{"canonical":"https://abierto.us/opportunities/36c77627q0022","key":"36C77627Q0022","url":"https://abierto.us/opportunities/36c77627q0022","title":"Y1DZ--PCAC EHRM Infrastructure Upgrades Construction - Togus VAMC (VA-27-00009716)","solicitation_number":"36C77627Q0022","notice_type":"r","open":false,"removed":false,"removed_at":null,"response_deadline":"2026-10-30T20:00:00Z","first_posted":"2026-10-15","last_posted":"2026-10-15","department":"VETERANS AFFAIRS, DEPARTMENT OF","subagency":"VETERANS AFFAIRS, DEPARTMENT OF","office":"PCAC (36C776)","naics":"236220","psc":"Y1DZ","set_aside":null,"place_state":"ME","place_scope":"site","site":null,"place_state_source":"sam_state_name","place_evidence":null,"place_county":"23011","place_county_name":"Kennebec County","place_city":"2302100","place_city_name":"Augusta","winner":null,"award_amount":null,"publications":[{"notice_id":"1cd6ba951c8e4bd5a8df3007a214004e","title":"Y1DZ--PCAC EHRM Infrastructure Upgrades Construction - Togus VAMC (VA-27-00009716)","solicitation_number":"36C77627Q0022","notice_type":"r","base_type":"r","posted":"2026-10-15","posted_at":"2026-10-15T15:25:51.077Z","due_at":"2026-10-30T20:00:00Z","due_date":"2026-10-30","cancelled":false,"archived":false,"archive_date":"2026-12-29","removed_at":null,"award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/1cd6ba951c8e4bd5a8df3007a214004e/view","enriched":true,"history":[{"index":1,"title":"Y1DZ--PCAC EHRM Infrastructure Upgrades Construction - Togus VAMC (VA-27-00009716)","action":"publish","latest":true,"deleted":false,"archived":false,"cancelled":false,"posted_at":"2026-10-15T15:25:51.077Z","notice_type":{"code":"r","label":"Sources Sought"},"request_type":"submit","opportunity_id":"1cd6ba951c8e4bd5a8df3007a214004e","solicitation_number":"36C77627Q0022"}]}],"latest_notice_id":"1cd6ba951c8e4bd5a8df3007a214004e","first_type":"r","notices":[{"award":{"awardee":{}},"dates":{"posted":"2026-10-15","posted_at":"2026-10-15T15:25:51.077Z","created_at":"2026-10-15T15:25:48.866Z","modified_at":"2026-10-15T15:25:51.077Z","response_deadline":{"raw":"2026-10-30T16:00:00-04:00","utc":"2026-10-30T20:00:00Z","date":"2026-10-30","time":"16:00:00","timezone":"America/New_York","utc_offset_seconds":-14400}},"links":{"sam":"https://sam.gov/workspace/contract/opp/1cd6ba951c8e4bd5a8df3007a214004e/view"},"naics":{"codes":["236220"],"primary":"236220"},"title":"Y1DZ--PCAC EHRM Infrastructure Upgrades Construction - Togus VAMC (VA-27-00009716)","agency":{"office":{"code":"36C776","name":"PCAC (36C776)"},"subtier":{"code":"3600","name":"VETERANS AFFAIRS, DEPARTMENT OF"},"department":{"code":"036","name":"VETERANS AFFAIRS, DEPARTMENT OF"},"office_address":{"zip":"44131","city":"INDEPENDENCE","state":"OH","country":"USA"},"organization_id":"100180033","organization_type":"OFFICE"},"status":{"active":true,"latest":true,"deleted":false,"archived":false,"cancelled":false,"publication":"published","archive_date":"2026-12-29","archive_type":"auto_custom"},"history":[{"index":1,"title":"Y1DZ--PCAC EHRM Infrastructure Upgrades Construction - Togus VAMC (VA-27-00009716)","action":"publish","latest":true,"deleted":false,"archived":false,"cancelled":false,"posted_at":"2026-10-15T15:25:51.077Z","notice_type":{"code":"r","label":"Sources Sought"},"request_type":"submit","opportunity_id":"1cd6ba951c8e4bd5a8df3007a214004e","solicitation_number":"36C77627Q0022"}],"contacts":[{"name":"joshua.gitchel@va.gov","role":"primary","email":"joshua.gitchel@va.gov","phone":"216-447-8300","title":"Josh Gitchel"}],"base_type":{"code":"r","label":"Sources Sought"},"notice_id":"1cd6ba951c8e4bd5a8df3007a214004e","lineage_id":"1cd6ba951c8e4bd5a8df3007a214004e","provenance":{"detail":{"endpoints":["opportunity","resources","history"],"fetched_at":"2026-10-16T03:54:01.101748121Z"},"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/datagov/ContractOpportunitiesFullCSV.csv","etag":"\"54ebca4dac568eb7dc87bfd7715389e5-24\"","fetched_at":"2026-10-16T03:35:14.858266068Z","row_sha256":"0171c5fe24c32c55a30b3952c69c10db3b340937d488dff3b33f26b863620f42","last_modified":"2026-10-16T03:30:28Z"},"updated_at":"2026-10-16T03:54:01.101748121Z","first_seen_at":"2026-10-16T03:35:14.858266068Z"},"description":{"html":"SYNOPSIS:\n\nINTRODUCTION: \nThis Sources Sought Notice is for market research and information purposes only at this time and shall not be construed as a solicitation or as an obligation on the part of the Department of Veterans Affairs (VA).\n\nThe Department of Veterans Affairs, Veterans Health Administration (VHA), Program Contracting Activity Central (PCAC) is conducting a market survey and is seeking potential sources for the EHRM Infrastructure Upgrades Construction project at the Togus VA Medical Center   located in Togus, ME.\n\nPROJECT DESCRIPTION:\nThis project will include but not limited to the following infrastructure improvements:      \n\n  The architectural demolition, reconfiguration, expansion, and renovation of existing spaces. The architectural construction of new finished spaces, doors, and flooring systems. \n  The structural alteration of existing structural components, and construction of new structural equipment support,\n  Electrical upgrades including electrical panels, normal and critical power distribution, bonding, Uninterrupted Power Supplies (UPS), lighting, and new power outlets.\n  The installation and programming of Building Automation System (BAS) equipment and interfaces, \n  Upgrades to existing HVAC, reprogramming of existing controls, and the installation of new HVAC and new controls.\n  The modification of existing plumbing to avoid Telecommunication Rooms, and the installation of new plumbing to support new mechanical systems, and interior drainage. \n  Upgrades to data communication infrastructure including new data outlets, patch panels, seismic rated IT racks, cable management, in building as necessary. This includes the re-cabling of all existing data cabling within the entire campus to CAT 6A. \n  Upgrade of the fiber infrastructure backbone, campus wide both within buildings and between buildings and all associated civil site construction and landscaping.\n  Civil site work, including the installation of concrete duct banks, installation of new pre-cast manholes, the excavation and repair of existing building waterproofing, and the restoration of site conditions. \n  The abatement of asbestos and lead based paint, including the preparation of an abatement plan in accordance with the requirements of the Maine Department of Environmental Protection.\n  The installation of a radon mitigation system, including the preparation of detailed working drawings that are signed by a radon mitigation contractor registered with the State of Maine.\n  Fire Suppression Upgrades including new gaseous suppression systems, and the modification of existing fire sprinkler systems. New fire sprinkler system for the new MCR Building. \n  Fire Alarm Upgrades.\n  Firestopping and fire caulking for all wall and floor penetrations within the project scope.\n  Physical security upgrades including Physical Access Control, intrusion detection, and security cameras, as shown on the contract drawings.\n  The project buildings include: 200, 200E, 201, 203, 204, 205, 206, 207, 208, 209, 210, 211, 212, 221, 232, 235, 238, 240, 248, 255, 300, BQ1, BQ3, BQ4, BQ27, BQ32, BQ69, 248, MRI, and site.\n\nPROCUREMENT INFORMATION:\nThe proposed project will be a competitive, firm-fixed-price contract utilizing the design-bid-build approach (Final Specifications and Drawings will be provided). The anticipated solicitation will be issued as a Request For Proposal (RFP) in accordance with FAR Parts 15 and 12, considering Technical and Price Factors. The results and analysis of the market research will finalize the determination of the type of socio-economic set-aside, if any, will depend upon the responses to this notice and any other information gathered during the market research process.\n\nThis project is planned for advertising in December 2026. In accordance with VAAR 836.204, the magnitude of construction is between $50,000,000.00 and $100,000,000.00. The North American Industry Classification System (NAICS) code 236220 (size standard $45.0 million) applies to this procurement. The duration of the project is currently estimated at 730 calendar days from the issuance of a Notice to Proceed. The services for this project will include providing all construction related services such as: providing labor, materials and equipment required to complete the project as per contract documents prepared by an independent Architect-Engineer firm. \n\nThere will be an Industry Day for this project on October 27, 2026 at Building 210 at the Togus campus located at 810 Eastern Avenue, Augusta ME 04330. Information on this event can be located at the following:\n\nhttps://sam.gov/workspace/contract/opp/e4ad29ff80624636a3bd4c8a622fa460/view \n\nCAPABILITY STATEMENT:\nRespondents shall provide a general capabilities statement to include the following information: \nSection 1: Provide company name, Unique Entity Identifier (UEI), company address, Point-of-Contact name, phone number and email.\nSection 2: Provide company business size based on NAICS code 236220. Also, provide business type (i.e., Large Business, Small Business, Service-Disabled Veteran Owned Small Business, Small Disadvantaged Business, Women-Owned Small Business, Hub Zone Small Business, etc.). \nSection 3: Provide a Statement of Interest in the project. \nSection 4: Provide the prime contractor s available bonding capacity in the form of a letter of intent from your bonding company with this submission. *Please ensure that the individual bonding capacity is in line with the VAAR Magnitude of Construction listed above.\nSection 5: Provide the type of work your company has performed in the past in support of the same or similar requirement. This section is IMPORTANT as it will help to determine the type of socio-economic set-aside, if any. Please provide the following in your response: \nNo more than three (3) contracts that your company has performed within the last seven (7) years that are of comparable size, complexity, and scope to this requirement. Include the project name, project owner and contact information as this person may be contacted for further information, project scope, project size (Example: square footage), building use (Example: Medical Facility, Office Building, etc.), project dollar value, start and completion dates. \nProvide specific examples that relate aspects of previous projects to the proposed project. Describe specific technical skills and key personnel your company possess to perform the requirements described under description of work.\nDescribe your Self-Performed** effort (as either a Prime or Subcontractor). Describe Self-Performed work in terms of dollar value and description. **Self-Performed means work performed by the offeror themselves, NOT work performed by another company for them for any of the project examples provided.\nSection 6: Project Labor Agreement (PLA) - A PLA is defined as a pre-hire Collective Bargaining Agreement with one or more labor organizations that establishes the terms and conditions of employment for a specific construction project and is an agreement described in 29 U.S.C. 158(f). The PLA questionnaire must be filled out and returned with the Sources Sought response. The questionnaire can be found at the end of this document.\nSee FAR Provision: 52.222-33 Notice of Requirement for Project Labor Agreement and FAR Clause 52.222-34 Project Labor Agreement for further details.\nIt is requested that interested contractors submit a response (electronic submission) of no more than nine (9) single sided pages, single-spaced, 12-point font minimum that addresses the above information (this is inclusive of the PLA questionnaire). This response must be submitted as a single application-generated (not scanned) PDF document that is less than or equal to 4MB in size. Please note that hard copies will not be accepted. Please also include a cover page, which includes, at a minimum: the company s name, address, Unique Entity Identifier (if available), socio-economic status, point-of-contact name, phone number, and e-mail address. Responses must include the Sources Sought number and project title in the subject line of their e-mail response. Submissions (responses) shall be submitted via email to the primary point of contact listed below by October 30, 2026 at 4:00 PM ET. No phone calls will be accepted. \n\nThe Capabilities Statement submitted in response to this Sources Sought shall not be considered to be a bid or proposal. This notice is for information and planning purposes only and is neither to be construed as a commitment by the Government nor will the Government pay for information solicited. No evaluation letters and/or results will be issued to the respondents. After completing its analyses, the Government will determine whether to limit competition among the small business categories listed above or proceed with full and open competition as other than small business. \n\nAt this time no solicitation exists; therefore, please do not request a copy of the solicitation. If a solicitation is released it will be synopsized in Contract Opportunities at https://sam.gov/. It is the potential offeror's responsibility to monitor this site for the release of any solicitation or synopsis.  \n\nContracting Office Address:  \nVHA Program Contracting Activity Central (VHA-PCAC)\n6100 Oak Tree Blvd. Suite 300\nIndependence, OH 44131 \n\nPrimary Point of Contact:\nJosh Gitchel\nContract Specialist\nJoshua.Gitchel@VA.Gov  \n\n\n\n \nPROJECT LABOR AGREEMENT (PLA) QUESTIONNAIRE\n(Please respond to the questions below)\n\n1. Is your company familiar with Project Labor Agreement (PLA) and its use on construction projects? \n\nYes/No \n\nComments:\n\n2. Would your company likely submit a proposal for the VA construction solicitation that requires the use of a PLA? \n\nYes/No \n\nComments: \n\n3. If VA requires a PLA, would your proposed construction cost likely to increase or decrease and what is the likely percentage of cost increase or decrease? \n\nComments:\n\n 4. Does the VA requirement to use of a PLA on a construction project restrict competition? \n\nYes/No \n\nComments: \n\n5. Do you expect subcontractor resistance should VA requires the use of a PLA on this construction solicitation? \n\nYes/No \n\nComments: \n\n6. Do you have additional comments regarding the use of a PLA for this project?\n\nComments:\n\n\n7. Has your Firm participated in projects with PLA agreements? \n\nYes/No \n \na. Were there cost increases, labor shortages, or other issues experienced on contracts that had the labor union clauses? If so, please provide more details.\n \nb. Did pricing remain as expected? If not, did it increase or decrease as a result?\n\nc. Was the project completed on time?\n \nd. Was craftsmanship acceptable (or better) than a level typically seen on other non-union projects.\n\n\n\n\n--- End of PLA Questionnaire ---","text":"SYNOPSIS:\n\nINTRODUCTION:\nThis Sources Sought Notice is for market research and information purposes only at this time and shall not be construed as a solicitation or as an obligation on the part of the Department of Veterans Affairs (VA).\n\nThe Department of Veterans Affairs, Veterans Health Administration (VHA), Program Contracting Activity Central (PCAC) is conducting a market survey and is seeking potential sources for the EHRM Infrastructure Upgrades Construction project at the Togus VA Medical Center located in Togus, ME.\n\nPROJECT DESCRIPTION:\nThis project will include but not limited to the following infrastructure improvements:\n\nThe architectural demolition, reconfiguration, expansion, and renovation of existing spaces. The architectural construction of new finished spaces, doors, and flooring systems.\nThe structural alteration of existing structural components, and construction of new structural equipment support,\nElectrical upgrades including electrical panels, normal and critical power distribution, bonding, Uninterrupted Power Supplies (UPS), lighting, and new power outlets.\nThe installation and programming of Building Automation System (BAS) equipment and interfaces,\nUpgrades to existing HVAC, reprogramming of existing controls, and the installation of new HVAC and new controls.\nThe modification of existing plumbing to avoid Telecommunication Rooms, and the installation of new plumbing to support new mechanical systems, and interior drainage.\nUpgrades to data communication infrastructure including new data outlets, patch panels, seismic rated IT racks, cable management, in building as necessary. This includes the re-cabling of all existing data cabling within the entire campus to CAT 6A.\nUpgrade of the fiber infrastructure backbone, campus wide both within buildings and between buildings and all associated civil site construction and landscaping.\nCivil site work, including the installation of concrete duct banks, installation of new pre-cast manholes, the excavation and repair of existing building waterproofing, and the restoration of site conditions.\nThe abatement of asbestos and lead based paint, including the preparation of an abatement plan in accordance with the requirements of the Maine Department of Environmental Protection.\nThe installation of a radon mitigation system, including the preparation of detailed working drawings that are signed by a radon mitigation contractor registered with the State of Maine.\nFire Suppression Upgrades including new gaseous suppression systems, and the modification of existing fire sprinkler systems. New fire sprinkler system for the new MCR Building.\nFire Alarm Upgrades.\nFirestopping and fire caulking for all wall and floor penetrations within the project scope.\nPhysical security upgrades including Physical Access Control, intrusion detection, and security cameras, as shown on the contract drawings.\nThe project buildings include: 200, 200E, 201, 203, 204, 205, 206, 207, 208, 209, 210, 211, 212, 221, 232, 235, 238, 240, 248, 255, 300, BQ1, BQ3, BQ4, BQ27, BQ32, BQ69, 248, MRI, and site.\n\nPROCUREMENT INFORMATION:\nThe proposed project will be a competitive, firm-fixed-price contract utilizing the design-bid-build approach (Final Specifications and Drawings will be provided). The anticipated solicitation will be issued as a Request For Proposal (RFP) in accordance with FAR Parts 15 and 12, considering Technical and Price Factors. The results and analysis of the market research will finalize the determination of the type of socio-economic set-aside, if any, will depend upon the responses to this notice and any other information gathered during the market research process.\n\nThis project is planned for advertising in December 2026. In accordance with VAAR 836.204, the magnitude of construction is between $50,000,000.00 and $100,000,000.00. The North American Industry Classification System (NAICS) code 236220 (size standard $45.0 million) applies to this procurement. The duration of the project is currently estimated at 730 calendar days from the issuance of a Notice to Proceed. The services for this project will include providing all construction related services such as: providing labor, materials and equipment required to complete the project as per contract documents prepared by an independent Architect-Engineer firm.\n\nThere will be an Industry Day for this project on October 27, 2026 at Building 210 at the Togus campus located at 810 Eastern Avenue, Augusta ME 04330. Information on this event can be located at the following:\n\nhttps://sam.gov/workspace/contract/opp/e4ad29ff80624636a3bd4c8a622fa460/view\n\nCAPABILITY STATEMENT:\nRespondents shall provide a general capabilities statement to include the following information:\nSection 1: Provide company name, Unique Entity Identifier (UEI), company address, Point-of-Contact name, phone number and email.\nSection 2: Provide company business size based on NAICS code 236220. Also, provide business type (i.e., Large Business, Small Business, Service-Disabled Veteran Owned Small Business, Small Disadvantaged Business, Women-Owned Small Business, Hub Zone Small Business, etc.).\nSection 3: Provide a Statement of Interest in the project.\nSection 4: Provide the prime contractor s available bonding capacity in the form of a letter of intent from your bonding company with this submission. *Please ensure that the individual bonding capacity is in line with the VAAR Magnitude of Construction listed above.\nSection 5: Provide the type of work your company has performed in the past in support of the same or similar requirement. This section is IMPORTANT as it will help to determine the type of socio-economic set-aside, if any. Please provide the following in your response:\nNo more than three (3) contracts that your company has performed within the last seven (7) years that are of comparable size, complexity, and scope to this requirement. Include the project name, project owner and contact information as this person may be contacted for further information, project scope, project size (Example: square footage), building use (Example: Medical Facility, Office Building, etc.), project dollar value, start and completion dates.\nProvide specific examples that relate aspects of previous projects to the proposed project. Describe specific technical skills and key personnel your company possess to perform the requirements described under description of work.\nDescribe your Self-Performed** effort (as either a Prime or Subcontractor). Describe Self-Performed work in terms of dollar value and description. **Self-Performed means work performed by the offeror themselves, NOT work performed by another company for them for any of the project examples provided.\nSection 6: Project Labor Agreement (PLA) - A PLA is defined as a pre-hire Collective Bargaining Agreement with one or more labor organizations that establishes the terms and conditions of employment for a specific construction project and is an agreement described in 29 U.S.C. 158(f). The PLA questionnaire must be filled out and returned with the Sources Sought response. The questionnaire can be found at the end of this document.\nSee FAR Provision: 52.222-33 Notice of Requirement for Project Labor Agreement and FAR Clause 52.222-34 Project Labor Agreement for further details.\nIt is requested that interested contractors submit a response (electronic submission) of no more than nine (9) single sided pages, single-spaced, 12-point font minimum that addresses the above information (this is inclusive of the PLA questionnaire). This response must be submitted as a single application-generated (not scanned) PDF document that is less than or equal to 4MB in size. Please note that hard copies will not be accepted. Please also include a cover page, which includes, at a minimum: the company s name, address, Unique Entity Identifier (if available), socio-economic status, point-of-contact name, phone number, and e-mail address. Responses must include the Sources Sought number and project title in the subject line of their e-mail response. Submissions (responses) shall be submitted via email to the primary point of contact listed below by October 30, 2026 at 4:00 PM ET. No phone calls will be accepted.\n\nThe Capabilities Statement submitted in response to this Sources Sought shall not be considered to be a bid or proposal. This notice is for information and planning purposes only and is neither to be construed as a commitment by the Government nor will the Government pay for information solicited. No evaluation letters and/or results will be issued to the respondents. After completing its analyses, the Government will determine whether to limit competition among the small business categories listed above or proceed with full and open competition as other than small business.\n\nAt this time no solicitation exists; therefore, please do not request a copy of the solicitation. If a solicitation is released it will be synopsized in Contract Opportunities at https://sam.gov/. It is the potential offeror's responsibility to monitor this site for the release of any solicitation or synopsis.\n\nContracting Office Address:\nVHA Program Contracting Activity Central (VHA-PCAC)\n6100 Oak Tree Blvd. Suite 300\nIndependence, OH 44131\n\nPrimary Point of Contact:\nJosh Gitchel\nContract Specialist\nJoshua.Gitchel@VA.Gov\n\nPROJECT LABOR AGREEMENT (PLA) QUESTIONNAIRE\n(Please respond to the questions below)\n\n1. Is your company familiar with Project Labor Agreement (PLA) and its use on construction projects?\n\nYes/No\n\nComments:\n\n2. Would your company likely submit a proposal for the VA construction solicitation that requires the use of a PLA?\n\nYes/No\n\nComments:\n\n3. If VA requires a PLA, would your proposed construction cost likely to increase or decrease and what is the likely percentage of cost increase or decrease?\n\nComments:\n\n4. Does the VA requirement to use of a PLA on a construction project restrict competition?\n\nYes/No\n\nComments:\n\n5. Do you expect subcontractor resistance should VA requires the use of a PLA on this construction solicitation?\n\nYes/No\n\nComments:\n\n6. Do you have additional comments regarding the use of a PLA for this project?\n\nComments:\n\n7. Has your Firm participated in projects with PLA agreements?\n\nYes/No\nÂ\na. Were there cost increases, labor shortages, or other issues experienced on contracts that had the labor union clauses? If so, please provide more details.\nÂ\nb. Did pricing remain as expected? If not, did it increase or decrease as a result?\n\nc. Was the project completed on time?\nÂ\nd. Was craftsmanship acceptable (or better) than a level typically seen on other non-union projects.\n\n--- End of PLA Questionnaire ---","origin":"detail"},"notice_type":{"code":"r","label":"Sources Sought"},"schema_version":1,"solicitation_number":"36C77627Q0022","place_of_performance":{"zip":"04330","city":{"name":"Augusta"},"state":{"name":"ME"},"street":"Industry Day: 810 Eastern Avenue"},"product_service_code":"Y1DZ"}],"due_at":"2026-10-30T20:00:00Z","due_date":"2026-10-30","closes_at":"2026-10-30T20:00:00Z","awardable":true,"dept_key":"d-036","dept_name":"VETERANS AFFAIRS, DEPARTMENT OF","sub_key":"s-3600","sub_name":"VETERANS AFFAIRS, DEPARTMENT OF","office_key":"o-36C776","office_name":"PCAC (36C776)","state":"ME","county":"23011","county_name":"Kennebec County","city":"2302100","city_name":"Augusta","country":null,"state_source":"sam_state_name","state_evidence":null,"site_key":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-10-16T04:37:13.634552Z","principal_notice_id":"1cd6ba951c8e4bd5a8df3007a214004e","description":{"text":"SYNOPSIS:\n\nINTRODUCTION:\nThis Sources Sought Notice is for market research and information purposes only at this time and shall not be construed as a solicitation or as an obligation on the part of the Department of Veterans Affairs (VA).\n\nThe Department of Veterans Affairs, Veterans Health Administration (VHA), Program Contracting Activity Central (PCAC) is conducting a market survey and is seeking potential sources for the EHRM Infrastructure Upgrades Construction project at the Togus VA Medical Center located in Togus, ME.\n\nPROJECT DESCRIPTION:\nThis project will include but not limited to the following infrastructure improvements:\n\nThe architectural demolition, reconfiguration, expansion, and renovation of existing spaces. The architectural construction of new finished spaces, doors, and flooring systems.\nThe structural alteration of existing structural components, and construction of new structural equipment support,\nElectrical upgrades including electrical panels, normal and critical power distribution, bonding, Uninterrupted Power Supplies (UPS), lighting, and new power outlets.\nThe installation and programming of Building Automation System (BAS) equipment and interfaces,\nUpgrades to existing HVAC, reprogramming of existing controls, and the installation of new HVAC and new controls.\nThe modification of existing plumbing to avoid Telecommunication Rooms, and the installation of new plumbing to support new mechanical systems, and interior drainage.\nUpgrades to data communication infrastructure including new data outlets, patch panels, seismic rated IT racks, cable management, in building as necessary. This includes the re-cabling of all existing data cabling within the entire campus to CAT 6A.\nUpgrade of the fiber infrastructure backbone, campus wide both within buildings and between buildings and all associated civil site construction and landscaping.\nCivil site work, including the installation of concrete duct banks, installation of new pre-cast manholes, the excavation and repair of existing building waterproofing, and the restoration of site conditions.\nThe abatement of asbestos and lead based paint, including the preparation of an abatement plan in accordance with the requirements of the Maine Department of Environmental Protection.\nThe installation of a radon mitigation system, including the preparation of detailed working drawings that are signed by a radon mitigation contractor registered with the State of Maine.\nFire Suppression Upgrades including new gaseous suppression systems, and the modification of existing fire sprinkler systems. New fire sprinkler system for the new MCR Building.\nFire Alarm Upgrades.\nFirestopping and fire caulking for all wall and floor penetrations within the project scope.\nPhysical security upgrades including Physical Access Control, intrusion detection, and security cameras, as shown on the contract drawings.\nThe project buildings include: 200, 200E, 201, 203, 204, 205, 206, 207, 208, 209, 210, 211, 212, 221, 232, 235, 238, 240, 248, 255, 300, BQ1, BQ3, BQ4, BQ27, BQ32, BQ69, 248, MRI, and site.\n\nPROCUREMENT INFORMATION:\nThe proposed project will be a competitive, firm-fixed-price contract utilizing the design-bid-build approach (Final Specifications and Drawings will be provided). The anticipated solicitation will be issued as a Request For Proposal (RFP) in accordance with FAR Parts 15 and 12, considering Technical and Price Factors. The results and analysis of the market research will finalize the determination of the type of socio-economic set-aside, if any, will depend upon the responses to this notice and any other information gathered during the market research process.\n\nThis project is planned for advertising in December 2026. In accordance with VAAR 836.204, the magnitude of construction is between $50,000,000.00 and $100,000,000.00. The North American Industry Classification System (NAICS) code 236220 (size standard $45.0 million) applies to this procurement. The duration of the project is currently estimated at 730 calendar days from the issuance of a Notice to Proceed. The services for this project will include providing all construction related services such as: providing labor, materials and equipment required to complete the project as per contract documents prepared by an independent Architect-Engineer firm.\n\nThere will be an Industry Day for this project on October 27, 2026 at Building 210 at the Togus campus located at 810 Eastern Avenue, Augusta ME 04330. Information on this event can be located at the following:\n\nhttps://sam.gov/workspace/contract/opp/e4ad29ff80624636a3bd4c8a622fa460/view\n\nCAPABILITY STATEMENT:\nRespondents shall provide a general capabilities statement to include the following information:\nSection 1: Provide company name, Unique Entity Identifier (UEI), company address, Point-of-Contact name, phone number and email.\nSection 2: Provide company business size based on NAICS code 236220. Also, provide business type (i.e., Large Business, Small Business, Service-Disabled Veteran Owned Small Business, Small Disadvantaged Business, Women-Owned Small Business, Hub Zone Small Business, etc.).\nSection 3: Provide a Statement of Interest in the project.\nSection 4: Provide the prime contractor s available bonding capacity in the form of a letter of intent from your bonding company with this submission. *Please ensure that the individual bonding capacity is in line with the VAAR Magnitude of Construction listed above.\nSection 5: Provide the type of work your company has performed in the past in support of the same or similar requirement. This section is IMPORTANT as it will help to determine the type of socio-economic set-aside, if any. Please provide the following in your response:\nNo more than three (3) contracts that your company has performed within the last seven (7) years that are of comparable size, complexity, and scope to this requirement. Include the project name, project owner and contact information as this person may be contacted for further information, project scope, project size (Example: square footage), building use (Example: Medical Facility, Office Building, etc.), project dollar value, start and completion dates.\nProvide specific examples that relate aspects of previous projects to the proposed project. Describe specific technical skills and key personnel your company possess to perform the requirements described under description of work.\nDescribe your Self-Performed** effort (as either a Prime or Subcontractor). Describe Self-Performed work in terms of dollar value and description. **Self-Performed means work performed by the offeror themselves, NOT work performed by another company for them for any of the project examples provided.\nSection 6: Project Labor Agreement (PLA) - A PLA is defined as a pre-hire Collective Bargaining Agreement with one or more labor organizations that establishes the terms and conditions of employment for a specific construction project and is an agreement described in 29 U.S.C. 158(f). The PLA questionnaire must be filled out and returned with the Sources Sought response. The questionnaire can be found at the end of this document.\nSee FAR Provision: 52.222-33 Notice of Requirement for Project Labor Agreement and FAR Clause 52.222-34 Project Labor Agreement for further details.\nIt is requested that interested contractors submit a response (electronic submission) of no more than nine (9) single sided pages, single-spaced, 12-point font minimum that addresses the above information (this is inclusive of the PLA questionnaire). This response must be submitted as a single application-generated (not scanned) PDF document that is less than or equal to 4MB in size. Please note that hard copies will not be accepted. Please also include a cover page, which includes, at a minimum: the company s name, address, Unique Entity Identifier (if available), socio-economic status, point-of-contact name, phone number, and e-mail address. Responses must include the Sources Sought number and project title in the subject line of their e-mail response. Submissions (responses) shall be submitted via email to the primary point of contact listed below by October 30, 2026 at 4:00 PM ET. No phone calls will be accepted.\n\nThe Capabilities Statement submitted in response to this Sources Sought shall not be considered to be a bid or proposal. This notice is for information and planning purposes only and is neither to be construed as a commitment by the Government nor will the Government pay for information solicited. No evaluation letters and/or results will be issued to the respondents. After completing its analyses, the Government will determine whether to limit competition among the small business categories listed above or proceed with full and open competition as other than small business.\n\nAt this time no solicitation exists; therefore, please do not request a copy of the solicitation. If a solicitation is released it will be synopsized in Contract Opportunities at https://sam.gov/. It is the potential offeror's responsibility to monitor this site for the release of any solicitation or synopsis.\n\nContracting Office Address:\nVHA Program Contracting Activity Central (VHA-PCAC)\n6100 Oak Tree Blvd. Suite 300\nIndependence, OH 44131\n\nPrimary Point of Contact:\nJosh Gitchel\nContract Specialist\nJoshua.Gitchel@VA.Gov\n\nPROJECT LABOR AGREEMENT (PLA) QUESTIONNAIRE\n(Please respond to the questions below)\n\n1. Is your company familiar with Project Labor Agreement (PLA) and its use on construction projects?\n\nYes/No\n\nComments:\n\n2. Would your company likely submit a proposal for the VA construction solicitation that requires the use of a PLA?\n\nYes/No\n\nComments:\n\n3. If VA requires a PLA, would your proposed construction cost likely to increase or decrease and what is the likely percentage of cost increase or decrease?\n\nComments:\n\n4. Does the VA requirement to use of a PLA on a construction project restrict competition?\n\nYes/No\n\nComments:\n\n5. Do you expect subcontractor resistance should VA requires the use of a PLA on this construction solicitation?\n\nYes/No\n\nComments:\n\n6. Do you have additional comments regarding the use of a PLA for this project?\n\nComments:\n\n7. Has your Firm participated in projects with PLA agreements?\n\nYes/No\nÂ\na. Were there cost increases, labor shortages, or other issues experienced on contracts that had the labor union clauses? If so, please provide more details.\nÂ\nb. Did pricing remain as expected? If not, did it increase or decrease as a result?\n\nc. Was the project completed on time?\nÂ\nd. Was craftsmanship acceptable (or better) than a level typically seen on other non-union projects.\n\n--- End of PLA Questionnaire ---","html":"SYNOPSIS:\n\nINTRODUCTION: \nThis Sources Sought Notice is for market research and information purposes only at this time and shall not be construed as a solicitation or as an obligation on the part of the Department of Veterans Affairs (VA).\n\nThe Department of Veterans Affairs, Veterans Health Administration (VHA), Program Contracting Activity Central (PCAC) is conducting a market survey and is seeking potential sources for the EHRM Infrastructure Upgrades Construction project at the Togus VA Medical Center   located in Togus, ME.\n\nPROJECT DESCRIPTION:\nThis project will include but not limited to the following infrastructure improvements:      \n\n  The architectural demolition, reconfiguration, expansion, and renovation of existing spaces. The architectural construction of new finished spaces, doors, and flooring systems. \n  The structural alteration of existing structural components, and construction of new structural equipment support,\n  Electrical upgrades including electrical panels, normal and critical power distribution, bonding, Uninterrupted Power Supplies (UPS), lighting, and new power outlets.\n  The installation and programming of Building Automation System (BAS) equipment and interfaces, \n  Upgrades to existing HVAC, reprogramming of existing controls, and the installation of new HVAC and new controls.\n  The modification of existing plumbing to avoid Telecommunication Rooms, and the installation of new plumbing to support new mechanical systems, and interior drainage. \n  Upgrades to data communication infrastructure including new data outlets, patch panels, seismic rated IT racks, cable management, in building as necessary. This includes the re-cabling of all existing data cabling within the entire campus to CAT 6A. \n  Upgrade of the fiber infrastructure backbone, campus wide both within buildings and between buildings and all associated civil site construction and landscaping.\n  Civil site work, including the installation of concrete duct banks, installation of new pre-cast manholes, the excavation and repair of existing building waterproofing, and the restoration of site conditions. \n  The abatement of asbestos and lead based paint, including the preparation of an abatement plan in accordance with the requirements of the Maine Department of Environmental Protection.\n  The installation of a radon mitigation system, including the preparation of detailed working drawings that are signed by a radon mitigation contractor registered with the State of Maine.\n  Fire Suppression Upgrades including new gaseous suppression systems, and the modification of existing fire sprinkler systems. New fire sprinkler system for the new MCR Building. \n  Fire Alarm Upgrades.\n  Firestopping and fire caulking for all wall and floor penetrations within the project scope.\n  Physical security upgrades including Physical Access Control, intrusion detection, and security cameras, as shown on the contract drawings.\n  The project buildings include: 200, 200E, 201, 203, 204, 205, 206, 207, 208, 209, 210, 211, 212, 221, 232, 235, 238, 240, 248, 255, 300, BQ1, BQ3, BQ4, BQ27, BQ32, BQ69, 248, MRI, and site.\n\nPROCUREMENT INFORMATION:\nThe proposed project will be a competitive, firm-fixed-price contract utilizing the design-bid-build approach (Final Specifications and Drawings will be provided). The anticipated solicitation will be issued as a Request For Proposal (RFP) in accordance with FAR Parts 15 and 12, considering Technical and Price Factors. The results and analysis of the market research will finalize the determination of the type of socio-economic set-aside, if any, will depend upon the responses to this notice and any other information gathered during the market research process.\n\nThis project is planned for advertising in December 2026. In accordance with VAAR 836.204, the magnitude of construction is between $50,000,000.00 and $100,000,000.00. The North American Industry Classification System (NAICS) code 236220 (size standard $45.0 million) applies to this procurement. The duration of the project is currently estimated at 730 calendar days from the issuance of a Notice to Proceed. The services for this project will include providing all construction related services such as: providing labor, materials and equipment required to complete the project as per contract documents prepared by an independent Architect-Engineer firm. \n\nThere will be an Industry Day for this project on October 27, 2026 at Building 210 at the Togus campus located at 810 Eastern Avenue, Augusta ME 04330. Information on this event can be located at the following:\n\nhttps://sam.gov/workspace/contract/opp/e4ad29ff80624636a3bd4c8a622fa460/view \n\nCAPABILITY STATEMENT:\nRespondents shall provide a general capabilities statement to include the following information: \nSection 1: Provide company name, Unique Entity Identifier (UEI), company address, Point-of-Contact name, phone number and email.\nSection 2: Provide company business size based on NAICS code 236220. Also, provide business type (i.e., Large Business, Small Business, Service-Disabled Veteran Owned Small Business, Small Disadvantaged Business, Women-Owned Small Business, Hub Zone Small Business, etc.). \nSection 3: Provide a Statement of Interest in the project. \nSection 4: Provide the prime contractor s available bonding capacity in the form of a letter of intent from your bonding company with this submission. *Please ensure that the individual bonding capacity is in line with the VAAR Magnitude of Construction listed above.\nSection 5: Provide the type of work your company has performed in the past in support of the same or similar requirement. This section is IMPORTANT as it will help to determine the type of socio-economic set-aside, if any. Please provide the following in your response: \nNo more than three (3) contracts that your company has performed within the last seven (7) years that are of comparable size, complexity, and scope to this requirement. Include the project name, project owner and contact information as this person may be contacted for further information, project scope, project size (Example: square footage), building use (Example: Medical Facility, Office Building, etc.), project dollar value, start and completion dates. \nProvide specific examples that relate aspects of previous projects to the proposed project. Describe specific technical skills and key personnel your company possess to perform the requirements described under description of work.\nDescribe your Self-Performed** effort (as either a Prime or Subcontractor). Describe Self-Performed work in terms of dollar value and description. **Self-Performed means work performed by the offeror themselves, NOT work performed by another company for them for any of the project examples provided.\nSection 6: Project Labor Agreement (PLA) - A PLA is defined as a pre-hire Collective Bargaining Agreement with one or more labor organizations that establishes the terms and conditions of employment for a specific construction project and is an agreement described in 29 U.S.C. 158(f). The PLA questionnaire must be filled out and returned with the Sources Sought response. The questionnaire can be found at the end of this document.\nSee FAR Provision: 52.222-33 Notice of Requirement for Project Labor Agreement and FAR Clause 52.222-34 Project Labor Agreement for further details.\nIt is requested that interested contractors submit a response (electronic submission) of no more than nine (9) single sided pages, single-spaced, 12-point font minimum that addresses the above information (this is inclusive of the PLA questionnaire). This response must be submitted as a single application-generated (not scanned) PDF document that is less than or equal to 4MB in size. Please note that hard copies will not be accepted. Please also include a cover page, which includes, at a minimum: the company s name, address, Unique Entity Identifier (if available), socio-economic status, point-of-contact name, phone number, and e-mail address. Responses must include the Sources Sought number and project title in the subject line of their e-mail response. Submissions (responses) shall be submitted via email to the primary point of contact listed below by October 30, 2026 at 4:00 PM ET. No phone calls will be accepted. \n\nThe Capabilities Statement submitted in response to this Sources Sought shall not be considered to be a bid or proposal. This notice is for information and planning purposes only and is neither to be construed as a commitment by the Government nor will the Government pay for information solicited. No evaluation letters and/or results will be issued to the respondents. After completing its analyses, the Government will determine whether to limit competition among the small business categories listed above or proceed with full and open competition as other than small business. \n\nAt this time no solicitation exists; therefore, please do not request a copy of the solicitation. If a solicitation is released it will be synopsized in Contract Opportunities at https://sam.gov/. It is the potential offeror's responsibility to monitor this site for the release of any solicitation or synopsis.  \n\nContracting Office Address:  \nVHA Program Contracting Activity Central (VHA-PCAC)\n6100 Oak Tree Blvd. Suite 300\nIndependence, OH 44131 \n\nPrimary Point of Contact:\nJosh Gitchel\nContract Specialist\nJoshua.Gitchel@VA.Gov  \n\n\n\n \nPROJECT LABOR AGREEMENT (PLA) QUESTIONNAIRE\n(Please respond to the questions below)\n\n1. Is your company familiar with Project Labor Agreement (PLA) and its use on construction projects? \n\nYes/No \n\nComments:\n\n2. Would your company likely submit a proposal for the VA construction solicitation that requires the use of a PLA? \n\nYes/No \n\nComments: \n\n3. If VA requires a PLA, would your proposed construction cost likely to increase or decrease and what is the likely percentage of cost increase or decrease? \n\nComments:\n\n 4. Does the VA requirement to use of a PLA on a construction project restrict competition? \n\nYes/No \n\nComments: \n\n5. Do you expect subcontractor resistance should VA requires the use of a PLA on this construction solicitation? \n\nYes/No \n\nComments: \n\n6. Do you have additional comments regarding the use of a PLA for this project?\n\nComments:\n\n\n7. Has your Firm participated in projects with PLA agreements? \n\nYes/No \n \na. Were there cost increases, labor shortages, or other issues experienced on contracts that had the labor union clauses? If so, please provide more details.\n \nb. Did pricing remain as expected? If not, did it increase or decrease as a result?\n\nc. Was the project completed on time?\n \nd. Was craftsmanship acceptable (or better) than a level typically seen on other non-union projects.\n\n\n\n\n--- End of PLA Questionnaire ---","origin":"detail"},"contacts":[{"name":"joshua.gitchel@va.gov","role":"primary","email":"joshua.gitchel@va.gov","phone":"216-447-8300","title":"Josh Gitchel"}],"place_of_performance":{"zip":"04330","city":{"name":"Augusta"},"state":{"name":"ME"},"street":"Industry Day: 810 Eastern Avenue"},"office_address":{"zip":"44131","city":"INDEPENDENCE","state":"OH","country":"USA"},"naics_codes":["236220"],"award":{"awardee":{}},"attachments":[{"resource_id":"6b8ee6fd92ed4eb2b3973fc4b7374b7c","name":"36C77627Q0022.docx","kind":"file","mime_type":".docx","size_bytes":23189,"posted_at":"2026-10-15T15:25:51.077Z","export_controlled":false,"sha256":null,"url":"https://sam.gov/api/prod/opps/v3/opportunities/resources/files/6b8ee6fd92ed4eb2b3973fc4b7374b7c/download","mirrored":false}],"awards":[],"related":[{"key":"36C77627Q0025","latest_notice_id":"06d655aa7b63488e90b48ff6e9334427","title":"605-341 - Relocate Dialysis Minor Construct - Loma Linda, CA","solicitation_number":"36C77627Q0025","notice_type":"r","first_type":"r","first_posted":"2026-10-20","last_posted":"2026-10-27","notices":2,"due_at":"2026-11-03T21:00:00Z","due_date":"2026-11-03","closes_at":"2026-11-03T21:00:00Z","awardable":true,"open":true,"removed":false,"dept_key":"d-036","dept_name":"VETERANS AFFAIRS, DEPARTMENT OF","sub_key":"s-3600","sub_name":"VETERANS AFFAIRS, DEPARTMENT OF","office_key":"o-36C776","office_name":"PCAC (36C776)","naics":"236220","psc":"Y1DZ","set_aside":null,"state":"CA","county":"06071","county_name":"San Bernardino County","city":"0642370","city_name":"Loma Linda","country":"USA","place_scope":"site","state_source":null,"state_evidence":null,"site":null,"site_key":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"removed_at":null,"updated_at":"2026-10-28T04:01:09.175983Z"},{"key":"36C77626Q0274","latest_notice_id":"0ac31cc25ab14f1a8a1c89454a30e6c5","title":"Q702--Martinsburg, WV Warehouse IOTA","solicitation_number":"36C77626Q0274","notice_type":"o","first_type":"p","first_posted":"2026-09-17","last_posted":"2026-10-28","notices":5,"due_at":"2026-11-04T15:00:00Z","due_date":"2026-11-04","closes_at":"2026-11-04T15:00:00Z","awardable":true,"open":true,"removed":false,"dept_key":"d-036","dept_name":"VETERANS AFFAIRS, DEPARTMENT OF","sub_key":"s-3600","sub_name":"VETERANS AFFAIRS, DEPARTMENT OF","office_key":"o-36C776","office_name":"PCAC (36C776)","naics":"541614","psc":"Q702","set_aside":"SDVOSBC","state":"WV","county":null,"county_name":null,"city":null,"city_name":null,"country":"USA","place_scope":"site","state_source":"title","state_evidence":"Q702--MARTINSBURG, WV","site":null,"site_key":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"removed_at":null,"updated_at":"2026-10-29T04:15:54.363094Z"},{"key":"36C77626R0118","latest_notice_id":"1c660a2fe04340faa6425e90b28fcbb7","title":"Y1DA--512A5-22-700 | EHRM Infra Upgrades | Perry Point, MD CO: Samantha Mihaila CS: Ric Sochor","solicitation_number":"36C77626R0118","notice_type":"p","first_type":"p","first_posted":"2026-10-21","last_posted":"2026-10-21","notices":1,"due_at":"2026-11-05T20:00:00Z","due_date":"2026-11-05","closes_at":"2026-11-05T20:00:00Z","awardable":true,"open":true,"removed":false,"dept_key":"d-036","dept_name":"VETERANS AFFAIRS, DEPARTMENT OF","sub_key":"s-3600","sub_name":"VETERANS AFFAIRS, DEPARTMENT OF","office_key":"o-36C776","office_name":"PCAC (36C776)","naics":"236220","psc":"Y1DA","set_aside":"SDVOSBC","state":"MD","county":null,"county_name":null,"city":null,"city_name":null,"country":null,"place_scope":"site","state_source":"title","state_evidence":"12A5-22-700 | EHRM INFRA UPGRADES | PERRY POINT, MD","site":null,"site_key":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"removed_at":null,"updated_at":"2026-10-22T04:09:15.685315Z"},{"key":"36C77627Q0036","latest_notice_id":"f1ec30f92ffe4e8db4bf04f1bb6aa713","title":"613-22-700 | EHRM Infrastructure Upgrades Construction | Martinsburg, WV","solicitation_number":"36C77627Q0036","notice_type":"r","first_type":"r","first_posted":"2026-10-23","last_posted":"2026-10-23","notices":1,"due_at":"2026-11-06T17:00:00Z","due_date":"2026-11-06","closes_at":"2026-11-06T17:00:00Z","awardable":true,"open":true,"removed":false,"dept_key":"d-036","dept_name":"VETERANS AFFAIRS, DEPARTMENT OF","sub_key":"s-3600","sub_name":"VETERANS AFFAIRS, DEPARTMENT OF","office_key":"o-36C776","office_name":"PCAC (36C776)","naics":"236220","psc":"Y1DA","set_aside":null,"state":"WV","county":"54003","county_name":"Berkeley County","city":null,"city_name":null,"country":"USA","place_scope":"site","state_source":null,"state_evidence":null,"site":null,"site_key":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"removed_at":null,"updated_at":"2026-10-24T03:56:54.139438Z"},{"key":"36C77627B00021","latest_notice_id":"dcb1fd7334634bfcbfbdbdf245b849c7","title":"Expand 111 OR Department 2AS Phase 1 - Construction - Milwaukee, WI - Project:695-501","solicitation_number":"36C77627B0002_1","notice_type":"p","first_type":"p","first_posted":"2026-10-07","last_posted":"2026-10-07","notices":1,"due_at":"2026-11-10T15:00:00Z","due_date":"2026-11-10","closes_at":"2026-11-10T15:00:00Z","awardable":true,"open":true,"removed":false,"dept_key":"d-036","dept_name":"VETERANS AFFAIRS, DEPARTMENT OF","sub_key":"s-3600","sub_name":"VETERANS AFFAIRS, DEPARTMENT OF","office_key":"o-36C776","office_name":"PCAC (36C776)","naics":"236220","psc":"Z1DA","set_aside":"SDVOSBC","state":"WI","county":"55079","county_name":"Milwaukee County","city":"5553000","city_name":"Milwaukee","country":"USA","place_scope":"site","state_source":null,"state_evidence":null,"site":null,"site_key":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"removed_at":null,"updated_at":"2026-10-08T03:46:32.887903Z"}],"similar_open":[{"key":"FA441826R0009","latest_notice_id":"f12091512ef942f486dc11ff2cb79ede","title":"JB Charleston Multiple Award Construction Contract","solicitation_number":"FA441826R0009","notice_type":"o","first_type":"o","first_posted":"2026-07-23","last_posted":"2026-10-30","notices":8,"due_at":"2026-11-02T17:00:00Z","due_date":"2026-11-02","closes_at":"2026-11-02T17:00:00Z","awardable":true,"open":true,"removed":false,"dept_key":"d-057","dept_name":"DEPT OF DEFENSE","sub_key":"s-5700","sub_name":"DEPT OF THE AIR FORCE","office_key":"o-FA4418","office_name":"FA4418 628 CONS PK","naics":"236220","psc":"Y1JZ","set_aside":null,"state":"SC","county":"45019","county_name":"Charleston County","city":null,"city_name":null,"country":"USA","place_scope":"site","state_source":null,"state_evidence":null,"site":null,"site_key":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"removed_at":null,"updated_at":"2026-10-31T03:50:03.904859Z"},{"key":"W912QR26RFICONSOLIDATEDPROJECTSWPAFB","latest_notice_id":"f2756ddd0e984cc19099220bfce9e686","title":"REQUEST FOR INFORMATION (RFI) / MARKET RESEARCH NOTICE RELATED TO SEVERAL UPCOMING PROJECTS at WRIGHT-PATTERSON AFB, OHIO","solicitation_number":"W912QR26_RFI_CONSOLIDATEDPROJECTS_WPAFB","notice_type":"r","first_type":"r","first_posted":"2026-10-07","last_posted":"2026-10-21","notices":4,"due_at":"2026-11-02T17:00:00Z","due_date":"2026-11-02","closes_at":"2026-11-02T17:00:00Z","awardable":true,"open":true,"removed":false,"dept_key":"d-021","dept_name":"DEPT OF DEFENSE","sub_key":"s-2100","sub_name":"DEPT OF THE ARMY","office_key":"o-W912QR","office_name":"W072 ENDIST LOUISVILLE","naics":"236220","psc":null,"set_aside":null,"state":"OH","county":"39057","county_name":"Greene County","city":"3986660","city_name":"Wright-Patterson AFB","country":"USA","place_scope":"site","state_source":null,"state_evidence":null,"site":"Wright-Patterson Air Force Base","site_key":"wright-patterson-air-force-base-oh","winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"removed_at":null,"updated_at":"2026-10-22T04:09:15.685315Z"},{"key":"FA813727R0002","latest_notice_id":"7f105ecbe35f4d1d822ca089d54bc22e","title":"WWYK250063 - INSTALL REACT VII FACILITY, B9001, POST V19","solicitation_number":"FA813727R0002","notice_type":"o","first_type":"o","first_posted":"2026-10-05","last_posted":"2026-10-15","notices":2,"due_at":"2026-11-02T20:00:00Z","due_date":"2026-11-02","closes_at":"2026-11-02T20:00:00Z","awardable":true,"open":true,"removed":false,"dept_key":"d-057","dept_name":"DEPT OF DEFENSE","sub_key":"s-5700","sub_name":"DEPT OF THE AIR FORCE","office_key":"o-FA8137","office_name":"FA8137 AFSC PZIOC","naics":"236220","psc":"Z1AA","set_aside":"WOSB","state":"OK","county":"40109","county_name":"Oklahoma County","city":null,"city_name":null,"country":"USA","place_scope":"site","state_source":null,"state_evidence":null,"site":null,"site_key":null,"winner":null,"winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"removed_at":null,"updated_at":"2026-10-16T03:38:05.572608Z"}],"similar_open_total":184}