{"canonical":"https://abierto.us/opportunities/75h70124q00026","key":"75H70124Q00026","url":"https://abierto.us/opportunities/75h70124q00026","title":"Nooksack Sulwhanon Community Well (Everson, WA)","solicitation_number":"75H70124Q00026","notice_type":"o","open":false,"response_deadline":"2025-03-13T21:00:00Z","first_posted":"2024-06-05","last_posted":"2025-03-10","department":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF","subagency":"INDIAN HEALTH SERVICE","office":"DIV OF ENGINEERING SVCS - SEATTLE","naics":"237110","psc":"Y1NE","set_aside":"SBA","place_state":"WA","place_county":"53073","place_county_name":"Whatcom County","place_city":"5322745","place_city_name":"Everson","winner":"JKA ENTERPRISES, INC","award_amount":null,"publications":[{"notice_id":"fc68befb2aa843c2bb69b8c81e505b86","title":"Nooksack Sulwhanon Community Well (Everson, WA)","solicitation_number":"75H70124Q00026","notice_type":"p","base_type":"p","posted":"2024-06-05","posted_at":null,"due_at":"2024-06-20T22:30:00Z","due_date":"2024-06-20","cancelled":null,"archived":null,"archive_date":"2024-07-05","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/fc68befb2aa843c2bb69b8c81e505b86/view","enriched":false,"history":[]},{"notice_id":"4bbd7fa577bd4cd1a366fe1579550354","title":"Nooksack Sulwhanon Community Well (Everson, WA)","solicitation_number":"75H70124Q00026","notice_type":"o","base_type":"p","posted":"2025-02-10","posted_at":null,"due_at":"2025-03-13T21:00:00Z","due_date":"2025-03-13","cancelled":null,"archived":null,"archive_date":"2025-03-28","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/4bbd7fa577bd4cd1a366fe1579550354/view","enriched":false,"history":[]},{"notice_id":"20b86ed1bdfc45a1bdb41254a53010ac","title":"Nooksack Sulwhanon Community Well (Everson, WA)","solicitation_number":"75H70124Q00026","notice_type":"o","base_type":"o","posted":"2025-03-10","posted_at":null,"due_at":"2025-03-13T21:00:00Z","due_date":"2025-03-13","cancelled":null,"archived":null,"archive_date":"2025-03-28","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/20b86ed1bdfc45a1bdb41254a53010ac/view","enriched":false,"history":[]}],"latest_notice_id":"20b86ed1bdfc45a1bdb41254a53010ac","first_type":"p","notices":[{"dates":{"posted":"2024-06-05","response_deadline":{"raw":"2024-06-20T15:30:00-07:00","utc":"2024-06-20T22:30:00Z","date":"2024-06-20","time":"15:30:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/fc68befb2aa843c2bb69b8c81e505b86/view"},"naics":{"codes":["237110"],"primary":"237110"},"title":"Nooksack Sulwhanon Community Well (Everson, WA)","agency":{"office":{"code":"75H701","name":"DIV OF ENGINEERING SVCS - SEATTLE"},"subtier":{"code":"7527","name":"INDIAN HEALTH SERVICE"},"department":{"code":"075","name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF"},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-07-05","archive_type":"auto15"},"contacts":[{"name":"Toby Hayden","role":"primary","email":"toby.hayden@ihs.gov","phone":"5034145524"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"fc68befb2aa843c2bb69b8c81e505b86","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"0305765988d447eac980866a3fa50be1525b69802c524a853331748290554d94","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"This is a PRESOLICITATION NOTICE for the upcoming Solicitation 75H70124Q00026 Nooksack Sulwhanon Community Well (Everson, WA), located in Everson, WA. These construction services will be in support of the Indian Health Service (IHS) prepared in accordance with FAR Part 36. The Government anticipates releasing the solicitation on or about the end of June 2024 and will remain open for approximately 15 calendar days. The solicitation and all amendments for this Request for Quotes will be posted on https://sam.gov under Contract Opportunities. A full scope of work, plans and specifications and Construction Wage Determination will be included in the solicitation documents. Additional details can be found in the solicitation when it is posted to https://sam.gov. SCOPE OF WORK: This project will complete a 12-inch diameter production well in an unconfined, shallow alluvial aquifer. This well will replace the existing 6-inch, 64-foot deep supply well for the Sulwhanon Community Water System (CWS), which does not have an adequate sanitary control area. The goal of the project is to achieve a safe, reliable drinking water source for 25 homes and 5 non-residential connections served by the Sulwhanon CWS. The well is estimated to be 12-inch diameter, in the range of 250 feet deep, with a 20-ft sanitary seal, screen assembly, and tailpipe and filter pack if necessary. Geologic conditions and presence of groundwater will dictate the final well depth and configuration. The work will also include well development, test pumping, disinfection, water sampling, and water quality testing. LOCATION OF PROJECT: 515 Sulwhanon Dr, Everson, WA 98247 (Whatcom County) TERO: TERO fees do NOT apply. CONSTRUCTION DURATION: Period of Performance is 120 calendar days from issuance of the Notice to Proceed. CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $100,000 and $250,000, in accordance with FAR 36.204. SITE VISIT: Details regarding a Site Visit will be included in the solicitation. NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES. CONTRACT TYPE: The Indian Health Service intends to award a single Firm Fixed Price (FFP) contract in support of this requirement. This solicitation will be procured as a Request for Quotes (RFQ) in accordance with FAR Part 13 and 36 procedures with price only evaluation criteria. This project will be solicited as a 100% small business set-aside under North American Industry Classification System (NAICS) code 237110 - Water and Sewer Line and Related Structures Construction. The associated size standard for this procurement is $45 million. For information concerning NAICS and SBA size standards, go to http://www.sba.gov. For information concerning NAICS and SBA size standards, go to http://www.sba.gov. There is a Size Standards Tool at https://www.sba.gov/size-standards/index.html. Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at: https://sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the Government may not delay award for the purpose of allowing a contractor additional time to register in SAM. It is the responsibility of the contractor to check SAM.gov frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties. This notice is for informational purposes only and is NOT a request for submission of offers. No other information is available until issuance of the solicitation itself. No bidder list is maintained. Interested bidders should follow this solicitation notice on https://sam.gov to receive email notifications of any updates to the","origin":"extract"},"notice_type":{"code":"p","label":"Presolicitation"},"schema_version":1,"solicitation_number":"75H70124Q00026","place_of_performance":{"zip":"98247","city":{"name":"Everson"},"state":{"code":"WA"},"country":{"code":"USA"}},"product_service_code":"Y1NE"},{"dates":{"posted":"2025-02-10","response_deadline":{"raw":"2025-03-13T14:00:00-07:00","utc":"2025-03-13T21:00:00Z","date":"2025-03-13","time":"14:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/4bbd7fa577bd4cd1a366fe1579550354/view"},"naics":{"codes":["237110"],"primary":"237110"},"title":"Nooksack Sulwhanon Community Well (Everson, WA)","agency":{"office":{"code":"75H701","name":"DIV OF ENGINEERING SVCS - SEATTLE"},"subtier":{"code":"7527","name":"INDIAN HEALTH SERVICE"},"department":{"code":"075","name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF"},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-03-28","archive_type":"auto15"},"contacts":[{"name":"Toby Hayden","role":"primary","email":"toby.hayden@ihs.gov","phone":"5034145524"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"4bbd7fa577bd4cd1a366fe1579550354","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"7e2fd1de47bb92a0d8d9d9f0d56321cd72809a75523d31e0dceeaba99c3a48bb","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"The attached SOLICITATION 75H70124Q00026 is issued on behalf of the Indian Health Service (IHS). The purpose of this project is to complete a 12-inch diameter production well to replace the existing 6-inch, 64-foot deep supply well for the Sulwhanon Community Water System (CWS), which does not have an adequate sanitary control area. The goal of the project is to achieve a safe, reliable drinking water source for 25 homes and 5 non-residential connections served by the Sulwhanon CWS. This project will be procured as a 100% Small Business set-aside solicitation under North American Industry Classification System (NAICS) code 237110 – Water and Sewer Line and Related Structures Construction with a size standard of $45 million. **Please review all attachments to this notice for details.** SCOPE OF WORK: See Section C of the attached solicitation (Attachment B01 75H70124Q00026) LOCATION OF PROJECT: Approximately 2515 Sulwhanon Dr, Everson, WA 98247 (Whatcom County) TERO: TERO fees do NOT apply. CONSTRUCTION DURATION: Period of Performance is 120 calendar days from issuance of the Notice to Proceed. CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $100,000 and $250,000, in accordance with FAR 36.204. CONTRACT TYPE: The IHS intends to award a Firm Fixed Price (FFP) construction contract in support of this requirement using price only evaluation criteria as detailed in Section M. This solicitation is issued as a Request for Quotes (RFQ) in accordance with FAR Part 13 and 36 procedures. QUOTE REQUIREMENTS: See Section L of the attached solicitation (Attachment B01 75H70124Q00026) SITE VISIT: An organized site visit is scheduled for March 6, 2025 at 10:30am PT; RSVP REQUIRED. See FAR 52.236-27, Site Visit Construction, for details. QUOTE DUE DATE: The quotation shall be submitted electronically in PDF format via email to toby.hayden@ihs.gov at your earliest convenience but no later than March 13, 2025 at 2:00 PM PT unless changed by amendment. EVALUATION: In accordance with FAR 13.106-2, the evaluation for this award will be based on price and the quoter’s compliance with the terms and conditions for this request for quotes; see Section L. The quoter shall possess all necessary certifications to perform the work specified in Section C in order to be eligible for award. Prices quoted must reflect the quoter’s understanding of the requirement, ability to perform, and be considered fair and reasonable to the Government. QUESTIONS: Quoters shall submit all questions concerning this solicitation in writing to the Contracting Officer, Toby Hayden, at toby.hayden@ihs.gov. Questions should be received no later than 7 days prior to quote due date to allow time for a response. NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES. For information concerning NAICS and SBA size standards, go to http://www.sba.gov. It is the responsibility of the contractor to check https://sam.gov/ frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties. NOTE: Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at: https://www.sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the government may not delay award for the purpose of allowing a contractor additional time to register in SAM.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"75H70124Q00026","place_of_performance":{"zip":"98247","city":{"name":"Everson"},"state":{"code":"WA"},"country":{"code":"USA"}},"product_service_code":"Y1NE"},{"dates":{"posted":"2025-03-10","response_deadline":{"raw":"2025-03-13T14:00:00-07:00","utc":"2025-03-13T21:00:00Z","date":"2025-03-13","time":"14:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/20b86ed1bdfc45a1bdb41254a53010ac/view"},"naics":{"codes":["237110"],"primary":"237110"},"title":"Nooksack Sulwhanon Community Well (Everson, WA)","agency":{"office":{"code":"75H701","name":"DIV OF ENGINEERING SVCS - SEATTLE"},"subtier":{"code":"7527","name":"INDIAN HEALTH SERVICE"},"department":{"code":"075","name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF"},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2025-03-28","archive_type":"auto15"},"contacts":[{"name":"Toby Hayden","role":"primary","email":"toby.hayden@ihs.gov","phone":"5034145524"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"20b86ed1bdfc45a1bdb41254a53010ac","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2025_archived_opportunities.csv","etag":"\"d47226e3d2c6545974b252e103f82b34-139\"","fetched_at":"2026-09-16T17:45:50.850439Z","row_sha256":"a246a26f7fd8ef036bd01a7e85e99d532377225b2ba67d65da6660f8bd7e1a15","last_modified":"2026-09-13T14:49:20Z"},"updated_at":"2026-09-16T17:45:50.850439Z","first_seen_at":"2026-09-16T17:45:50.850439Z"},"description":{"text":"***AMENDMENT A00001: The purpose of this amendment is to answer several questions asked in response to this solicitation. See attachment labeled \"B05 75H70124Q00026-A00001\" for details. As a reminder, offerors must acknowledge all amendments on the SF1442 when submitting a quote.*** The attached SOLICITATION 75H70124Q00026 is issued on behalf of the Indian Health Service (IHS). The purpose of this project is to complete a 12-inch diameter production well to replace the existing 6-inch, 64-foot deep supply well for the Sulwhanon Community Water System (CWS), which does not have an adequate sanitary control area. The goal of the project is to achieve a safe, reliable drinking water source for 25 homes and 5 non-residential connections served by the Sulwhanon CWS. This project will be procured as a 100% Small Business set-aside solicitation under North American Industry Classification System (NAICS) code 237110 – Water and Sewer Line and Related Structures Construction with a size standard of $45 million. **Please review all attachments to this notice for details.** SCOPE OF WORK: See Section C of the attached solicitation (Attachment B01 75H70124Q00026) LOCATION OF PROJECT: Approximately 2515 Sulwhanon Dr, Everson, WA 98247 (Whatcom County) TERO: TERO fees do NOT apply. CONSTRUCTION DURATION: Period of Performance is 120 calendar days from issuance of the Notice to Proceed. CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $100,000 and $250,000, in accordance with FAR 36.204. CONTRACT TYPE: The IHS intends to award a Firm Fixed Price (FFP) construction contract in support of this requirement using price only evaluation criteria as detailed in Section M. This solicitation is issued as a Request for Quotes (RFQ) in accordance with FAR Part 13 and 36 procedures. QUOTE REQUIREMENTS: See Section L of the attached solicitation (Attachment B01 75H70124Q00026) SITE VISIT: An organized site visit is scheduled for March 6, 2025 at 10:30am PT; RSVP REQUIRED. See FAR 52.236-27, Site Visit Construction, for details. QUOTE DUE DATE: The quotation shall be submitted electronically in PDF format via email to toby.hayden@ihs.gov at your earliest convenience but no later than March 13, 2025 at 2:00 PM PT unless changed by amendment. EVALUATION: In accordance with FAR 13.106-2, the evaluation for this award will be based on price and the quoter’s compliance with the terms and conditions for this request for quotes; see Section L. The quoter shall possess all necessary certifications to perform the work specified in Section C in order to be eligible for award. Prices quoted must reflect the quoter’s understanding of the requirement, ability to perform, and be considered fair and reasonable to the Government. QUESTIONS: Quoters shall submit all questions concerning this solicitation in writing to the Contracting Officer, Toby Hayden, at toby.hayden@ihs.gov. Questions should be received no later than 7 days prior to quote due date to allow time for a response. NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES. For information concerning NAICS and SBA size standards, go to http://www.sba.gov. It is the responsibility of the contractor to check https://sam.gov/ frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties. NOTE: Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at: https://www.sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the government may not delay award for the purpose of allowing a contractor additional time to register in SAM.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"75H70124Q00026","place_of_performance":{"zip":"98247","city":{"name":"Everson"},"state":{"code":"WA"},"country":{"code":"USA"}},"product_service_code":"Y1NE"}],"due_at":"2025-03-13T21:00:00Z","due_date":"2025-03-13","closes_at":"2025-03-13T21:00:00Z","awardable":false,"dept_key":"d-075","dept_name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF","sub_key":"s-7527","sub_name":"INDIAN HEALTH SERVICE","office_key":"o-75H701","office_name":"DIV OF ENGINEERING SVCS - SEATTLE","state":"WA","county":"53073","county_name":"Whatcom County","city":"5322745","city_name":"Everson","country":"USA","winner_key":"LHTTQZD3HF75","amount":null,"linked_awards":3,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z","principal_notice_id":"20b86ed1bdfc45a1bdb41254a53010ac","description":{"text":"***AMENDMENT A00001: The purpose of this amendment is to answer several questions asked in response to this solicitation. See attachment labeled \"B05 75H70124Q00026-A00001\" for details. As a reminder, offerors must acknowledge all amendments on the SF1442 when submitting a quote.*** The attached SOLICITATION 75H70124Q00026 is issued on behalf of the Indian Health Service (IHS). The purpose of this project is to complete a 12-inch diameter production well to replace the existing 6-inch, 64-foot deep supply well for the Sulwhanon Community Water System (CWS), which does not have an adequate sanitary control area. The goal of the project is to achieve a safe, reliable drinking water source for 25 homes and 5 non-residential connections served by the Sulwhanon CWS. This project will be procured as a 100% Small Business set-aside solicitation under North American Industry Classification System (NAICS) code 237110 – Water and Sewer Line and Related Structures Construction with a size standard of $45 million. **Please review all attachments to this notice for details.** SCOPE OF WORK: See Section C of the attached solicitation (Attachment B01 75H70124Q00026) LOCATION OF PROJECT: Approximately 2515 Sulwhanon Dr, Everson, WA 98247 (Whatcom County) TERO: TERO fees do NOT apply. CONSTRUCTION DURATION: Period of Performance is 120 calendar days from issuance of the Notice to Proceed. CONSTRUCTION MAGNITUDE: The magnitude of this construction project is anticipated to be between $100,000 and $250,000, in accordance with FAR 36.204. CONTRACT TYPE: The IHS intends to award a Firm Fixed Price (FFP) construction contract in support of this requirement using price only evaluation criteria as detailed in Section M. This solicitation is issued as a Request for Quotes (RFQ) in accordance with FAR Part 13 and 36 procedures. QUOTE REQUIREMENTS: See Section L of the attached solicitation (Attachment B01 75H70124Q00026) SITE VISIT: An organized site visit is scheduled for March 6, 2025 at 10:30am PT; RSVP REQUIRED. See FAR 52.236-27, Site Visit Construction, for details. QUOTE DUE DATE: The quotation shall be submitted electronically in PDF format via email to toby.hayden@ihs.gov at your earliest convenience but no later than March 13, 2025 at 2:00 PM PT unless changed by amendment. EVALUATION: In accordance with FAR 13.106-2, the evaluation for this award will be based on price and the quoter’s compliance with the terms and conditions for this request for quotes; see Section L. The quoter shall possess all necessary certifications to perform the work specified in Section C in order to be eligible for award. Prices quoted must reflect the quoter’s understanding of the requirement, ability to perform, and be considered fair and reasonable to the Government. QUESTIONS: Quoters shall submit all questions concerning this solicitation in writing to the Contracting Officer, Toby Hayden, at toby.hayden@ihs.gov. Questions should be received no later than 7 days prior to quote due date to allow time for a response. NOTE: ALL DATES ARE SUBJECT TO CHANGE. SEE SOLICITATION FOR OFFICIAL DATES, TIMES, AND LOCATIONS OF SITE VISITS AND DEADLINES. For information concerning NAICS and SBA size standards, go to http://www.sba.gov. It is the responsibility of the contractor to check https://sam.gov/ frequently for any amendments or changes to the solicitation. Hard copy documents will NOT be available – all documents for proposal purposes will be posted at the website for download by interested parties. NOTE: Registration in the System for Award Management (SAM) database is mandatory to be considered for award. Offerors may obtain information on registration and annual confirmation requirements via the internet at: https://www.sam.gov. Contractors are encouraged to complete SAM registration as soon as possible; the government may not delay award for the purpose of allowing a contractor additional time to register in SAM.","html":null,"origin":"extract"},"contacts":[{"name":"Toby Hayden","role":"primary","email":"toby.hayden@ihs.gov","phone":"5034145524"}],"place_of_performance":{"zip":"98247","city":{"name":"Everson"},"state":{"code":"WA"},"country":{"code":"USA"}},"office_address":{"zip":"98121","city":"SEATTLE","state":"WA","country":"USA"},"naics_codes":["237110"],"award":null,"attachments":[],"awards":[{"award_key":"CONT_AWD_75H70125C00031_7527_-NONE-_-NONE-","permalink":"https://www.usaspending.gov/award/CONT_AWD_75H70125C00031_7527_-NONE-_-NONE-/","piid":"75H70125C00031","parent_piid":null,"award_type":"DEFINITIVE CONTRACT","vendor_key":"LHTTQZD3HF75","recipient_name":"JKA ENTERPRISES, INC","recipient_uei":"LHTTQZD3HF75","recipient_cage":"61H51","recipient_city":"MONROE","recipient_state":"WA","sub_name":"Indian Health Service","office_name":"DIV OF ENGINEERING SVCS - SEATTLE","office_key":"o-75H701","first_action_date":"2025-09-08","last_action_date":"2026-09-03","actions":7,"obligated":"351688.64","current_total_value":"351688.64","potential_total_value":"351688.64","naics":"237110","psc":"Y1NE","extent_competed":"COMPETED UNDER SAP","set_aside":"SMALL BUSINESS SET ASIDE - TOTAL","offers_received":4,"description":"CONSTRUCTION OF NOOKSACK SULWHANON COMMUNITY WELL (EVERSON, WA)","method":"solicitation","confidence":"high","evidence":["solicitation number 75H70124Q00026 equals the FPDS solicitation identifier","same awarding office 75H701"],"opportunity_key":null,"opportunity_title":null}],"related":[{"key":"75H70126Q00034","latest_notice_id":"e161697568fb499cbccce5908ec5b6e3","title":"J. Jenkins OSS (COW)","solicitation_number":"75H70126Q00034","notice_type":"k","first_type":"r","first_posted":"2026-08-07","last_posted":"2026-08-25","notices":2,"due_at":"2026-09-21T19:00:00Z","due_date":"2026-09-21","closes_at":"2026-09-21T19:00:00Z","awardable":true,"open":true,"dept_key":"d-075","dept_name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF","sub_key":"s-7527","sub_name":"INDIAN HEALTH SERVICE","office_key":"o-75H701","office_name":"DIV OF ENGINEERING SVCS - SEATTLE","naics":"237110","psc":"Y1NZ","set_aside":"SBA","state":"WA","county":"53015","county_name":"Cowlitz County","city":"5310565","city_name":"Castle Rock","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z"},{"key":"75H70126Q00036","latest_notice_id":"b47014ab43ca4ed2a483b3a66fecd84a","title":"Jennifer Brown (COW)","solicitation_number":"75H70126Q00036","notice_type":"r","first_type":"r","first_posted":"2026-09-09","last_posted":"2026-09-09","notices":1,"due_at":"2026-09-24T19:00:00Z","due_date":"2026-09-24","closes_at":"2026-09-24T19:00:00Z","awardable":true,"open":true,"dept_key":"d-075","dept_name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF","sub_key":"s-7527","sub_name":"INDIAN HEALTH SERVICE","office_key":"o-75H701","office_name":"DIV OF ENGINEERING SVCS - SEATTLE","naics":"237110","psc":"Y1NZ","set_aside":"SBA","state":"WA","county":"53011","county_name":"Clark County","city":"5358410","city_name":"Ridgefield","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z"},{"key":"75H70126R00026","latest_notice_id":"9483c35d66534a47b935a6ca23dfde47","title":"iHouse Apartment Construction","solicitation_number":"75H70126R00026","notice_type":"o","first_type":"o","first_posted":"2026-07-15","last_posted":"2026-09-17","notices":3,"due_at":"2026-10-08T21:00:00Z","due_date":"2026-10-08","closes_at":"2026-10-08T21:00:00Z","awardable":true,"open":true,"dept_key":"d-075","dept_name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF","sub_key":"s-7527","sub_name":"INDIAN HEALTH SERVICE","office_key":"o-75H701","office_name":"DIV OF ENGINEERING SVCS - SEATTLE","naics":"236220","psc":"Y1FA","set_aside":"ISBEE","state":"AZ","county":"04005","county_name":"Coconino County","city":"0474470","city_name":"Tonalea","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-18T04:00:44.545196Z"},{"key":"75H70126Q00035","latest_notice_id":"0e3bc7dc6b384de08bbbdb01b5b1f9aa","title":"Bill Parkin (MAK)","solicitation_number":"75H70126Q00035","notice_type":"k","first_type":"r","first_posted":"2026-08-27","last_posted":"2026-09-17","notices":2,"due_at":"2026-10-16T18:00:00Z","due_date":"2026-10-16","closes_at":"2026-10-16T18:00:00Z","awardable":true,"open":true,"dept_key":"d-075","dept_name":"HEALTH AND HUMAN SERVICES, DEPARTMENT OF","sub_key":"s-7527","sub_name":"INDIAN HEALTH SERVICE","office_key":"o-75H701","office_name":"DIV OF ENGINEERING SVCS - SEATTLE","naics":"237110","psc":"Y1NZ","set_aside":"SBA","state":"WA","county":"53009","county_name":"Clallam County","city":"5348295","city_name":"Neah Bay","country":"USA","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-18T04:00:44.545196Z"}]}