":"2026-05-26","response_deadline":{"raw":"2026-06-03T12:00:00-07:00","utc":"2026-06-03T19:00:00Z","date":"2026-06-03","time":"12:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/b32fe6b4b11a4b2a93ea0a31c15b5eca/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Grindstone Water Storage Tank Replacement","agency":{"office":{"code":"75H701","name":"DIV OF ENGINEERING SVCS - SEATTLE"},"subtier":{"code":"7527","name":"INDIAN HEALTH SERVICE"},"department":{"code":"075","name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF"},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-06-18","archive_type":"auto15"},"contacts":[{"name":"Thupten Tsering","role":"primary","email":"Thupten.Tsering@ihs.gov","phone":"2066152452"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"b32fe6b4b11a4b2a93ea0a31c15b5eca","set_aside":{"code":"ISBEE","label":"Indian Small Business Economic Enterprise (Department of the Interior)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T16:22:53.920682Z","row_sha256":"efa73ad43b3d7d7c36e06c35aefef55ff94f577e49415f3273886e50ea02e356","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T16:22:53.920682Z","first_seen_at":"2026-09-16T16:22:53.920682Z"},"description":{"text":"** See amendment 1 dated 5/19/2026 ** ** See amendment 2 dated 5/26/2026 ** See attached SOLICITATION NOTICE for solicitation number 75H70126R00008 for a construction project for the Indian Health Service (IHS). The purpose of this project is to remove (2) existing water storage tanks, install electrical control wire in conduit, and install equipment for water monitoring requirements. Project 17-N18 will replace the existing 60,000-gal tank with a new 135,000-gal bolted steel tank. After the new tank is brought online; the existing 60,000-gal tank will be removed from the site and the new tank will be enclosed by chain-link fence. Project 20-N65 will allow communication between the tank, tribal office building, and water treatment plant. The monitoring equipment will assist the tribe to meet requirements of the EPA -in order to comply with the surface water treatment rule. This project will be procured as a 100% set-aside for Indian Small Business Economic Enterprises (ISBEE) utilizing North American Industry Classification System (NAICS) code 236220 Commercial and Institutional Building Construction. The associated size standard for this procurement is $45 million. Please review all attachments to this notice for details. SCOPE OF WORK: See Section C of the attached solicitation for details. LOCATION OF PROJECT: Elk Creek, CA. See project documents. TERO: TERO fees do apply. CONSTRUCTION DURATION: Period of Performance is 180 calendar days after issuance of a Notice to Proceed. SITE VISIT: See FAR 52.236-27 CONTRACT TYPE: The IHS intends to award a Firm Fixed Price (FFP) construction contract in support of this requirement. This solicitation will be procured as a Request for Proposal (RFP) in accordance with FAR Part 15 and 36 procedures. PROPOSAL REQUIREMENTS: See Sections L&M of the solicitation. PROPOSAL DUE DATE: The offeror’s proposal shall be submitted electronically no later than the due date and time indicated in block 13 of the SF 1442, unless changed by amendment. EVALUATION: In accordance with FAR 15.101-2, the evaluation for this award will be based on the lowest price technically acceptable proposal (LPTA). See Sections L&M of the solicitation for specific requirements. Prices proposed must reflect the offeror’s understanding of the requirement, ability to perform, and be considered fair and reasonable to the Government. Price is the discriminating factor for award among eligible offers. The total firm fixed price listed in block 17 of the SF1442 shall be utilized for the overall price evaluation and to determine the lowest priced offer. QUESTIONS: Offerors shall submit all questions concerning this solicitation in writing to the Contract Specialist, Thupten Tsering, at Thupten.Tsering@ihs.gov NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES. For the purposes of this procurement, a concern is considered a small business if its average annual revenue for the last three (3) years is less than $45 million. For information concerning NAICS and SBA size standards, go to http://www.sba.gov. It is the responsibility of the contractor to check https://sam.gov/ frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties. NOTE: Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at: https://www.sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the government may not delay award for the purpose of allowing a contractor additional time to register in SAM.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"75H70126R00008","place_of_performance":{"zip":"95939","city":{"name":"Elk Creek"},"state":{"code":"CA"},"country":{"code":"USA"}},"product_service_code":"Y1NE"},{"dates":{"posted":"2026-06-02","response_deadline":{"raw":"2026-06-03T12:00:00-07:00","utc":"2026-06-03T19:00:00Z","date":"2026-06-03","time":"12:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/53fdf3c0672b4affbac89b047f476a62/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Grindstone Water Storage Tank Replacement","agency":{"office":{"code":"75H701","name":"DIV OF ENGINEERING SVCS - SEATTLE"},"subtier":{"code":"7527","name":"INDIAN HEALTH SERVICE"},"department":{"code":"075","name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF"},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-06-18","archive_type":"auto15"},"contacts":[{"name":"Thupten Tsering","role":"primary","email":"Thupten.Tsering@ihs.gov","phone":"2066152452"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"53fdf3c0672b4affbac89b047f476a62","set_aside":{"code":"ISBEE","label":"Indian Small Business Economic Enterprise (Department of the Interior)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T16:22:53.920682Z","row_sha256":"8a64b0e871587dfa603542aa35e719a9f2f45215d19d27f55fb5bdb3b617dd69","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T16:22:53.920682Z","first_seen_at":"2026-09-16T16:22:53.920682Z"},"description":{"text":"** See amendment 1 dated 5/19/2026 ** ** See amendment 2 dated 5/26/2026 ** ** See amendment 3 dated 6/2/2026 ** See attached SOLICITATION NOTICE for solicitation number 75H70126R00008 for a construction project for the Indian Health Service (IHS). The purpose of this project is to remove (2) existing water storage tanks, install electrical control wire in conduit, and install equipment for water monitoring requirements. Project 17-N18 will replace the existing 60,000-gal tank with a new 135,000-gal bolted steel tank. After the new tank is brought online; the existing 60,000-gal tank will be removed from the site and the new tank will be enclosed by chain-link fence. Project 20-N65 will allow communication between the tank, tribal office building, and water treatment plant. The monitoring equipment will assist the tribe to meet requirements of the EPA -in order to comply with the surface water treatment rule. This project will be procured as a 100% set-aside for Indian Small Business Economic Enterprises (ISBEE) utilizing North American Industry Classification System (NAICS) code 236220 Commercial and Institutional Building Construction. The associated size standard for this procurement is $45 million. Please review all attachments to this notice for details. SCOPE OF WORK: See Section C of the attached solicitation for details. LOCATION OF PROJECT: Elk Creek, CA. See project documents. TERO: TERO fees do apply. CONSTRUCTION DURATION: Period of Performance is 180 calendar days after issuance of a Notice to Proceed. SITE VISIT: See FAR 52.236-27 CONTRACT TYPE: The IHS intends to award a Firm Fixed Price (FFP) construction contract in support of this requirement. This solicitation will be procured as a Request for Proposal (RFP) in accordance with FAR Part 15 and 36 procedures. PROPOSAL REQUIREMENTS: See Sections L&M of the solicitation. PROPOSAL DUE DATE: The offeror’s proposal shall be submitted electronically no later than the due date and time indicated in block 13 of the SF 1442, unless changed by amendment. EVALUATION: In accordance with FAR 15.101-2, the evaluation for this award will be based on the lowest price technically acceptable proposal (LPTA). See Sections L&M of the solicitation for specific requirements. Prices proposed must reflect the offeror’s understanding of the requirement, ability to perform, and be considered fair and reasonable to the Government. Price is the discriminating factor for award among eligible offers. The total firm fixed price listed in block 17 of the SF1442 shall be utilized for the overall price evaluation and to determine the lowest priced offer. QUESTIONS: Offerors shall submit all questions concerning this solicitation in writing to the Contract Specialist, Thupten Tsering, at Thupten.Tsering@ihs.gov NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES. For the purposes of this procurement, a concern is considered a small business if its average annual revenue for the last three (3) years is less than $45 million. For information concerning NAICS and SBA size standards, go to http://www.sba.gov. It is the responsibility of the contractor to check https://sam.gov/ frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties. NOTE: Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at: https://www.sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the government may not delay award for the purpose of allowing a contractor additional time to register in SAM.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"75H70126R00008","place_of_performance":{"zip":"95939","city":{"name":"Elk Creek"},"state":{"code":"CA"},"country":{"code":"USA"}},"product_service_code":"Y1NE"},{"award":{"date":"2026-06-30","amount":"1050150.00","number":"75H70126C00022","awardee":{"raw":"S.T.RHOADES CONSTRUCTION INCORPORATED Redding CA 96002 USA","name":"S.T.RHOADES CONSTRUCTION INCORPORATED Redding","location":{"zip":"96002","state":{"code":"CA"},"country":{"code":"USA"}}}},"dates":{"posted":"2026-06-30","award_date":"2026-06-30"},"links":{"sam":"https://sam.gov/workspace/contract/opp/ff561f9766ba4ac09dfcdef2a5ae2784/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Grindstone Water Storage Tank Replacement","agency":{"office":{"code":"75H701","name":"DIV OF ENGINEERING SVCS - SEATTLE"},"subtier":{"code":"7527","name":"INDIAN HEALTH SERVICE"},"department":{"code":"075","name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF"},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2026-07-15","archive_type":"auto15"},"contacts":[{"name":"Thupten Tsering","role":"primary","email":"Thupten.Tsering@ihs.gov","phone":"2066152452"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"ff561f9766ba4ac09dfcdef2a5ae2784","set_aside":{"code":"ISBEE","label":"Indian Small Business Economic Enterprise (Department of the Interior)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2026_archived_opportunities.csv","etag":"\"d9374b90a938e9923d910594731b7b57-106\"","fetched_at":"2026-09-16T00:55:27.040971Z","row_sha256":"acd204cd0df4eea441c4fb76640e66fd856d9dc489141c9c3e8d446729a3e02f","last_modified":"2026-09-13T14:50:39Z"},"updated_at":"2026-09-16T01:23:19.355361Z","first_seen_at":"2026-09-16T00:55:27.040971Z"},"notice_type":{"code":"a","label":"Award Notice"},"schema_version":1,"solicitation_number":"75H70126C","place_of_performance":{"zip":"95939","city":{"name":"Elk Creek"},"state":{"code":"CA"},"country":{"code":"USA"}},"product_service_code":"Y1NE"},{"award":{"date":"2022-08-19","amount":"3775028.00","number":"75H70126C00024","awardee":{"raw":"T. F. Powers Construction Co Fargo ND 58102 USA","name":"T. F. Powers Construction Co Fargo","location":{"zip":"58102","state":{"code":"ND"},"country":{"code":"USA"}}}},"dates":{"posted":"2026-08-31","award_date":"2022-08-19"},"links":{"sam":"https://sam.gov/workspace/contract/opp/5538b7f63b284bcea9b95a449b41deca/view"},"naics":{"codes":["237310"],"primary":"237310"},"title":"Lame Deer Heliport and Concrete Support Structure Remediation","agency":{"office":{"code":"75H701","name":"DIV OF ENGINEERING SVCS - SEATTLE"},"subtier":{"code":"7527","name":"INDIAN HEALTH SERVICE"},"department":{"code":"075","name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF"},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":true,"archive_date":"2026-09-15","archive_type":"auto_custom"},"contacts":[{"name":"Matt D Sanders","role":"primary","email":"matt.sanders@ihs.gov","phone":"240-472-6176"},{"name":"Andrew E. Hart","role":"secondary","email":"andrew.hart@ihs.gov","phone":"2066152453"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"5538b7f63b284bcea9b95a449b41deca","provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/datagov/ContractOpportunitiesFullCSV.csv","etag":"\"1571ce30698fe7b740fc98b2cfaecbac-30\"","fetched_at":"2026-09-16T00:55:28.845070Z","row_sha256":"767742891797bf720b7fed3ae89fc6c6ef71538221473d97d0add5c96812835e","last_modified":"2026-09-15T03:30:54Z"},"updated_at":"2026-09-16T01:23:25.591796Z","first_seen_at":"2026-09-15T22:52:52.472456Z"},"notice_type":{"code":"a","label":"Award Notice"},"schema_version":1,"solicitation_number":"75H70126C","place_of_performance":{"zip":"59043","city":{"name":"Lame Deer"},"state":{"code":"MT"},"country":{"code":"USA"}},"product_service_code":"Y1BZ"}],"due_at":"2026-06-03T19:00:00Z","due_date":"2026-06-03","closes_at":"2026-06-03T19:00:00Z","awardable":false,"dept_key":"d-075","dept_name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF","sub_key":"s-7527","sub_name":"INDIAN HEALTH SERVICE","office_key":"o-75H701","office_name":"DIV OF ENGINEERING SVCS - SEATTLE","state":"MT","country":"USA","winner_key":"HQURD9P18U46","amount":"3775028.00","linked_awards":15,"cancelled":false,"archived":false,"updated_at":"2026-09-16T18:59:55.702078Z","principal_notice_id":"53fdf3c0672b4affbac89b047f476a62","description":{"text":"** See amendment 1 dated 5/19/2026 ** ** See amendment 2 dated 5/26/2026 ** ** See amendment 3 dated 6/2/2026 ** See attached SOLICITATION NOTICE for solicitation number 75H70126R00008 for a construction project for the Indian Health Service (IHS). The purpose of this project is to remove (2) existing water storage tanks, install electrical control wire in conduit, and install equipment for water monitoring requirements. Project 17-N18 will replace the existing 60,000-gal tank with a new 135,000-gal bolted steel tank. After the new tank is brought online; the existing 60,000-gal tank will be removed from the site and the new tank will be enclosed by chain-link fence. Project 20-N65 will allow communication between the tank, tribal office building, and water treatment plant. The monitoring equipment will assist the tribe to meet requirements of the EPA -in order to comply with the surface water treatment rule. This project will be procured as a 100% set-aside for Indian Small Business Economic Enterprises (ISBEE) utilizing North American Industry Classification System (NAICS) code 236220 Commercial and Institutional Building Construction. The associated size standard for this procurement is $45 million. Please review all attachments to this notice for details. SCOPE OF WORK: See Section C of the attached solicitation for details. LOCATION OF PROJECT: Elk Creek, CA. See project documents. TERO: TERO fees do apply. CONSTRUCTION DURATION: Period of Performance is 180 calendar days after issuance of a Notice to Proceed. SITE VISIT: See FAR 52.236-27 CONTRACT TYPE: The IHS intends to award a Firm Fixed Price (FFP) construction contract in support of this requirement. This solicitation will be procured as a Request for Proposal (RFP) in accordance with FAR Part 15 and 36 procedures. PROPOSAL REQUIREMENTS: See Sections L&M of the solicitation. PROPOSAL DUE DATE: The offeror’s proposal shall be submitted electronically no later than the due date and time indicated in block 13 of the SF 1442, unless changed by amendment. EVALUATION: In accordance with FAR 15.101-2, the evaluation for this award will be based on the lowest price technically acceptable proposal (LPTA). See Sections L&M of the solicitation for specific requirements. Prices proposed must reflect the offeror’s understanding of the requirement, ability to perform, and be considered fair and reasonable to the Government. Price is the discriminating factor for award among eligible offers. The total firm fixed price listed in block 17 of the SF1442 shall be utilized for the overall price evaluation and to determine the lowest priced offer. QUESTIONS: Offerors shall submit all questions concerning this solicitation in writing to the Contract Specialist, Thupten Tsering, at Thupten.Tsering@ihs.gov NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES. For the purposes of this procurement, a concern is considered a small business if its average annual revenue for the last three (3) years is less than $45 million. For information concerning NAICS and SBA size standards, go to http://www.sba.gov. It is the responsibility of the contractor to check https://sam.gov/ frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties. NOTE: Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at: https://www.sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the government may not delay award for the purpose of allowing a contractor additional time to register in SAM.","html":null,"origin":"extract"},"contacts":[{"name":"Matt D Sanders","role":"primary","email":"matt.sanders@ihs.gov","phone":"240-472-6176"},{"name":"Andrew E. Hart","role":"secondary","email":"andrew.hart@ihs.gov","phone":"2066152453"}],"place_of_performance":{"zip":"95939","city":{"name":"Elk Creek"},"state":{"code":"CA"},"country":{"code":"USA"}},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"naics_codes":["236220"],"award":null,"attachments":[],"awards":[{"award_key":"CONT_AWD_75H70126C00022_7527_-NONE-_-NONE-","permalink":"https://www.usaspending.gov/award/CONT_AWD_75H70126C00022_7527_-NONE-_-NONE-/","piid":"75H70126C00022","parent_piid":null,"award_type":"DEFINITIVE CONTRACT","vendor_key":"GPGGLWNXJE13","recipient_name":"S.T.RHOADES CONSTRUCTION INCORPORATED","recipient_uei":"GPGGLWNXJE13","recipient_cage":"5BLA3","recipient_city":"REDDING","recipient_state":"CA","sub_name":"Indian Health Service","office_name":"DIV OF ENGINEERING SVCS - SEATTLE","office_key":"o-75H701","first_action_date":"2026-06-30","last_action_date":"2026-06-30","actions":1,"obligated":"1050150.00","current_total_value":"1050150.00","potential_total_value":"1050150.00","naics":"237110","psc":"Y1DA","extent_competed":"FULL AND OPEN COMPETITION AFTER EXCLUSION OF SOURCES","set_aside":"INDIAN SMALL BUSINESS ECONOMIC ENTERPRISE","offers_received":3,"description":"124160 / 129346 GRINDSTONE WATER STORAGE TANK REPLACEMENT AND WATER QUALITY MONITORING EQUIPMENT","method":"solicitation","confidence":"high","evidence":["solicitation number 75H70126R00008 equals the FPDS solicitation identifier","same awarding office 75H701"],"opportunity_key":null,"opportunity_title":null},{"award_key":"CONT_AWD_75H70126C00024_7527_-NONE-_-NONE-","permalink":"https://www.usaspending.gov/award/CONT_AWD_75H70126C00024_7527_-NONE-_-NONE-/","piid":"75H70126C00024","parent_piid":null,"award_type":"DEFINITIVE CONTRACT","vendor_key":"HQURD9P18U46","recipient_name":"T. F. POWERS CONSTRUCTION CO","recipient_uei":"HQURD9P18U46","recipient_cage":"0LE04","recipient_city":"FARGO","recipient_state":"ND","sub_name":"Indian Health Service","office_name":"DIV OF ENGINEERING SVCS - SEATTLE","office_key":"o-75H701","first_action_date":"2026-08-19","last_action_date":"2026-08-19","actions":1,"obligated":"3775028.00","current_total_value":"3775028.00","potential_total_value":"3775028.00","naics":"237310","psc":"Z2BZ","extent_competed":"FULL AND OPEN COMPETITION","set_aside":"NO SET ASIDE USED.","offers_received":3,"description":"[E.O. 14398] CONTRACTOR SHALL FURNISH ALL LABOR, EQUIPMENT, MATERIALS, SUPPLIES, SUPERVISION, TOOLS, PERMITS, TRANSPORTATION, QUALITY CONTROL, AND INCIDENTALS IN ORDER TO PERFORM PROJECT TITLED LAME DEER HELIPORT AND CONCRETE SUPPORT REMEDIATION","method":"solicitation","confidence":"high","evidence":["solicitation number 75H70126R00019 equals the FPDS solicitation identifier","same awarding office 75H701"],"opportunity_key":null,"opportunity_title":null}],"related":[{"key":"75J70126Q00033","latest_notice_id":"8848365f1fcd4caba336b7e3ede3c07a","title":"Teresa Thurston Replacement OSS","solicitation_number":"75J70126Q00033","notice_type":"k","first_type":"k","first_posted":"2026-08-21","last_posted":"2026-09-01","notices":2,"due_at":"2026-09-17T19:00:00Z","due_date":"2026-09-17","closes_at":"2026-09-17T19:00:00Z","awardable":true,"open":true,"dept_key":"d-075","dept_name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF","sub_key":"s-7527","sub_name":"INDIAN HEALTH SERVICE","office_key":"o-75H701","office_name":"DIV OF ENGINEERING SVCS - SEATTLE","naics":"237110","psc":"Y1NZ","set_aside":"SBA","state":"WA","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T07:31:38.954589Z"},{"key":"75H70126Q00034","latest_notice_id":"e161697568fb499cbccce5908ec5b6e3","title":"J. Jenkins OSS (COW)","solicitation_number":"75H70126Q00034","notice_type":"k","first_type":"r","first_posted":"2026-08-07","last_posted":"2026-08-25","notices":2,"due_at":"2026-09-21T19:00:00Z","due_date":"2026-09-21","closes_at":"2026-09-21T19:00:00Z","awardable":true,"open":true,"dept_key":"d-075","dept_name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF","sub_key":"s-7527","sub_name":"INDIAN HEALTH SERVICE","office_key":"o-75H701","office_name":"DIV OF ENGINEERING SVCS - SEATTLE","naics":"237110","psc":"Y1NZ","set_aside":"SBA","state":"WA","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T07:31:38.954589Z"},{"key":"75H70126Q00036","latest_notice_id":"b47014ab43ca4ed2a483b3a66fecd84a","title":"Jennifer Brown (COW)","solicitation_number":"75H70126Q00036","notice_type":"r","first_type":"r","first_posted":"2026-09-09","last_posted":"2026-09-09","notices":1,"due_at":"2026-09-24T19:00:00Z","due_date":"2026-09-24","closes_at":"2026-09-24T19:00:00Z","awardable":true,"open":true,"dept_key":"d-075","dept_name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF","sub_key":"s-7527","sub_name":"INDIAN HEALTH SERVICE","office_key":"o-75H701","office_name":"DIV OF ENGINEERING SVCS - SEATTLE","naics":"237110","psc":"Y1NZ","set_aside":"SBA","state":"WA","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T07:31:38.954589Z"},{"key":"75H70126R00026","latest_notice_id":"0aec2f11264e4cc0a733a5565625e8e7","title":"iHouse Apartment Construction","solicitation_number":"75H70126R00026","notice_type":"o","first_type":"o","first_posted":"2026-07-15","last_posted":"2026-08-19","notices":2,"due_at":"2026-09-24T21:00:00Z","due_date":"2026-09-24","closes_at":"2026-09-24T21:00:00Z","awardable":true,"open":true,"dept_key":"d-075","dept_name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF","sub_key":"s-7527","sub_name":"INDIAN HEALTH SERVICE","office_key":"o-75H701","office_name":"DIV OF ENGINEERING SVCS - SEATTLE","naics":"236220","psc":"Y1FA","set_aside":"ISBEE","state":"AZ","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T07:31:38.954589Z"}]}