{"canonical":"https://abierto.us/opportunities/12905b24q0086","key":"12905B24Q0086","url":"https://abierto.us/opportunities/12905b24q0086","title":"Annex Building Electrical and Data Outlet Installation project located in Hilo, HI.","solicitation_number":"12905B24Q0086","notice_type":"a","open":false,"response_deadline":"2024-05-24T20:00:00Z","first_posted":"2024-04-21","last_posted":"2024-06-06","department":"AGRICULTURE, DEPARTMENT OF","subagency":"AGRICULTURAL RESEARCH SERVICE","office":"USDA ARS PWA AAO ACQ/PER PROP","naics":"238210","psc":"Z2AA","set_aside":"SBA","place_state":"HI","place_county":"15001","place_county_name":"Hawaii County","place_city":"1514650","place_city_name":"Hilo","winner":"DKN ELECTRICAL LLC","award_amount":"26525.48","publications":[{"notice_id":"07df33d0201749abadb70bbcf562ac46","title":"Annex Building Electrical and Data Outlet Installation project located in Hilo, HI.","solicitation_number":"12905B24Q0086","notice_type":"p","base_type":"p","posted":"2024-04-21","posted_at":null,"due_at":"2024-05-03T20:00:00Z","due_date":"2024-05-03","cancelled":null,"archived":null,"archive_date":"2024-05-04","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/07df33d0201749abadb70bbcf562ac46/view","enriched":false,"history":[]},{"notice_id":"bb0fbb631aec443aaade75b8bfbd7d80","title":"Annex Building Electrical and Data Outlet Installation project located in Hilo, HI.","solicitation_number":"12905B24Q0086","notice_type":"p","base_type":"p","posted":"2024-04-21","posted_at":null,"due_at":"2024-05-03T20:00:00Z","due_date":"2024-05-03","cancelled":null,"archived":null,"archive_date":"2024-05-04","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/bb0fbb631aec443aaade75b8bfbd7d80/view","enriched":false,"history":[]},{"notice_id":"5b4e95b2e98a4506b75d04f991ce4259","title":"Annex Building Electrical and Data Outlet Installation project located in Hilo, HI.","solicitation_number":"12905B24Q0086","notice_type":"o","base_type":"p","posted":"2024-05-06","posted_at":null,"due_at":"2024-05-24T20:00:00Z","due_date":"2024-05-24","cancelled":null,"archived":null,"archive_date":"2024-05-26","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/5b4e95b2e98a4506b75d04f991ce4259/view","enriched":false,"history":[]},{"notice_id":"e52699ac52564d978d76913f79e2bf01","title":"Annex Building Electrical and Data Outlet Installation project located in Hilo, HI.","solicitation_number":"12905B24Q0086","notice_type":"o","base_type":"o","posted":"2024-05-15","posted_at":null,"due_at":"2024-05-24T20:00:00Z","due_date":"2024-05-24","cancelled":null,"archived":null,"archive_date":"2024-05-26","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/e52699ac52564d978d76913f79e2bf01/view","enriched":false,"history":[]},{"notice_id":"9bb3ea5f91d14e5f9e2dfb103ad49be9","title":"Annex Building Electrical and Data Outlet Installation project located in Hilo, HI.","solicitation_number":"12905B24Q0086","notice_type":"o","base_type":"o","posted":"2024-05-17","posted_at":null,"due_at":"2024-05-24T20:00:00Z","due_date":"2024-05-24","cancelled":null,"archived":null,"archive_date":"2024-05-26","award_number":null,"awardee_name":null,"amount":null,"link_sam":"https://sam.gov/workspace/contract/opp/9bb3ea5f91d14e5f9e2dfb103ad49be9/view","enriched":false,"history":[]},{"notice_id":"6729e4288af54c19bdd5e3491a5bed85","title":"Annex Building Electrical and Data Outlet Installation project located in Hilo, HI.","solicitation_number":"12905B24Q0086","notice_type":"a","base_type":"o","posted":"2024-06-06","posted_at":null,"due_at":null,"due_date":null,"cancelled":null,"archived":null,"archive_date":"2024-07-06","award_number":"12905B24P0099","awardee_name":"DKN ELECTRICAL LLC Pahoa","amount":"26525.48","link_sam":"https://sam.gov/workspace/contract/opp/6729e4288af54c19bdd5e3491a5bed85/view","enriched":false,"history":[]}],"latest_notice_id":"6729e4288af54c19bdd5e3491a5bed85","first_type":"p","notices":[{"dates":{"posted":"2024-04-21","response_deadline":{"raw":"2024-05-03T13:00:00-07:00","utc":"2024-05-03T20:00:00Z","date":"2024-05-03","time":"13:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/07df33d0201749abadb70bbcf562ac46/view"},"naics":{"codes":["238210"],"primary":"238210"},"title":"Annex Building Electrical and Data Outlet Installation project located in Hilo, HI.","agency":{"office":{"code":"12905B","name":"USDA ARS PWA AAO ACQ/PER PROP"},"subtier":{"code":"12H2","name":"AGRICULTURAL RESEARCH SERVICE"},"department":{"code":"012","name":"AGRICULTURE, DEPARTMENT OF"},"office_address":{"zip":"94710","city":"ALBANY","state":"CA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-05-04","archive_type":"auto_custom"},"contacts":[{"name":"Mr. Lam Pham","role":"primary","email":"lam.pham@usda.gov"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"07df33d0201749abadb70bbcf562ac46","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"90f40801bf246739708284bc4ffd208f315762320a69ff02753ac552c848e08f","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"The United States Department of Agriculture (USDA), Agricultural Research Service (ARS), Pacific West Area (PWA) Office has a construction project for the Annex Building Electrical and Date Outlet located at 64 Nowelo Street, Hilo, Hawaii 96720. The contractor shall provide all labor, equipment, materials, supplies, transportation, and supervision performing all required work in accordance with the plans and specifications for this requirement. In accordance with Federal Acquisition Regulation (FAR) 36.204 the magnitude of this construction project is between $25,000 and $100,000. USDA will issue a Firm Fixed Price Construction Contract. The Request for Quotation (RFQ) 12905B24Q0086 may be issued on or around May 06, 2024 The requirement will be 100 % SMALL BUSINESS SET ASIDE, under NAICS Code 238210 with a size standard of $19.0 Completion timeframe for the resulting contract is to be determined. The RFQ will be accessible via https://sam.gov/ in the “Contracting Opportunities” section. Potential Offerors are responsible for monitoring this site for release of the RFQ package and any amendments. All offerors shall be registered with the System for Award Management Registration per FAR Clause 52.204-7 and 52.204-8. No paper copies of the solicitation will be mailed, and telephone requests will not be honored. Pursuant to FAR 36.211(b), information regarding USDA’s definitization of equitable adjustments for change orders under construction contracts may be found at https://www.usda.gov/da/ocp/contracting USDA’s procedures that apply to the definitization of equitable adjustments for change orders under construction contracts may be found in the USDA Contracting Desk Book, located at https://www.usda.gov/da/ocp/ppd/policies-regulations , under Parts 436 and 443.","origin":"extract"},"notice_type":{"code":"p","label":"Presolicitation"},"schema_version":1,"solicitation_number":"12905B24Q0086","place_of_performance":{"zip":"96720","city":{"name":"Hilo"},"state":{"code":"HI"},"country":{"code":"USA"}},"product_service_code":"Z2AA"},{"dates":{"posted":"2024-04-21","response_deadline":{"raw":"2024-05-03T13:00:00-07:00","utc":"2024-05-03T20:00:00Z","date":"2024-05-03","time":"13:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/bb0fbb631aec443aaade75b8bfbd7d80/view"},"naics":{"codes":["238210"],"primary":"238210"},"title":"Annex Building Electrical and Data Outlet Installation project located in Hilo, HI.","agency":{"office":{"code":"12905B","name":"USDA ARS PWA AAO ACQ/PER PROP"},"subtier":{"code":"12H2","name":"AGRICULTURAL RESEARCH SERVICE"},"department":{"code":"012","name":"AGRICULTURE, DEPARTMENT OF"},"office_address":{"zip":"94710","city":"ALBANY","state":"CA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-05-04","archive_type":"auto_custom"},"contacts":[{"name":"Mr. Lam Pham","role":"primary","email":"lam.pham@usda.gov"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"bb0fbb631aec443aaade75b8bfbd7d80","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"01736a94cdf42ecbfc50747755fca52265c54fe2bce24c936d576803f29a56d6","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"The United States Department of Agriculture (USDA), Agricultural Research Service (ARS), Pacific West Area (PWA) Office has a construction project for the Annex Building Electrical and Date Outlet located at 64 Nowelo Street, Hilo, Hawaii 96720. The contractor shall provide all labor, equipment, materials, supplies, transportation, and supervision performing all required work in accordance with the plans and specifications for this requirement. In accordance with Federal Acquisition Regulation (FAR) 36.204 the magnitude of this construction project is between $25,000 and $100,000. USDA will issue a Firm Fixed Price Construction Contract. The Request for Quotation (RFQ) 12905B24Q0086 may be issued on or around May 06, 2024 The requirement will be 100 % SMALL BUSINESS SET ASIDE, under NAICS Code 238210 with a size standard of $19.0 Completion timeframe for the resulting contract is to be determined. The RFQ will be accessible via https://sam.gov/ in the “Contracting Opportunities” section. Potential Offerors are responsible for monitoring this site for release of the RFQ package and any amendments. All offerors shall be registered with the System for Award Management Registration per FAR Clause 52.204-7 and 52.204-8. No paper copies of the solicitation will be mailed, and telephone requests will not be honored. Pursuant to FAR 36.211(b), information regarding USDA’s definitization of equitable adjustments for change orders under construction contracts may be found at https://www.usda.gov/da/ocp/contracting USDA’s procedures that apply to the definitization of equitable adjustments for change orders under construction contracts may be found in the USDA Contracting Desk Book, located at https://www.usda.gov/da/ocp/ppd/policies-regulations , under Parts 436 and 443.","origin":"extract"},"notice_type":{"code":"p","label":"Presolicitation"},"schema_version":1,"solicitation_number":"12905B24Q0086","place_of_performance":{"zip":"96720","city":{"name":"Hilo"},"state":{"code":"HI"},"country":{"code":"USA"}},"product_service_code":"Z2AA"},{"dates":{"posted":"2024-05-06","response_deadline":{"raw":"2024-05-24T13:00:00-07:00","utc":"2024-05-24T20:00:00Z","date":"2024-05-24","time":"13:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/5b4e95b2e98a4506b75d04f991ce4259/view"},"naics":{"codes":["238210"],"primary":"238210"},"title":"Annex Building Electrical and Data Outlet Installation project located in Hilo, HI.","agency":{"office":{"code":"12905B","name":"USDA ARS PWA AAO ACQ/PER PROP"},"subtier":{"code":"12H2","name":"AGRICULTURAL RESEARCH SERVICE"},"department":{"code":"012","name":"AGRICULTURE, DEPARTMENT OF"},"office_address":{"zip":"94710","city":"ALBANY","state":"CA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-05-26","archive_type":"auto_custom"},"contacts":[{"name":"Mr. Lam Pham","role":"primary","email":"lam.pham@usda.gov"}],"base_type":{"code":"p","label":"Presolicitation"},"notice_id":"5b4e95b2e98a4506b75d04f991ce4259","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"2bc92fafa7c9d7ceb1d05aaa1db6ae2c2d97d852fead69f5ac45777631b39e00","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"The estimated magnitude of this project is between $25,000 and $100,000 ---------------------------------------------------------------------------------------------------- A single site visit will be scheduled for Tuesday 05/14/2024 at 09:00 am local time. This site visit is intended to give prospective offerors the opportunity to familiarize themselves with the location and to gauge the scope of work required of the contract. Prospective attendees SHALL email: lam.pham@usda.gov; pernell.hanoa@usda.gov; carlee.wehrsig@usda.gov ; with the attendee's full name as it appears on a Government-issued picture ID (which must be presented at the time of the site visit) and citizenship status, and their company name, physical address, email address, and phone number. The deadline for requesting a site visit is Monday 05/13/2024 at 10:00 am Local Time. Failure to comply with the registration instructions above will result in denial of access to the location and/or participation in site visit activities. --------------------------------------------------------------------------------------------------------------- All questions pertaining to this solicitation must be submitted in writing using the Request for Information form via email to lam.pham@usda.gov by 11:00 a.m. Pacific Time, on Thursday, 05/16/2024. Questions that are not submitted in writing using the Request for Information form or that are not submitted by this deadline above may not receive a response. Answers to all Questions will be incorporated into the solicitation by an amendment. ------------------------------------------------------------------------------------------------------------ Quotes are to receive no later than 1:00 p.m. Pacific Time, on Friday May 24, 2024. Quote must be in writing and emailed to: lam.pham@usda.gov Late quotes after this deadline may be considered only if it is in the government’s best interest and if it will not unduly delay award. To be considered for award, quotes must be submitted by email by the noted due date & time to lam.pham@usda.gov Any other method of submitting your quote may result in your quote not being considered.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"12905B24Q0086","place_of_performance":{"zip":"96720","city":{"name":"Hilo"},"state":{"code":"HI"},"country":{"code":"USA"}},"product_service_code":"Z2AA"},{"dates":{"posted":"2024-05-15","response_deadline":{"raw":"2024-05-24T13:00:00-07:00","utc":"2024-05-24T20:00:00Z","date":"2024-05-24","time":"13:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/e52699ac52564d978d76913f79e2bf01/view"},"naics":{"codes":["238210"],"primary":"238210"},"title":"Annex Building Electrical and Data Outlet Installation project located in Hilo, HI.","agency":{"office":{"code":"12905B","name":"USDA ARS PWA AAO ACQ/PER PROP"},"subtier":{"code":"12H2","name":"AGRICULTURAL RESEARCH SERVICE"},"department":{"code":"012","name":"AGRICULTURE, DEPARTMENT OF"},"office_address":{"zip":"94710","city":"ALBANY","state":"CA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-05-26","archive_type":"auto_custom"},"contacts":[{"name":"Mr. Lam Pham","role":"primary","email":"lam.pham@usda.gov"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"e52699ac52564d978d76913f79e2bf01","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"d0d12bf9926bdefbd4a496c49d78cb70ae25247f38358c3de3d5c09bdbd1f837","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"The estimated magnitude of this project is between $25,000 and $100,000 --------------------------------------------------------------------------------------------------------------- All questions pertaining to this solicitation must be submitted in writing using the Request for Information form via email to lam.pham@usda.gov by 11:00 a.m. Pacific Time, on Thursday, 05/16/2024. Questions that are not submitted in writing using the Request for Information form or that are not submitted by this deadline above may not receive a response. Answers to all Questions will be incorporated into the solicitation by an amendment. ------------------------------------------------------------------------------------------------------------ Quotes are to receive no later than 1:00 p.m. Pacific Time, on Friday May 24, 2024. Quote must be in writing and emailed to: lam.pham@usda.gov Late quotes after this deadline may be considered only if it is in the government’s best interest and if it will not unduly delay award. To be considered for award, quotes must be submitted by email by the noted due date & time to lam.pham@usda.gov Any other method of submitting your quote may result in your quote not being considered.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"12905B24Q0086","place_of_performance":{"zip":"96720","city":{"name":"Hilo"},"state":{"code":"HI"},"country":{"code":"USA"}},"product_service_code":"Z2AA"},{"dates":{"posted":"2024-05-17","response_deadline":{"raw":"2024-05-24T13:00:00-07:00","utc":"2024-05-24T20:00:00Z","date":"2024-05-24","time":"13:00:00","utc_offset_seconds":-25200}},"links":{"sam":"https://sam.gov/workspace/contract/opp/9bb3ea5f91d14e5f9e2dfb103ad49be9/view"},"naics":{"codes":["238210"],"primary":"238210"},"title":"Annex Building Electrical and Data Outlet Installation project located in Hilo, HI.","agency":{"office":{"code":"12905B","name":"USDA ARS PWA AAO ACQ/PER PROP"},"subtier":{"code":"12H2","name":"AGRICULTURAL RESEARCH SERVICE"},"department":{"code":"012","name":"AGRICULTURE, DEPARTMENT OF"},"office_address":{"zip":"94710","city":"ALBANY","state":"CA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-05-26","archive_type":"auto_custom"},"contacts":[{"name":"Mr. Lam Pham","role":"primary","email":"lam.pham@usda.gov"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"9bb3ea5f91d14e5f9e2dfb103ad49be9","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"9eed979e67ba7337c41c1c92b674c45b529cc2dcc710960321ac8787d8e5846f","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"description":{"text":"The estimated magnitude of this project is between $25,000 and $100,000 --------------------------------------------------------------------------------------------------------------- All questions pertaining to this solicitation must be submitted in writing using the Request for Information form via email to lam.pham@usda.gov by 11:00 a.m. Pacific Time, on Thursday, 05/16/2024. Questions that are not submitted in writing using the Request for Information form or that are not submitted by this deadline above may not receive a response. Answers to all Questions will be incorporated into the solicitation by an amendment. ------------------------------------------------------------------------------------------------------------ Quotes are to receive no later than 1:00 p.m. Pacific Time, on Friday May 24, 2024. Quote must be in writing and emailed to: lam.pham@usda.gov Late quotes after this deadline may be considered only if it is in the government’s best interest and if it will not unduly delay award. To be considered for award, quotes must be submitted by email by the noted due date & time to lam.pham@usda.gov Any other method of submitting your quote may result in your quote not being considered.","origin":"extract"},"notice_type":{"code":"o","label":"Solicitation"},"schema_version":1,"solicitation_number":"12905B24Q0086","place_of_performance":{"zip":"96720","city":{"name":"Hilo"},"state":{"code":"HI"},"country":{"code":"USA"}},"product_service_code":"Z2AA"},{"award":{"date":"2024-06-06","amount":"26525.48","number":"12905B24P0099","awardee":{"raw":"DKN ELECTRICAL LLC Pahoa HI 96778 USA","name":"DKN ELECTRICAL LLC Pahoa","location":{"zip":"96778","state":{"code":"HI"},"country":{"code":"USA"}}}},"dates":{"posted":"2024-06-06","award_date":"2024-06-06"},"links":{"sam":"https://sam.gov/workspace/contract/opp/6729e4288af54c19bdd5e3491a5bed85/view"},"naics":{"codes":["238210"],"primary":"238210"},"title":"Annex Building Electrical and Data Outlet Installation project located in Hilo, HI.","agency":{"office":{"code":"12905B","name":"USDA ARS PWA AAO ACQ/PER PROP"},"subtier":{"code":"12H2","name":"AGRICULTURAL RESEARCH SERVICE"},"department":{"code":"012","name":"AGRICULTURE, DEPARTMENT OF"},"office_address":{"zip":"94710","city":"ALBANY","state":"CA","country":"USA"},"organization_type":"OFFICE"},"status":{"active":false,"archive_date":"2024-07-06","archive_type":"auto_custom"},"contacts":[{"name":"Mr. Lam Pham","role":"primary","email":"lam.pham@usda.gov"}],"base_type":{"code":"o","label":"Solicitation"},"notice_id":"6729e4288af54c19bdd5e3491a5bed85","set_aside":{"code":"SBA","label":"Total Small Business Set-Aside (FAR 19.5)"},"provenance":{"extract":{"url":"https://s3.amazonaws.com/falextracts/Contract%20Opportunities/Archived%20Data/FY2024_archived_opportunities.csv","etag":"\"d582488fe153a9f11bf629913d176ffc-137\"","fetched_at":"2026-09-16T19:07:39.720164Z","row_sha256":"677a204fbe879504da20656fa1fec5970f545c983f888a9d2098f60bdd9aeb3c","last_modified":"2026-09-13T14:47:40Z"},"updated_at":"2026-09-16T19:07:39.720164Z","first_seen_at":"2026-09-16T19:07:39.720164Z"},"notice_type":{"code":"a","label":"Award Notice"},"schema_version":1,"solicitation_number":"12905B24Q0086","place_of_performance":{"zip":"96720","city":{"name":"Hilo"},"state":{"code":"HI"},"country":{"code":"USA"}},"product_service_code":"Z2AA"}],"due_at":"2024-05-24T20:00:00Z","due_date":"2024-05-24","closes_at":"2024-05-24T20:00:00Z","awardable":false,"dept_key":"d-012","dept_name":"AGRICULTURE, DEPARTMENT OF","sub_key":"s-12H2","sub_name":"AGRICULTURAL RESEARCH SERVICE","office_key":"o-12905B","office_name":"USDA ARS PWA AAO ACQ/PER PROP","state":"HI","county":"15001","county_name":"Hawaii County","city":"1514650","city_name":"Hilo","country":"USA","winner_key":"DL7BGHEFD3M9","amount":"26525.48","linked_awards":6,"cancelled":false,"archived":false,"updated_at":"2026-09-16T21:18:12.857524Z","principal_notice_id":"9bb3ea5f91d14e5f9e2dfb103ad49be9","description":{"text":"The estimated magnitude of this project is between $25,000 and $100,000 --------------------------------------------------------------------------------------------------------------- All questions pertaining to this solicitation must be submitted in writing using the Request for Information form via email to lam.pham@usda.gov by 11:00 a.m. Pacific Time, on Thursday, 05/16/2024. Questions that are not submitted in writing using the Request for Information form or that are not submitted by this deadline above may not receive a response. Answers to all Questions will be incorporated into the solicitation by an amendment. ------------------------------------------------------------------------------------------------------------ Quotes are to receive no later than 1:00 p.m. Pacific Time, on Friday May 24, 2024. Quote must be in writing and emailed to: lam.pham@usda.gov Late quotes after this deadline may be considered only if it is in the government’s best interest and if it will not unduly delay award. To be considered for award, quotes must be submitted by email by the noted due date & time to lam.pham@usda.gov Any other method of submitting your quote may result in your quote not being considered.","html":null,"origin":"extract"},"contacts":[{"name":"Mr. Lam Pham","role":"primary","email":"lam.pham@usda.gov"}],"place_of_performance":{"zip":"96720","city":{"name":"Hilo"},"state":{"code":"HI"},"country":{"code":"USA"}},"office_address":{"zip":"94710","city":"ALBANY","state":"CA","country":"USA"},"naics_codes":["238210"],"award":null,"attachments":[],"awards":[{"award_key":"CONT_AWD_12905B24P0099_12H2_-NONE-_-NONE-","permalink":"https://www.usaspending.gov/award/CONT_AWD_12905B24P0099_12H2_-NONE-_-NONE-/","piid":"12905B24P0099","parent_piid":null,"award_type":"PURCHASE ORDER","vendor_key":"DL7BGHEFD3M9","recipient_name":"DKN ELECTRICAL LLC","recipient_uei":"DL7BGHEFD3M9","recipient_cage":"9DHZ3","recipient_city":"PAHOA","recipient_state":"HI","sub_name":"Agricultural Research Service","office_name":"USDA ARS PWA AAO ACQ/PER PROP","office_key":"o-12905B","first_action_date":"2024-06-06","last_action_date":"2024-06-06","actions":1,"obligated":"26525.48","current_total_value":"26525.48","potential_total_value":"26525.48","naics":"238210","psc":"Z2AA","extent_competed":"COMPETED UNDER SAP","set_aside":"SMALL BUSINESS SET ASIDE - TOTAL","offers_received":12,"description":"DATA AND ELECTRICAL BUILDING NETWORK INSTALLATION","method":"piid","confidence":"high","evidence":["award number 12905B24P0099 equals the contract number","same awarding office 12905B"],"opportunity_key":null,"opportunity_title":null}],"related":[]}