{"canonical":"https://abierto.us/opportunities/12905b24r0011","key":"12905B24R0011","url":"https://abierto.us/opportunities/12905b24r0011","title":"Amendment 02- 12905B24R0011 - USDA Water System Improvements DuBois, ID","solicitation_number":"12905B24R0011","notice_type":"o","open":false,"response_deadline":"2024-07-24T00:00:00Z","first_posted":"2024-05-14","last_posted":"2024-07-11","department":"AGRICULTURE, DEPARTMENT OF","subagency":"AGRICULTURAL RESEARCH SERVICE","office":"USDA ARS PWA AAO ACQ/PER PROP","naics":"237110","psc":"Y1NE","set_aside":"SBA","place_state":"ID","place_county":"16033","place_county_name":"Clark County","place_city":"1622960","place_city_name":"Dubois","winner":null,"award_amount":null,"publications":[{"notice_id":"73c9f65588a34f049b75c57ee66965b6","title":"12905B24R0011 - USDA Water System Improvements DuBois, ID","solicitation_number":"12905B24R0011","notice_type":"p","base_type":"r","posted":"2024-05-14","posted_at":null,"due_at":"2024-07-04T00:05:00Z","due_date":"2024-07-03","cancelled":null,"archived":null,"archive_date":"2024-07-18","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/73c9f65588a34f049b75c57ee66965b6/view","enriched":false,"history":[]},{"notice_id":"2cfa78d8a96b437cb9ecdad76ab7820e","title":"12905B24R0011 - USDA Water System Improvements DuBois, ID","solicitation_number":"12905B24R0011","notice_type":"p","base_type":"p","posted":"2024-05-15","posted_at":null,"due_at":"2024-05-29T00:00:00Z","due_date":"2024-05-28","cancelled":null,"archived":null,"archive_date":"2024-06-12","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/2cfa78d8a96b437cb9ecdad76ab7820e/view","enriched":false,"history":[]},{"notice_id":"1a7dcf0e95894805bc7b99151c5df13d","title":"12905B24R0011 - USDA Water System Improvements DuBois, ID","solicitation_number":"12905B24R0011","notice_type":"o","base_type":"p","posted":"2024-06-05","posted_at":null,"due_at":"2024-07-10T00:00:00Z","due_date":"2024-07-09","cancelled":null,"archived":null,"archive_date":"2024-07-24","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/1a7dcf0e95894805bc7b99151c5df13d/view","enriched":false,"history":[]},{"notice_id":"7badd8b4ad6e4cf381e11be9cef13899","title":"12905B24R0011 - USDA Water System Improvements DuBois, ID","solicitation_number":"12905B24R0011","notice_type":"o","base_type":"o","posted":"2024-06-27","posted_at":null,"due_at":"2024-07-10T00:00:00Z","due_date":"2024-07-09","cancelled":null,"archived":null,"archive_date":"2024-07-24","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/7badd8b4ad6e4cf381e11be9cef13899/view","enriched":false,"history":[]},{"notice_id":"7555ae59220e4d00a3005e48133ee606","title":"Amendment 01 - 12905B24R0011 - USDA Water System Improvements DuBois, ID","solicitation_number":"12905B24R0011","notice_type":"o","base_type":"o","posted":"2024-07-08","posted_at":null,"due_at":"2024-07-19T00:00:00Z","due_date":"2024-07-18","cancelled":null,"archived":null,"archive_date":"2024-08-02","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/7555ae59220e4d00a3005e48133ee606/view","enriched":false,"history":[]},{"notice_id":"d8c27d06077d41d990e459d98805d0a2","title":"Amendment 02- 12905B24R0011 - USDA Water System Improvements DuBois, ID","solicitation_number":"12905B24R0011","notice_type":"o","base_type":"o","posted":"2024-07-11","posted_at":null,"due_at":"2024-07-24T00:00:00Z","due_date":"2024-07-23","cancelled":null,"archived":null,"archive_date":"2024-08-07","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/d8c27d06077d41d990e459d98805d0a2/view","enriched":false,"history":[]}],"latest_notice_id":"d8c27d06077d41d990e459d98805d0a2","first_type":"p","notices":[{"dates":{"posted":"2024-05-14","response_deadline":{"raw":"2024-07-03T17:05:00-07:00","utc":"2024-07-04T00:05:00Z","date":"2024-07-03","time":"17:05:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/73c9f65588a34f049b75c57ee66965b6/view"},"naics":{"codes":["237110"],"primary":"237110"},"title":"12905B24R0011 - USDA Water System Improvements DuBois, ID","agency":{"office":{"code":"12905B","name":"USDA ARS PWA AAO ACQ/PER PROP"},"subtier":{"code":"12H2","name":"AGRICULTURAL RESEARCH SERVICE"},"department":{"code":"012","name":"AGRICULTURE, DEPARTMENT OF"},"office_address":{"zip":"94710","city":"ALBANY","state":"CA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-07-18","archive_type":"auto15"},"contacts":[{"name":"Theodore Blume","role":"primary","email":"Theodore.Blume@usda.gov"}],"base_type":{"code":"r","label":"Sources Sought"},"notice_id":"73c9f65588a34f049b75c57ee66965b6","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"3633048889b1661219502cbf2d539fef8fe67cd04ac0fc83a86db71006dd8213","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"THIS IS AN INFORMATIONAL NOTICE ONLY The United States Department of Agriculture (USDA), Agricultural Research Service (ARS), Pacific West Area Office has a construction requirement for the following but is not limited to: Drill new water well to provide an additional potable water source for site; decommission and cap existing well in building; upgrade and add piping in wellhouse including the chlorination system; construct new valve vault near water storage tank; rehabilitate water storage tank interior; and a new telemetry system. Work shall include temporary potable water storage and phasing of work to minimize impacts to residents. All work shall include testing (of temporary and permanent facilities), connections and all appurtenances required to provide a functioning well and potable water system. Electrical: Disconnect existing well #2 while maintaining power to building. Provide new 480-volt power supply for new well. Provide PLC base monitoring /control with telemetry from water tank to wellhouse at USDA-ARS-PWS Range Sheep Production Efficiency Research Unit, 19 Office Loop DuBoise ID 83423. The Contractor shall provide all labor, equipment, materials, supplies, transportation, and supervision performing all required work in accordance with the plans and specifications for this requirement. In accordance with Federal Acquisition Regulation (FAR) 36.204 the magnitude of this construction project is between $500,000.00 and $1,000,000.00. USDA will issue a Firm Fixed Price Construction Contract. The Request for Proposal 12905B24R0011 may be issued on or around 28 May 2024. The requirement will be 100% total set-aside for small business, under NAICS Code 237110 with a size standard of $45M. Completion timeframe for the resulting contract is to be determined. The RFP will be accessible via https://sam.gov/ in the “Contracting Opportunities” section. Potential Offerors are responsible for monitoring this site for release of the RFP package and any amendments. All offerors shall be registered with the System for Award Management Registration per FAR Clause 52.204-7 and 52.204-8. No paper copies of the solicitation will be mailed and telephone requests will not be honored.","origin":"extract"},"notice_type":{"code":"p","label":"Presolicitation"},"schema_version":1,"solicitation_number":"12905B24R0011","place_of_performance":{"zip":"83423","city":{"name":"Dubois"},"state":{"code":"ID"},"country":{"code":"USA"}},"product_service_code":"Y1NE"},{"dates":{"posted":"2024-05-15","response_deadline":{"raw":"2024-05-28T17:00:00-07:00","utc":"2024-05-29T00:00:00Z","date":"2024-05-28","time":"17:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/2cfa78d8a96b437cb9ecdad76ab7820e/view"},"naics":{"codes":["237110"],"primary":"237110"},"title":"12905B24R0011 - USDA Water System Improvements DuBois, ID","agency":{"office":{"code":"12905B","name":"USDA ARS PWA AAO ACQ/PER PROP"},"subtier":{"code":"12H2","name":"AGRICULTURAL RESEARCH SERVICE"},"department":{"code":"012","name":"AGRICULTURE, DEPARTMENT OF"},"office_address":{"zip":"94710","city":"ALBANY","state":"CA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-06-12","archive_type":"auto15"},"contacts":[{"name":"Theodore Blume","role":"primary","email":"Theodore.Blume@usda.gov"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"2cfa78d8a96b437cb9ecdad76ab7820e","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"800a984578cb2a52b9a82e5d554709510ea3bf2acbff9bf6be3635a1108fae40","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"THIS IS AN INFORMATIONAL NOTICE ONLY The United States Department of Agriculture (USDA), Agricultural Research Service (ARS), Pacific West Area Office has a construction requirement for the following but is not limited to: Drill new water well to provide an additional potable water source for site; decommission and cap existing well in building; upgrade and add piping in wellhouse including the chlorination system; construct new valve vault near water storage tank; rehabilitate water storage tank interior; and a new telemetry system. Work shall include temporary potable water storage and phasing of work to minimize impacts to residents. All work shall include testing (of temporary and permanent facilities), connections and all appurtenances required to provide a functioning well and potable water system. Electrical: Disconnect existing well #2 while maintaining power to building. Provide new 480-volt power supply for new well. Provide PLC base monitoring /control with telemetry from water tank to wellhouse at USDA-ARS-PWS Range Sheep Production Efficiency Research Unit, 19 Office Loop DuBoise ID 83423. The Contractor shall provide all labor, equipment, materials, supplies, transportation, and supervision performing all required work in accordance with the plans and specifications for this requirement. In accordance with Federal Acquisition Regulation (FAR) 36.204 the magnitude of this construction project is between $500,000.00 and $1,000,000.00. USDA will issue a Firm Fixed Price Construction Contract. The Request for Proposal 12905B24R0011 may be issued on or around 28 May 2024. The requirement will be 100% total set-aside for small business, under NAICS Code 237110 with a size standard of $45M. Completion timeframe for the resulting contract is to be determined. The RFP will be accessible via https://sam.gov/ in the “Contracting Opportunities” section. Potential Offerors are responsible for monitoring this site for release of the RFP package and any amendments. All offerors shall be registered with the System for Award Management Registration per FAR Clause 52.204-7 and 52.204-8. No paper copies of the solicitation will be mailed and telephone requests will not be honored.","origin":"extract"},"notice_type":{"code":"p","label":"Presolicitation"},"schema_version":1,"solicitation_number":"12905B24R0011","place_of_performance":{"zip":"83423","city":{"name":"Dubois"},"state":{"code":"ID"},"country":{"code":"USA"}},"product_service_code":"Y1NE"},{"dates":{"posted":"2024-06-05","response_deadline":{"raw":"2024-07-09T17:00:00-07:00","utc":"2024-07-10T00:00:00Z","date":"2024-07-09","time":"17:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/1a7dcf0e95894805bc7b99151c5df13d/view"},"naics":{"codes":["237110"],"primary":"237110"},"title":"12905B24R0011 - USDA Water System Improvements DuBois, ID","agency":{"office":{"code":"12905B","name":"USDA ARS PWA AAO ACQ/PER PROP"},"subtier":{"code":"12H2","name":"AGRICULTURAL RESEARCH SERVICE"},"department":{"code":"012","name":"AGRICULTURE, DEPARTMENT OF"},"office_address":{"zip":"94710","city":"ALBANY","state":"CA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-07-24","archive_type":"auto15"},"contacts":[{"name":"Theodore Blume","role":"primary","email":"Theodore.Blume@usda.gov"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"1a7dcf0e95894805bc7b99151c5df13d","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"00e8cc3edd642656faa22d099c8c7f83f3fa6872be5fc0c2ff1b65df1648cedd","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"This is the only official location where these documents can be obtained and where updates are posted. The United States Department of Agriculture (USDA), Agricultural Research Service (ARS), Pacific West Area Office has a construction requirement for the following but is not limited to: Drill new water well to provide an additional potable water source for site; decommission and cap existing well in building; upgrade and add piping in wellhouse including the chlorination system; construct new valve vault near water storage tank; rehabilitate water storage tank interior; and a new telemetry system. Work shall include temporary potable water storage and phasing of work to minimize impacts to residents. All work shall include testing (of temporary and permanent facilities), connections and all appurtenances required to provide a functioning well and potable water system. Electrical: Disconnect existing well #2 while maintaining power to building. Provide new 480-volt power supply for new well. Provide PLC base monitoring /control with telemetry from water tank to wellhouse at USDA-ARS-PWS Range Sheep Production Efficiency Research Unit, 19 Office Loop DuBoise ID 83423. The Contractor shall provide all labor, equipment, materials, supplies, transportation, and supervision performing all required work in accordance with the plans and specifications for this requirement. Potential Offerors are responsible for monitoring this site for release of any amendments. No ‘hard copy’ solicitation materials are available. No paper copies of the solicitation will be mailed, and telephone requests will not be honored. MAGNITUDE OF CONSTRUCTION PROJECT - Between $500,000 and $1,000,000. A single organized site visit is completed on Wednesday, 12 June 2024 at 10:00 a.m. Mountain Time. Please ensure to sign on-site sign-in sheet All questions pertaining to this solicitation, including questions that arise during the site visit, must be submitted to theodore.blume@usda.gov by 1:00 p.m. Mountain Time, Monday, 24 June 2024 via the Attachment V - RFI form. Bid Bond Guarantees are also required when the proposal is above $150K. Proposals are to receive no later than 5:00 p.m. Pacific Time, Tuesday, 9 July 2024. Ensure proposal follows submittal instructions in Section L. Proposal must be in writing and emailed to: theodore.blume@usda.gov PROPOSAL MUST BE ANNOTATED AS SUCH AND REFERENCE THE SOLICITATION NUMBER. 12905B24R0011 Late proposals submitted after this deadline may be considered only if it is in the government’s best interest and if it will not unduly delay award. Note: Performance and Payment bonds will be required after award should they meet the threshold per FAR 28.102. As a general reference, payment bonds are needed for all proposals above $35K and performance bonds are needed above $150K. Payment and Performance bonds are due ten (10) days after award and must be accepted by the Contracting Officer prior to mobilization.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"12905B24R0011","place_of_performance":{"zip":"83423","city":{"name":"Dubois"},"state":{"code":"ID"},"country":{"code":"USA"}},"product_service_code":"Y1NE"},{"dates":{"posted":"2024-06-27","response_deadline":{"raw":"2024-07-09T17:00:00-07:00","utc":"2024-07-10T00:00:00Z","date":"2024-07-09","time":"17:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/7badd8b4ad6e4cf381e11be9cef13899/view"},"naics":{"codes":["237110"],"primary":"237110"},"title":"12905B24R0011 - USDA Water System Improvements DuBois, ID","agency":{"office":{"code":"12905B","name":"USDA ARS PWA AAO ACQ/PER PROP"},"subtier":{"code":"12H2","name":"AGRICULTURAL RESEARCH SERVICE"},"department":{"code":"012","name":"AGRICULTURE, DEPARTMENT OF"},"office_address":{"zip":"94710","city":"ALBANY","state":"CA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-07-24","archive_type":"auto15"},"contacts":[{"name":"Theodore Blume","role":"primary","email":"Theodore.Blume@usda.gov"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"7badd8b4ad6e4cf381e11be9cef13899","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"c44c8e7ce31b9ddbd083f10b1137244505c80181d16b7dabe71095cf27698d33","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"CONTRACTOR QUESTIONS ARE NOW UPLOADED INTO THE ATTACHMENTS. NOTE: SOME QUESTIONS WILL RECEIVE RESPONSES ON 8 JULY 2024. This is the only official location where these documents can be obtained and where updates are posted. The United States Department of Agriculture (USDA), Agricultural Research Service (ARS), Pacific West Area Office has a construction requirement for the following but is not limited to: Drill new water well to provide an additional potable water source for site; decommission and cap existing well in building; upgrade and add piping in wellhouse including the chlorination system; construct new valve vault near water storage tank; rehabilitate water storage tank interior; and a new telemetry system. Work shall include temporary potable water storage and phasing of work to minimize impacts to residents. All work shall include testing (of temporary and permanent facilities), connections and all appurtenances required to provide a functioning well and potable water system. Electrical: Disconnect existing well #2 while maintaining power to building. Provide new 480-volt power supply for new well. Provide PLC base monitoring /control with telemetry from water tank to wellhouse at USDA-ARS-PWS Range Sheep Production Efficiency Research Unit, 19 Office Loop DuBoise ID 83423. The Contractor shall provide all labor, equipment, materials, supplies, transportation, and supervision performing all required work in accordance with the plans and specifications for this requirement. Potential Offerors are responsible for monitoring this site for release of any amendments. No ‘hard copy’ solicitation materials are available. No paper copies of the solicitation will be mailed, and telephone requests will not be honored. MAGNITUDE OF CONSTRUCTION PROJECT - Between $500,000 and $1,000,000. A single organized site visit is completed on Wednesday, 12 June 2024 at 10:00 a.m. Mountain Time. Please ensure to sign on-site sign-in sheet All questions pertaining to this solicitation, including questions that arise during the site visit, must be submitted to theodore.blume@usda.gov by 1:00 p.m. Mountain Time, Monday, 24 June 2024 via the Attachment V - RFI form. Bid Bond Guarantees are also required when the proposal is above $150K. Proposals are to receive no later than 5:00 p.m. Pacific Time, Tuesday, 9 July 2024. Ensure proposal follows submittal instructions in Section L. Proposal must be in writing and emailed to: theodore.blume@usda.gov PROPOSAL MUST BE ANNOTATED AS SUCH AND REFERENCE THE SOLICITATION NUMBER. 12905B24R0011 Late proposals submitted after this deadline may be considered only if it is in the government’s best interest and if it will not unduly delay award. Note: Performance and Payment bonds will be required after award should they meet the threshold per FAR 28.102. As a general reference, payment bonds are needed for all proposals above $35K and performance bonds are needed above $150K. Payment and Performance bonds are due ten (10) days after award and must be accepted by the Contracting Officer prior to mobilization.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"12905B24R0011","place_of_performance":{"zip":"83423","city":{"name":"Dubois"},"state":{"code":"ID"},"country":{"code":"USA"}},"product_service_code":"Y1NE"},{"dates":{"posted":"2024-07-08","response_deadline":{"raw":"2024-07-18T17:00:00-07:00","utc":"2024-07-19T00:00:00Z","date":"2024-07-18","time":"17:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/7555ae59220e4d00a3005e48133ee606/view"},"naics":{"codes":["237110"],"primary":"237110"},"title":"Amendment 01 - 12905B24R0011 - USDA Water System Improvements DuBois, ID","agency":{"office":{"code":"12905B","name":"USDA ARS PWA AAO ACQ/PER PROP"},"subtier":{"code":"12H2","name":"AGRICULTURAL RESEARCH SERVICE"},"department":{"code":"012","name":"AGRICULTURE, DEPARTMENT OF"},"office_address":{"zip":"94710","city":"ALBANY","state":"CA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-08-02","archive_type":"auto15"},"contacts":[{"name":"Theodore Blume","role":"primary","email":"Theodore.Blume@usda.gov"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"7555ae59220e4d00a3005e48133ee606","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"c1a3cba01a3bb2a63dcef910839fd61d03909f764eaeac82ec7e9c176643fb22","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"AMENDMENT 01 - The RFP close date is extended to 18 July 2024 at 5:00pm PDT. Remaining contractor RFI responses will be posted on Amendment 02 once received. CONTRACTOR QUESTIONS ARE NOW UPLOADED INTO THE ATTACHMENTS. NOTE: SOME QUESTIONS WILL RECEIVE RESPONSES ON 8 JULY 2024. This is the only official location where these documents can be obtained and where updates are posted. The United States Department of Agriculture (USDA), Agricultural Research Service (ARS), Pacific West Area Office has a construction requirement for the following but is not limited to: Drill new water well to provide an additional potable water source for site; decommission and cap existing well in building; upgrade and add piping in wellhouse including the chlorination system; construct new valve vault near water storage tank; rehabilitate water storage tank interior; and a new telemetry system. Work shall include temporary potable water storage and phasing of work to minimize impacts to residents. All work shall include testing (of temporary and permanent facilities), connections and all appurtenances required to provide a functioning well and potable water system. Electrical: Disconnect existing well #2 while maintaining power to building. Provide new 480-volt power supply for new well. Provide PLC base monitoring /control with telemetry from water tank to wellhouse at USDA-ARS-PWS Range Sheep Production Efficiency Research Unit, 19 Office Loop DuBoise ID 83423. The Contractor shall provide all labor, equipment, materials, supplies, transportation, and supervision performing all required work in accordance with the plans and specifications for this requirement. Potential Offerors are responsible for monitoring this site for release of any amendments. No ‘hard copy’ solicitation materials are available. No paper copies of the solicitation will be mailed, and telephone requests will not be honored. MAGNITUDE OF CONSTRUCTION PROJECT - Between $500,000 and $1,000,000. A single organized site visit is completed on Wednesday, 12 June 2024 at 10:00 a.m. Mountain Time. Please ensure to sign on-site sign-in sheet All questions pertaining to this solicitation, including questions that arise during the site visit, must be submitted to theodore.blume@usda.gov by 1:00 p.m. Mountain Time, Monday, 24 June 2024 via the Attachment V - RFI form. Bid Bond Guarantees are also required when the proposal is above $150K. Proposals are to receive no later than 5:00 p.m. Pacific Time, Tuesday, 9 July 2024. Ensure proposal follows submittal instructions in Section L. Proposal must be in writing and emailed to: theodore.blume@usda.gov PROPOSAL MUST BE ANNOTATED AS SUCH AND REFERENCE THE SOLICITATION NUMBER. 12905B24R0011 Late proposals submitted after this deadline may be considered only if it is in the government’s best interest and if it will not unduly delay award. Note: Performance and Payment bonds will be required after award should they meet the threshold per FAR 28.102. As a general reference, payment bonds are needed for all proposals above $35K and performance bonds are needed above $150K. Payment and Performance bonds are due ten (10) days after award and must be accepted by the Contracting Officer prior to mobilization.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"12905B24R0011","place_of_performance":{"zip":"83423","city":{"name":"Dubois"},"state":{"code":"ID"},"country":{"code":"USA"}},"product_service_code":"Y1NE"},{"dates":{"posted":"2024-07-11","response_deadline":{"raw":"2024-07-23T17:00:00-07:00","utc":"2024-07-24T00:00:00Z","date":"2024-07-23","time":"17:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/d8c27d06077d41d990e459d98805d0a2/view"},"naics":{"codes":["237110"],"primary":"237110"},"title":"Amendment 02- 12905B24R0011 - USDA Water System Improvements DuBois, ID","agency":{"office":{"code":"12905B","name":"USDA ARS PWA AAO ACQ/PER PROP"},"subtier":{"code":"12H2","name":"AGRICULTURAL RESEARCH SERVICE"},"department":{"code":"012","name":"AGRICULTURE, DEPARTMENT OF"},"office_address":{"zip":"94710","city":"ALBANY","state":"CA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-08-07","archive_type":"auto15"},"contacts":[{"name":"Theodore Blume","role":"primary","email":"Theodore.Blume@usda.gov"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"d8c27d06077d41d990e459d98805d0a2","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"d30c687f0cb257ae5e645430035626e2f17c96ac824cb6ca46d9053efffd9a3e","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"AMENDMENT 02 - The RFP close date is extended to 23 July 2024 at 5:00pm PDT. This amendment amends the Specifications 09 97 13.16, visise paragraph 1.4.5.2 Qualifications of QC Specialist Coating Inspectios and revise paragraph 2.2 Coating System. These revisions are located in the attached Questions and Answer document. Also, the preliminary engineering report titled USDA ARS PER-FINAL has been uploaded as it is referenced in the revisions mentioned above. AMENDMENT 01 - The RFP close date is extended to 18 July 2024 at 5:00pm PDT. Remaining contractor RFI responses will be posted on Amendment 02 once received. CONTRACTOR QUESTIONS ARE NOW UPLOADED INTO THE ATTACHMENTS. NOTE: SOME QUESTIONS WILL RECEIVE RESPONSES ON 8 JULY 2024. This is the only official location where these documents can be obtained and where updates are posted. The United States Department of Agriculture (USDA), Agricultural Research Service (ARS), Pacific West Area Office has a construction requirement for the following but is not limited to: Drill new water well to provide an additional potable water source for site; decommission and cap existing well in building; upgrade and add piping in wellhouse including the chlorination system; construct new valve vault near water storage tank; rehabilitate water storage tank interior; and a new telemetry system. Work shall include temporary potable water storage and phasing of work to minimize impacts to residents. All work shall include testing (of temporary and permanent facilities), connections and all appurtenances required to provide a functioning well and potable water system. Electrical: Disconnect existing well #2 while maintaining power to building. Provide new 480-volt power supply for new well. Provide PLC base monitoring /control with telemetry from water tank to wellhouse at USDA-ARS-PWS Range Sheep Production Efficiency Research Unit, 19 Office Loop DuBoise ID 83423. The Contractor shall provide all labor, equipment, materials, supplies, transportation, and supervision performing all required work in accordance with the plans and specifications for this requirement. Potential Offerors are responsible for monitoring this site for release of any amendments. No ‘hard copy’ solicitation materials are available. No paper copies of the solicitation will be mailed, and telephone requests will not be honored. MAGNITUDE OF CONSTRUCTION PROJECT - Between $500,000 and $1,000,000. A single organized site visit is completed on Wednesday, 12 June 2024 at 10:00 a.m. Mountain Time. Please ensure to sign on-site sign-in sheet All questions pertaining to this solicitation, including questions that arise during the site visit, must be submitted to theodore.blume@usda.gov by 1:00 p.m. Mountain Time, Monday, 24 June 2024 via the Attachment V - RFI form. Bid Bond Guarantees are also required when the proposal is above $150K. Proposals are to receive no later than 5:00 p.m. Pacific Time, Tuesday, 9 July 2024. Ensure proposal follows submittal instructions in Section L. Proposal must be in writing and emailed to: theodore.blume@usda.gov PROPOSAL MUST BE ANNOTATED AS SUCH AND REFERENCE THE SOLICITATION NUMBER. 12905B24R0011 Late proposals submitted after this deadline may be considered only if it is in the government’s best interest and if it will not unduly delay award. Note: Performance and Payment bonds will be required after award should they meet the threshold per FAR 28.102. As a general reference, payment bonds are needed for all proposals above $35K and performance bonds are needed above $150K. Payment and Performance bonds are due ten (10) days after award and must be accepted by the Contracting Officer prior to mobilization.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"12905B24R0011","place_of_performance":{"zip":"83423","city":{"name":"Dubois"},"state":{"code":"ID"},"country":{"code":"USA"}},"product_service_code":"Y1NE"}],"due_at":"2024-07-24T00:00:00Z","due_date":"2024-07-23","closes_at":"2024-07-24T00:00:00Z","awardable":true,"dept_key":"d-012","dept_name":"AGRICULTURE, DEPARTMENT OF","sub_key":"s-12H2","sub_name":"AGRICULTURAL RESEARCH SERVICE","office_key":"o-12905B","office_name":"USDA ARS PWA AAO ACQ/PER PROP","state":"ID","county":"16033","county_name":"Clark County","city":"1622960","city_name":"Dubois","country":"USA","winner_key":null,"amount":null,"linked_awards":0,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z","principal_notice_id":"d8c27d06077d41d990e459d98805d0a2","description":{"text":"AMENDMENT 02 - The RFP close date is extended to 23 July 2024 at 5:00pm PDT. This amendment amends the Specifications 09 97 13.16, visise paragraph 1.4.5.2 Qualifications of QC Specialist Coating Inspectios and revise paragraph 2.2 Coating System. These revisions are located in the attached Questions and Answer document. Also, the preliminary engineering report titled USDA ARS PER-FINAL has been uploaded as it is referenced in the revisions mentioned above. AMENDMENT 01 - The RFP close date is extended to 18 July 2024 at 5:00pm PDT. Remaining contractor RFI responses will be posted on Amendment 02 once received. CONTRACTOR QUESTIONS ARE NOW UPLOADED INTO THE ATTACHMENTS. NOTE: SOME QUESTIONS WILL RECEIVE RESPONSES ON 8 JULY 2024. This is the only official location where these documents can be obtained and where updates are posted. The United States Department of Agriculture (USDA), Agricultural Research Service (ARS), Pacific West Area Office has a construction requirement for the following but is not limited to: Drill new water well to provide an additional potable water source for site; decommission and cap existing well in building; upgrade and add piping in wellhouse including the chlorination system; construct new valve vault near water storage tank; rehabilitate water storage tank interior; and a new telemetry system. Work shall include temporary potable water storage and phasing of work to minimize impacts to residents. All work shall include testing (of temporary and permanent facilities), connections and all appurtenances required to provide a functioning well and potable water system. Electrical: Disconnect existing well #2 while maintaining power to building. Provide new 480-volt power supply for new well. Provide PLC base monitoring /control with telemetry from water tank to wellhouse at USDA-ARS-PWS Range Sheep Production Efficiency Research Unit, 19 Office Loop DuBoise ID 83423. The Contractor shall provide all labor, equipment, materials, supplies, transportation, and supervision performing all required work in accordance with the plans and specifications for this requirement. Potential Offerors are responsible for monitoring this site for release of any amendments. No ‘hard copy’ solicitation materials are available. No paper copies of the solicitation will be mailed, and telephone requests will not be honored. MAGNITUDE OF CONSTRUCTION PROJECT - Between $500,000 and $1,000,000. A single organized site visit is completed on Wednesday, 12 June 2024 at 10:00 a.m. Mountain Time. Please ensure to sign on-site sign-in sheet All questions pertaining to this solicitation, including questions that arise during the site visit, must be submitted to theodore.blume@usda.gov by 1:00 p.m. Mountain Time, Monday, 24 June 2024 via the Attachment V - RFI form. Bid Bond Guarantees are also required when the proposal is above $150K. Proposals are to receive no later than 5:00 p.m. Pacific Time, Tuesday, 9 July 2024. Ensure proposal follows submittal instructions in Section L. Proposal must be in writing and emailed to: theodore.blume@usda.gov PROPOSAL MUST BE ANNOTATED AS SUCH AND REFERENCE THE SOLICITATION NUMBER. 12905B24R0011 Late proposals submitted after this deadline may be considered only if it is in the government’s best interest and if it will not unduly delay award. Note: Performance and Payment bonds will be required after award should they meet the threshold per FAR 28.102. As a general reference, payment bonds are needed for all proposals above $35K and performance bonds are needed above $150K. Payment and Performance bonds are due ten (10) days after award and must be accepted by the Contracting Officer prior to mobilization.","html":null,"origin":"extract"},"contacts":[{"name":"Theodore Blume","role":"primary","email":"Theodore.Blume@usda.gov"}],"place_of_performance":{"zip":"83423","city":{"name":"Dubois"},"state":{"code":"ID"},"country":{"code":"USA"}},"office_address":{"zip":"94710","city":"ALBANY","state":"CA","country":"USA"},"naics_codes":["237110"],"award":null,"attachments":[],"awards":[],"related":[]}